1)_GOGA_149952_P15PS01390.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Patricia Auten 303-987-6689

1x

P15PS01390

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Golden Gate National Recreation Area, Alcatraz Island (Building 68) - GOGA 149952

Project Title: Stabilize and Repair the Exterior Walls of the Cellhouse for

Visitor/Resource Protection

County, State: San Francisco County, California

Estimated Value: $15,000,000 - $20,000,000

SITE VISIT: July 15, 2015 - 9:00 a.m. Pacific Time Participants will meet at the

Golden Gate National Parks, Park Headquarters Building 201, Fort Mason, San

Francisco, CA 94123-0022 (Use the entrance at Franklin and Bay Streets)

PLEASE NOTE: Due to limited transportation to the island for site tours, it is mandatory that ALL interested parties RSVP via email to Patti Auten at

Patti_Auten@nps.gov. Your RSVP must include the name of your company and ALL the names of those who will be attending, including your subcontractors. (See Section L for further details)

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

15 365 calendar days and complete it within ________________ ________________ calendar days after receiving

Section F - Clause 52.211-10

08/10/2015

NSN 7540-01-155-3212

x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d) x

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, DSC Contracting Services Div 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

David E. Thomas

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Solicitation Document No.

P15PS01390

Document Title

GOGA 149952 Cellhouse (Building 68) Alcatraz Island

TABLE OF CONTENTS

SECTION B – SUPPLIES OR SERVICES AND PRICES

CONTRACT PRICE SCHEDULES

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

WORK COVERED BY CONTRACT DOCUMENTS

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F - DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEP 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

DIAPR 2010-14 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JUL 2010)

DIAPR 2011-04 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(IPP) (APR 2013)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

CLAUSE 1: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE ITEMS

CLAUSE 2: KEY PERSONNEL

LIABILITY INSURANCE - DEPARTMENT OF THE INTERIOR (JULY 1996)

LOCAL CLAUSE - 52.203-99 PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN

INTERNAL CONFIDENTIALITY AGREEMENTS (DEVIATION 2015-02) (FEB 2015)

SECTION I – CONTRACT CLAUSES

52.202-1 DEFINITIONS (NOV 2013)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-7 ANTI-KICKBACK PROCEDURES (MAY 2014)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (OCT 2010)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APR 2010)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (DEC 2007)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER FIBER CONTENT PAPER (MAY 2011)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUL 2013) .. 40

Document Title

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (JUL 2013)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (JAN 2014)

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (AUG 2013)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013) 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (DEC 2014)

52.210-1 MARKET RESEARCH (APR 2011)

52.215-2 AUDIT AND RECORDS—NEGOTIATION (OCT 2010)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984)

52.215-8 ORDER OF PRECEDENCE—UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—MODIFICATIONS (AUG 2011)

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (OCT 2010)

52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN CERTIFIED

COST OR PRICING DATA—MODIFICATIONS (OCT 2010)

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS (OCT 2014)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT 2014)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (OCT 2014)—ALTERNATE II (OCT 2001)

52.219-16 LIQUIDATED DAMAGES—SUBCONTRACTING PLAN (JAN 1999)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JUL 2013)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS—OVERTIME COMPENSATION (MAY 2014)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (MAY 2014)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (MAY 2014)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION—DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIREMENTS AND RELATED REGULATIONS

(MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APRIL 2015)

52.222-26 EQUAL OPPORTUNITY (APRIL 2015)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APRIL 2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUL 2014)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

Document Title

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUL 2014)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (MARCH 2015)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (AUG 2013)

52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 13658 (DEC 2014)

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

(SEP 2013)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)—ALTERNATE I

(JAN 1995)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011) – ALTERNATE I (MAY 2011)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA- DESIGNATED

PRODUCTS (MAY 2008)

52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)

52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2008)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (AUG 2011) . 89

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.225-11 BUY AMERICAN-CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS UNDER TRADE

AGREEMENTS (MAY 2014)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (DEC 2007)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.228-1 BID GUARANTEE (SEP 1996)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE—WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 PLEDGES OF ASSETS (JAN 2012)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (MAY 2014)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS—CONSTRUCTION (OCT 2010)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (MAY 2014)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

Document Title

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (DEC 2013)

52.233-1 DISPUTES (MAY 2014)—ALTERNATE I (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-16 QUANTITY SURVEYS (Apr 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (APR 2015)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING—CONSTRUCTION (OCT 2010)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012)—ALTERNATE I

(SEPT 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

SECTION J – LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

52.203-98 PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN INTERNAL

CONFIDENTIALITY AGREEMENTS—REPRESENTATION (DEVIATION 2015-02) (FEB 2015)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (NOV 2014)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS—REPRESENTATION

(DEC 2014)

Document Title

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

52.236-28 PREPARATION OF PROPOSALS—CONSTRUCTION (OCT 1997)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION

A. GENERAL:

B. SUBMISSION INSTRUCTIONS:

C. PROPOSAL FORMAT:

VOLUME I - TECHNICAL PROPOSAL

VOLUME II - BUSINESS AND PRICE PROPOSAL:

52.204-7 SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (NOV 2014)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (NOV 2014)

52.211-6 BRAND NAME OR EQUAL (AUG 1999)

52.215-1 INSTRUCTIONS TO OFFERORS—COMPETITIVE ACQUISITION (JAN 2004)

52.215-16 FACILITIES CAPITAL COST OF MONEY (JUN 2003)

52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN CERTIFIED

COST OR PRICING DATA (OCT 2010)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE INTERIOR (APR 1984)

52.216-1 TYPE OF CONTRACT (APR 1984)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS – SECONDARY SITE OF THE WORK (MAY 2014) 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

1452.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (SEPT 2006) (DEVIATION JUL 1996)

52.236-27 SITE VISIT (CONSTRUCTION) – ALTERNATE I (FEB 1995)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

SECTION M – EVALUATION FACTORS FOR AWARD

SIGNIFICANT FACTORS AND SUBFACTORS

A. BASIS FOR AWARD:

B. EVALUATION PROCESS:

C. EVALUATION FACTORS:

VOLUME I

1. FACTOR 1 - TECHNICAL CAPABILITY:

2. FACTOR 2 - PAST PERFORMANCE:

VOLUME II

NON TECHNICAL FACTOR I – SUBCONTRACTING PLAN:

NON TECHNICAL FACTOR III - PRICE:

D. RELATIVE IMPORTANCE OF EVALUATION FACTORS:

PROVISIONS

52.217-5 -- EVALUATION OF OPTIONS. (JUL 1990)

Document Title

SECTION B – SUPPLIES OR SERVICES AND PRICES

CONTRACT PRICE SCHEDULES

The following Contract Price Schedules are for reference only, please complete and submit using the attached Excel file with your proposal.

CONTRACT

LINE ITEM

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

BASE (PHASE 2A)

1 General Work Items 1 Lump Sum $0.00 $0.00 2 Type F Concrete Patch - With Anodes 1137 S.F. $0.00 $0.00 3 Type F Concrete Patch - No Anodes 106 S.F. $0.00 4 Type FT Concrete Patch - With Anodes 2 S.F. $0.00 5 Type FT Concrete Patch - No Anodes 66 S.F. $0.00 6 Type E Concrete Patch - With Anodes 255 L.F. $0.00 7 Type E Concrete Patch - No Anodes 199 L.F. $0.00 8 Type T Concrete Patch 66 S.F. $0.00 9 Type W Concrete Patch - Exterior - With Anodes 5 L.F. $0.00

10 Type W Concrete Patch - Exterior - No Anodes 561 L.F. $0.00 11 Type Ws Concrete Patch 113 L.F. $0.00 12 Type P Concrete Patch 303 S.F. $0.00 13 Type FF Concrete Patch 90 S.F. $0.00 14 Type O Concrete Patch 48 L.F. $0.00 15 Type Cb Concrete Patch 10 L.F. $0.00 16 Type Ci Crack Repair - Epoxy Injection 45 L.F. $0.00 17 Type Cp Crack Repair - Rout & Point 10 L.F. $0.00 18 Type AI Patch - Remove Abandoned Insert 554 EA $0.00 19 Type W Concrete Patch - Interior 15 L.F. $0.00 20 Type W Concrete Patch – Through Wall 33 L.F. $0.00 21 Type F Concrete Patch - Interior 31 S.F. $0.00 22 Type E Concrete Patch - Interior 109 L.F. $0.00

TOTAL BASE PRICE (Contract Line Item Number 1 through 22) ------------------------------------ Base Price -$

23 PHASE 2A - OPTION 1 $0

24 PHASE 2A - OPTION 2 $0

25 PHASE 2A - OPTION 3 $0

26 PHASE 2A - OPTION 4 $0

27 PHASE 2B - BASE $0

28 PHASE 2B - OPTION 1 $0

29 PHASE 2B - OPTION 2 $0

30 PHASE 2B - OPTION 3 $0

31 PHASE 2B - OPTION 4 $0

32 PHASE 2B - OPTION 5 $0

33 PHASE 2B - OPTION 6 $0

34 PHASE 2B - OPTION 7 $0

TOTAL BASE PRICE Plus Options ------------------------------------ -$

See Separate Breakdown See Separate Breakdown See Separate Breakdown

See Separate Breakdown See Separate Breakdown See Separate Breakdown See Separate Breakdown See Separate Breakdown

See Separate Breakdown

See Separate Breakdown See Separate Breakdown See Separate Breakdown

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases 2A:

CONTRACT PRICE SCHEDULE - BASE (PHASE 2A)

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

23 CLIN #23 BREAKDOWN

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 311 S.F. $0.00 $0.00 Type F Concrete Patch - No Anodes 69 S.F. $0.00 $0.00 Type FT Concrete Patch - No Anodes 10 S.F. $0.00 $0.00 Type E Concrete Patch - With Anodes 95 L.F. $0.00 $0.00 Type E Concrete Patch - No Anodes 184 L.F. $0.00 $0.00 Type T Concrete Patch 67 S.F. $0.00 $0.00 Type W Concrete Patch - Exterior - No Anodes 64 L.F. $0.00 $0.00 Type Ws Concrete Patch 21 L.F. $0.00 $0.00 Type FF Concrete Patch 39 S.F. $0.00 $0.00 Type O Concrete Patch 91 L.F. $0.00 $0.00 Type Cb Concrete Patch 6 L.F. $0.00 $0.00 Type Ci Crack Repair - Epoxy Injection 81 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 123 EA $0.00 $0.00 Type F Concrete Patch - Interior 28 S.F. $0.00 $0.00 Type E Concrete Patch - Interior 12 L.F. $0.00 $0.00

TOTAL CLIN #23 - PHASE 2A OPTION 1 -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #23 BREAKDOWN

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases 2A:

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

24 CLIN #24 - PHASE 2A OPTION 2

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 65 S.F. $0.00 $0.00 Type F Concrete Patch - No Anodes 33 S.F. $0.00 $0.00 Type E Concrete Patch - With Anodes 66 L.F. $0.00 $0.00 Type E Concrete Patch - No Anodes 14 L.F. $0.00 $0.00 Type W Concrete Patch - Exterior - No Anodes 130 L.F. $0.00 $0.00 Type P Concrete Patch 34 S.F. $0.00 $0.00 Type O Concrete Patch 8 L.F. $0.00 $0.00 Type Ci Crack Repair - Epoxy Injection 6 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 25 EA $0.00 $0.00 Type E Concrete Patch - Interior 11 L.F. $0.00 $0.00

TOTAL CLIN #24 - PHASE 2A OPTION 2 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #24 - PHASE 2A OPTION 2

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases 2A:

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

25 CLIN #25 - PHASE 2A OPTION 3

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 5 S.F. $0.00 $0.00 Type E Concrete Patch - With Anodes 16 L.F. $0.00 $0.00

Type W Concrete Patch - Exterior - With Anodes 17 L.F. $0.00 $0.00

Type Ws Concrete Patch 8 L.F. $0.00 $0.00 Type P Concrete Patch 35 S.F. $0.00 $0.00 Type O Concrete Patch 18 L.F. $0.00 $0.00 Type Ci Crack Repair - Epoxy Injection 11 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 57 EA $0.00 $0.00

TOTAL CLIN #25 Option 3 PRICE ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #25 - PHASE 2A OPTION 3

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

26 CLIN #26 - PHASE 2A OPTION 4

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 68 S.F. $0.00 $0.00 Type E Concrete Patch - With Anodes 13 L.F. $0.00 $0.00

Type W Concrete Patch - Exterior - With Anodes 39 L.F. $0.00 $0.00

Type Ws Concrete Patch 41 L.F. $0.00 $0.00 Type P Concrete Patch 89 S.F. $0.00 $0.00 Type O Concrete Patch 5 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 28 EA $0.00 $0.00

TOTAL CLIN #26 - Option 4 PRICE ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #26 - PHASE 2A OPTION 4

