Solicitation Amendment 0006.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): The purpose of this Amendment is to:

1) Provide response to PPIs - Supporting documents for Amendment 0006 responses are available via email request to Stephanie Wray at Stephanie.L.

Wray2.civ@us.navy.mil, AND Ed Flint at edward.d.flint.civ@us.navy.mil. Contractors must provide or have provided a completed Attachment K to obtain.

2) Revise FAR 52.211-12, Liquidated Damages-Construction.

3) Update the drawings and specifications as indicated in the attached continuation sheet.

Section 00 70 00 - Conditions of the Contract

Additional Information/Notes

The following clauses were modified:

52.211-12Liquidated Damages-Construction.Sep 2000 hereby reads as follows:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of [See Table Below] r each calendar day of delay until the work is completed or fo accepted.

Milest one Description

Calen dar

Days to com plete

Liquid ated Da mages per Day

Start date based upon notice to proceed or award of:

Applicable CLIN(s)

M1 Completion of 16-inch Water Main from Gate 2 to Building 163 including Gate 2 Meter Pit

222 $500 Option Item No. 1

CLIN 0002

M2 Submittals Reviewed, Approved, and

Order Placed for Transformers T-3 and T-4 and ALL Generators with Enclosures

270 $1,000 Notice to Proceed

CLIN

0001, CLIN

0014, and

CLIN 0015

M3

Submittals Reviewed, Approved, and Order Placed for MV-SWGR-1, 2, 3, 4

& 35 with Enclosures 365 $1,500

Notice to Proceed CLIN 0001

N6247026R00040006

M4 Completion of 2.5 MG Water Storage

Tank

427 $1,000 Option Item No. 2

CLIN 0003

M5 Completion of 12-inch Water Main in

Meade Avenue 469 $1,000 Option Item

No. 3

CLIN 0004

M6 Installation and commissioning of the Microgrid controller at Building 162

820 $1,250 Notice to Proceed

CLIN 0001

M7 Completion of Cleaning and Lining of

Water Main in Sicard Street 680 $500 Option Item

No. 4

CLIN 0005

M8 Building 162 Substation 2

Commissioning of New Switchgear 1,095 $4,000 Notice to

Proceed

CLIN 0001

M9 Completion of 20-inch Water Main from Gate 1 to Building 163 including Gate 1

Meter Pit 1,155 $3,500

Option Item No. 5 CLIN 0006

M10 Completion of Building 163 Pump

Station Upgrades 1,155 $2,500 Option Item

No. 6

CLIN 0007

M11 Completion of 13.2 kV work at Franklin

Yard 1,280 $5,250 Notice to

Proceed

CLIN 0001

M12 Building 72 Power Plant Addition Complete & Ready for Switchgear

Installation 1,460 $5,500

Notice to Proceed CLIN 0001

M13 Completion of 35 kV System 1,642 $6,500 Notice to Proceed

CLIN 0001

Benefi cial O ccupa ncy Date

Project Completion 1,930 $34,000 Notice to Proceed

All Exercised

CLINS

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

6506 HAMPTON BLVD, NORFOLK VA 23508-1278

NORFOLK, VA 23508-1278

UNITED STATES

Stephanie Wray, Email: stephanie.l.wray2.civ@us.navy.mil Telephone: 757-322-8172 AdminBy:

SCD: PAS: