N4008525R2513 AMD 0014.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

J

PAGE OF PAGES

1 3

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

04-Aug-2025

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY CODE N40085 7. ADMINISTERED BY (If other than item 6) CODE

NAVFACSYSCOM MID-ATLANTIC

CONTRACTING CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

See Item 6

8. NAME AND ADDRESS OF CONT RACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

N4008525R2513

X 9B. DATED (SEE ITEM 11)

14-Feb-2025

10A. MOD. OF CONT RACT /ORDER NO.

10B. DAT ED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENT S OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT

TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNT ING AND APPROPRIAT ION DAT A (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICAT IONS OF CONT RACTS/ORDERS.

IT MODIFIES THE CONT RACT /ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONT RACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONT RACT /ORDER IS MODIFIED TO REFLECT THE ADMINIST RAT IVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORT ANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Solicitation No.: N4008525R2513 - PI2045M Repair of 3rd Battalion Pond Causeway, MCRD, Parris Island, SC

SEE SF30 BLOCK 14 CONTINUATION PAGE(S)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONT RACTING OFFICER (Type or print)

TEL: EMAIL:

15B. CONT RACT OR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNIT ED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C. DATE SIGNED

04-Aug-2025

EXCEPTION TO SF 30

30-105-04

STANDARD FORM 30 (Rev. 10-83) APPROVED BY OIRM 11-84 Prescribed by GSA

FAR (48 CFR) 53.243

N4008525R2513

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 BLOCK 14 CONTINUATION PAGE (SF30)

The following have been added by full text:

AMENDMENT 0014

The purpose of this amendment is to provide the following:

1. Issue discussion questions to Offerors in the competitive range*

2. Updated Attachment C – Price Proposal Form

3. Revised INSTRUCTIONS TO OFFERORS, 3. EVALUATION FACTORS FOR AWARD, Factor 2, Management Approach and Schedule

*For those Offeror’s notified that they are included in the Competitive Range, please refer to your Evaluation Notice for the Due Date and Submission Requirements for Revised Proposals.

3. EVALUATION FACTORS FOR AWARD

Factor 2, Management Approach and Schedule:

(i) Solicitation Submittal Requirements:

From:

Offerors shall provide a critical path method (CPM) schedule for execution and completion of the work to achieve the required interim and final completion milestones for the project. At a minimum, the CPM schedule shall address the following:

• Identify major activities and milestones o Post-Award Kickoff (PAK) meeting Milestone o Pre-Construction Meeting Milestone o Preconstruction Submittals Finish Milestone o Contractor Mobilization Finish Milestone o 1.10.1.6.5 NAVFAC Red Zone - Facility Turnover Planning Meeting Milestones o Substantial Completion Milestone o DD-1354 Finish Milestone o Projected Completion Milestone o Contract Completion Date (CCD) Milestone o Mobilization start date o Power and communication relocation start date o Culvert construction start date o Bridge construction start date o Roadway repair(s) start date o Beneficial occupancy date

• Provide sequencing (precedence/succession) of critical activities

• Demonstrate knowledge of project regulatory constraints

N4008525R2513

• Sufficiently detailed to identify critical and near-critical activities

• The CPM Schedule should document any tasks on the Critical Path.

• Provide all Project Schedule source files.

To:

Offerors shall provide a critical path method (CPM) schedule for execution and completion of the work to achieve the required interim and final completion milestones for the project. At a minimum, the CPM schedule shall address the following:

• Identify major activities and milestones o Post-Award Kickoff (PAK) meeting Milestone o Pre-Construction Meeting Milestone o Preconstruction Submittals Finish Milestone o Contractor Mobilization Finish Milestone o 1.10.1.6.5 NAVFAC Red Zone - Facility Turnover Planning Meeting Milestones o Substantial Completion Milestone o DD-1354 Finish Milestone o Projected Completion Milestone o Contract Completion Date (CCD) Milestone o Mobilization start date o Power and communication relocation start date o Culvert construction start date o Bridge construction start date o Roadway repair(s) start date o Beneficial occupancy date

• Provide sequencing (precedence/succession) of critical activities

• Demonstrate knowledge of project regulatory constraints

• Sufficiently detailed to identify critical and near-critical activities

• The CPM Schedule should document any tasks on the Critical Path.

(End of Summary of Changes)