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

27 CLIN #27 - PHASE 2B BASE

General Work Items 1 Lump Sum $0.00 $0 Type F Concrete Patch - With Anodes 388 S.F. $0.00 $0.00 Type F Concrete Patch - No Anodes 69 S.F. $0.00 Type FT Concrete Patch - With Anodes 2 S.F. $0.00 Type FT Concrete Patch - No Anodes 29 S.F. $0.00 Type E Concrete Patch - With Anodes 525 L.F. $0.00 Type E Concrete Patch - No Anodes 1 L.F. $0.00 Type T Concrete Patch 128 S.F. $0.00

Type W Concrete Patch - Exterior - With Anodes 18 L.F. $0.00

Type W Concrete Patch - Exterior - No Anodes 457 L.F. $0.00 Type Ws Concrete Patch 43 L.F. $0.00 Type P Concrete Patch 47 S.F. $0.00 Type FF Concrete Patch 45 S.F. $0.00 Type O Concrete Patch 98 L.F. $0.00 Type Cb Concrete Patch 49 L.F. $0.00 Type Ci Crack Repair - Epoxy Injection 51 L.F. $0.00 Type Cp Crack Repair - Rout & Point 10 L.F. $0.00 Type AI Patch - Remove Abandoned Insert 23 EA $0.00 Type W Concrete Patch – Through Wall 28 L.F. $0.00 Type F Concrete Patch - Interior 5 S.F. $0.00 Type E Concrete Patch - Interior 64 L.F. $0.00

TOTAL CLIN #27 - PHASE 2B BASE ------------------------------------ $0.00

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #27 - PHASE 2B BASE

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

28 CLIN #28 - PHASE 2B OPTION 1

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 33 S.F. $0.00 $0.00 Type E Concrete Patch - No Anodes 27 L.F. $0.00 $0.00 Type W Concrete Patch - Exterior - No Anodes 48 L.F. $0.00 $0.00 Type Ws Concrete Patch 20 L.F. $0.00 $0.00 Type O Concrete Patch 28 L.F. $0.00 $0.00 Type Cb Concrete Patch 11 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 4 EA $0.00 $0.00

TOTAL Option 1 PRICE (Contract Line Item Number 1 through 22) ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #28 - PHASE 2B OPTION 1

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

29 CLIN #29 - PHASE 2B OPTION 2

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 33 S.F. $0.00 $0.00 Type F Concrete Patch - No Anodes 19 S.F. $0.00 $0.00 Type E Concrete Patch - No Anodes 70 L.F. $0.00 $0.00 Type W Concrete Patch - Exterior - No Anodes 42 L.F. $0.00 $0.00 Type Ws Concrete Patch 22 L.F. $0.00 $0.00 Type O Concrete Patch 12 L.F. $0.00 $0.00 Type Ci Crack Repair - Epoxy Injection 8 L.F. $0.00 $0.00 Type AI Patch - Remove Abandoned Insert 11 EA $0.00 $0.00 Type W Concrete Patch – Through Wall 15 L.F. $0.00 $0.00 Type E Concrete Patch - Interior 52 L.F. $0.00 $0.00

TOTAL CLIN #29 - PHASE 2B OPTION2 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #29 - PHASE 2B OPTION 2

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

30 CLIN #30 - PHASE 2B OPTION 3

General Work Items 1 Lump Sum $0.00 $0.00 Type F Concrete Patch - With Anodes 41 S.F. $0.00 $0.00 Type E Concrete Patch - With Anodes 21 L.F. $0.00 Type W Concrete Patch - Exterior - No Anodes 45 L.F. $0.00 $0.00 Type Ws Concrete Patch 9 L.F. $0.00 $0.00 Type P Concrete Patch 23 S.F. $0.00 $0.00 Type O Concrete Patch 4 L.F. $0.00 $0.00 Type W Concrete Patch - Interior 8 L.F. $0.00 $0.00 Type E Concrete Patch - Interior 29 L.F. $0.00 $0.00

TOTAL CLIN#30 - PHASE 2B OPTION 3 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #30 - PHASE 2B OPTION 3

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

31 CLIN #31 - PHASE 2B OPTION 4

General Work Items $0.00 $0.00

Type F Concrete Patch - With Anodes 57 S.F. $0.00 $0.00

Type E Concrete Patch - With Anodes 26 L.F. $0.00 $0.00

Type W Concrete Patch - Exterior - No Anodes 114 L.F. $0.00 $0.00

Type Ws Concrete Patch 19 L.F. $0.00 $0.00

Type P Concrete Patch 9 S.F. $0.00 $0.00

Type O Concrete Patch 4 L.F. $0.00 $0.00

Type W Concrete Patch - Interior 11 L.F. $0.00 $0.00

Type W Concrete Patch – Through Wall 20 L.F. $0.00 $0.00

Type E Concrete Patch - Interior 64 L.F. $0.00 $0.00

TOTAL CLIN #31 - PHASE 2B OPTION 4 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE -CLIN #31 - PHASE 2B OPTION 4

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases 2B: Exterior Concrete Repair, Interior Wall Repair and Window Repair.

