Approved_1640322spc01of01.pdf

Naval Fac.ilit11es Engineering Command

MID-ATLANTIC

CONTRACT NO. N3943020D2207

ePROJECT NO. 1640322

P-1097 Relocate UEMMS

MSF New London, Connecticut

PREPARED BY:

Childs Engineering Corporation

34 William Way

Bellingham, MA 02019

IN ASSOCIATION WITH

Austin Brockenbrough

1011 Boulder Springs Drive

Suite 200

Richmond, VA 23225

Jensen Hughes

4445 Corporation Lane

Suite 211

Virginia Beach, VA 234 6 2

Civil

APPROVED BY:

Specifications:

For Commander, NAVFAC:

Date: 1/26/2023

UNCLASSIFIED/FOR OFFICIAL USE ONLY

P-1097 Relocate UEMMS, MSF New London, Connecticut

PROJECT TABLE OF CONTENTS

DI VI SI ON 00 - PROCUREMENT AND CONTRACTI NG REQUI REMENTS

00 01 15 02/11 LIST OF DRAWINGS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 11 00 08/15 SUMMARY OF WORK

01 14 00 11/22 WORK RESTRICTIONS

01 20 00 11/20, CHG 2: 08/21 PRICE AND PAYMENT PROCEDURES

01 30 00 11/20, CHG 2: 05/22 ADMINISTRATIVE REQUIREMENTS

01 31 23.13 20 05/17, CHG 7: 11/21 ELECTRONIC CONSTRUCTION AND FACILITY

SUPPORT CONTRACT MANAGEMENT SYSTEM

01 32 17.00 20 05/18 COST-LOADED NETWORK ANALYSIS SCHEDULES

(NAS)

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 35 13 11/20, CHG 1: 02/22 SPECIAL PROJECT PROCEDURES

01 35 26 11/20, CHG 3: 02/22 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 02/19 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 20 11/11, CHG 8: 02/21 QUALITY CONTROL

01 45 35 11/20 SPECIAL INSPECTIONS

01 50 00 11/20, CHG 2: 08/22 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 08/22 TEMPORARY ENVIRONMENTAL CONTROLS

01 57 20 MARINE MAMMAL PROTECTION

01 58 00 08/19, CHG 5: 08/22 PROJECT IDENTIFICATION

01 78 00 05/19 CLOSEOUT SUBMITTALS

01 78 23 08/15, CHG 2: 08/21 OPERATION AND MAINTENANCE DATA

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00 08/22 DEMOLITION AND DECONSTRUCTION

02 41 01 SILTATION CURTAINS/DEBRIS BOOMS

DI VI SI ON 05 - METALS

05 05 23.16 08/18 STRUCTURAL WELDING

05 12 00 08/18 STRUCTURAL STEEL

05 50 13 05/17 MISCELLANEOUS METAL FABRICATIONS

05 51 00 02/17 METAL STAIRS

05 51 33 02/16 METAL LADDERS

05 52 00 02/18 METAL RAILINGS

DI VI SI ON 06 - WOOD, PLASTI CS, AND COMPOSI TES

06 73 01 05/18 FIBERGLASS REINFORCED PLASTIC (FRP)

GRATING

DI VI SI ON 08 - OPENI NGS

08 11 13 08/20 STEEL DOORS AND FRAMES

08 71 00 02/16 DOOR HARDWARE

DI VI SI ON 09 - FI NI SHES

09 97 13.26 COATING OF STEEL WATERFRONT

STRUCTURES, ZERO VOC, (SZC) SPLASH

ZONE COATING

PROJECT TABLE OF CONTENTS Page 1

DI VI SI ON 10 - SPECI ALTI ES

10 14 00.10 08/17 EXTERIOR SIGNAGE

DI VI SI ON 13 - SPECI AL CONSTRUCTI ON

13 34 19 08/20, CHG 1: 02/21 METAL BUILDING SYSTEMS

DI VI SI ON 21 - FI RE SUPPRESSI ON

21 22 00.00 40 05/16 CLEAN AGENT FIRE EXTINGUISHING SYSTEMS

DI VI SI ON 23 - HEATI NG, VENTI LATI NG, AND AI R CONDI TI ONI NG ( HVAC)