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

32 CLIN #32 - PHASE 2B OPTION 5

General Work Items $0.00 $0.00

Type F Concrete Patch - With Anodes 117 S.F. $0.00 $0.00

Type F Concrete Patch - No Anodes 15 S.F. $0.00 $0.00

Type FT Concrete Patch - No Anodes 30 S.F. $0.00 $0.00

Type E Concrete Patch - With Anodes 30 L.F. $0.00 $0.00

Type E Concrete Patch - No Anodes 49 L.F. $0.00 $0.00

Type T Concrete Patch 75 S.F. $0.00 $0.00

Type W Concrete Patch - Exterior - No Anodes 54 L.F. $0.00 $0.00

Type Ws Concrete Patch 9 L.F. $0.00 $0.00

Type O Concrete Patch 42 L.F. $0.00 $0.00

Type Cb Concrete Patch 6 L.F. $0.00 $0.00

Type E Concrete Patch - Interior 7 L.F. $0.00 $0.00

TOTAL CLIN #32 - PHASE 2B OPTION 5 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #32 - PHASE 2B OPTION 5

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

33 CLIN #33 - PHASE 2B OPTION 6

General Work Items 1 $0.00 $0.00

Type F Concrete Patch - With Anodes 90 S.F. $0.00 $0.00

Type E Concrete Patch - With Anodes 54 L.F. $0.00 $0.00

Type W Concrete Patch - Exterior - No Anodes 21 L.F. $0.00 $0.00

Type P Concrete Patch 9 S.F. $0.00 $0.00

Type Ci Crack Repair - Epoxy Injection 6 L.F. $0.00 $0.00

Type W Concrete Patch - Interior 8 L.F. $0.00 $0.00

Type W Concrete Patch – Through Wall 8 L.F. $0.00 $0.00

TOTAL CLIN #33 - PHASE 2B OPTION 6 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #33 - PHASE 2B OPTION 6

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY

UNIT OF

MEASURE

UNIT PRICE TOTAL PRICE

34 CLIN #34 - PHASE 2B OPTION 7

General Work Items $0.00 $0.00

Type F Concrete Patch - With Anodes 54 S.F. $0.00 $0.00

Type F Concrete Patch - No Anodes 7 S.F. $0.00 $0.00

Type E Concrete Patch - With Anodes 151 L.F. $0.00 $0.00

Type E Concrete Patch - No Anodes 7 L.F. $0.00 $0.00

Type W Concrete Patch - Exterior - No Anodes 48 L.F. $0.00 $0.00

Type Ws Concrete Patch 20 L.F. $0.00 $0.00

Type P Concrete Patch 75 S.F. $0.00 $0.00

Type O Concrete Patch 28 L.F. $0.00 $0.00

Type AI Patch - Remove Abandoned Insert 18 EA $0.00 $0.00

Type W Concrete Patch - Interior 26 L.F. $0.00 $0.00

TOTAL CLIN #34 - PHASE 2B OPTION 7 ------------------------------------ -$

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern.

Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 365 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

CONTRACT PRICE SCHEDULE - CLIN #34 - PHASE 2B OPTION 7

SOLICITATION NUMBER:

PARK - PMIS: GOGA/149952

DEVELOPED AREA: Golden Gate National Recreation Area - Alcatraz Island

PROJECT TITLE: Stabilize & Repair the Exterior Walls of the Cellhouse for Visitor/Resource Protection - Alcatraz Phases

Document Title

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

WORK COVERED BY CONTRACT DOCUMENTS

The work consists of the following:

1. The Work includes repair and stabilization of the exterior walls of the Cellhouse including:

a. Repair of exterior of the perimeter concrete walls.

b. Repair of selected portions of interior concrete walls including finishes.

c. Repair and stabilization of windows and selected doors.

The project will be constructed in two Phases (2A & 2B). However, the two phases will be done as a single prime contract. Phase 2B will be an Option under the contract to be elected in Fiscal Year 2016.

Specifications provided under separate cover.

Document Title

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not-

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the…