23 30 00 05/20, CHG 1: 02/22 HVAC AIR DISTRIBUTION

23 81 23 11/20 COMPUTER ROOM AIR CONDITIONING UNITS

DI VI SI ON 26 - ELECTRI CAL

26 08 00 11/21 APPARATUS INSPECTION AND TESTING

26 20 00 08/19, CHG 3: 11/21 INTERIOR DISTRIBUTION SYSTEM

26 41 00 11/13 LIGHTNING PROTECTION SYSTEM

26 51 00 05/20, CHG 2: 11/21 INTERIOR LIGHTING

26 56 00 08/21 EXTERIOR LIGHTING

DI VI SI ON 27 - COMMUNI CATI ONS

27 10 00 08/11 BUILDING TELECOMMUNICATIONS CABLING

SYSTEM

DI VI SI ON 28 - ELECTRONI C SAFETY AND SECURI TY

28 31 70 08/20 INTERIOR FIRE ALARM SYSTEM, ADDRESSABLE

DI VI SI ON 31 - EARTHWORK

31 62 16.13 11/20, CHG 1: 05/22 STEEL PIPE PILES

31 62 19.15 PILE JACKETING

DI VI SI ON 35 - WATERWAY AND MARI NE CONSTRUCTI ON

35 31 19.20 01/08 ARTICULATING CONCRETE BLOCK REVETMENTS

35 51 13.00 20 04/06 STEEL FLOATING PIER FOR SMALL CRAFT

35 59 13.16 11/21 EXTRUDED MARINE FENDERS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/11

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

DRAWING NO. NAVFAC DWG NO. TITLE

G-001 10009530 TITLE SHEET

G-002 10009531 DRAWING INDEX

AND GENERAL

NOTES

B-101 10009532 SOIL BORING

PLAN AND LOGS

C-101 10009533 SITE PLAN

C-301 10009534 CABLE SECTION

DETAILS

S-101 10009535 DCS TOWER

ELEVATIONS

S-102 10009536 DCS TOWER

ISOMETRIC

S-103 10009537 DCS TOWER

FOUNDATION

S-104 10009538 DCS TOWER

FOUNDATION

DETAILS

S-105 10009539 DCS PLATFORM 1

S-106 10009540 DCS PLATFORM 2

S-107 10009541 DCS PLATFORM 3

S-108 10009542 DCS BUILDING

S-109 10009543 DCS BUILDING

S-110 10009544 DCS BUILDING

DETAILS

S-111 10009545 FLOATING DOCK

S-112 10009546 FLOAT FRAMING

DETAILS

DOCUMENT 00 01 15 Page 1

DRAWING NO. NAVFAC DWG NO. TITLE

S-113 10009547 PILE GUIDE

DETAILS

S-501 10009548 DETAILS

S-502 10009549 DETAILS

S-503 10009550 SECURITY

ENCLOSURE

S-504 10009551 SECURITY

ENCLOSURE

DETAILS

S-505 10009552 LADDER DETAILS

S-506 10009553 MISC. DETAILS

S-507 10009554 SHIP LADDER

DETAILS

S-508 10009555 MISC. DETAILS

E-001 10009556 ELECTRICAL

ABBREVIATIONS,

LEGENDS & NOTES

E-401 10009557 RANGE HOUSE

PLANS &

ELEVATIONS

E-402 10009558 DCS TOWER

PLANS

E-403 10009559 DCS TOWER

PLANS

E-404 10009560 DCS TOWER

LIGHTING

PROTECTION

AND GROUNDING

PLANS

E-501 10009561 DETAILS

E-502 10009562 DETAILS

E-601 10009563 POWER RISER

DIAGRAM

E-602 10009564 ELECTRICAL

SCHEDULES AND

PLATES

FX001 10009565 FIRE

PROTECTION

NOTES AND

LEGEND

FX101 10009566 FIRE

PROTECTION

FLOOR PLAN

DOCUMENT 00 01 15 Page 2

DRAWING NO. NAVFAC DWG NO. TITLE

F501 10009567 FIRE

PROTECTION

DETAILS

M-401 10009568 DCS TOWER

PLAN HVAC

1.3 SUPPLEMENTARY

1.3.1 Boring Logs

The Government does not guarantee that borings indicate actual conditions, except for the exact locations and the time that they were made.

Subsurface data, not specified or indicated, have been obtained by the Government at this station. The data is available for examination by prospective bidders in the office of the Contracting Officerand on the drawings.

-- End of Document --

DOCUMENT 00 01 15 Page 3

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes the construction of a new DCS Tower for the New London Magnetic Silencing Facility at a new location further south in the Thames River.

The construction shall include the prefabrication and installation of a new DCS tower. The new design includes but is not limited to a rigid guide frame structure, foundation piles, three platforms, a floating dock, steel DCS, davit crane, and composite and senor cable risers. A siltation curtain and debris boom shall be around the work area when work is done over the water.

1.2.2 Location

The work is located in Thames River, New London, Connecticut, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, SECTION 01 11 00 Page 1 existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Scan the construction site with Ground Penetrating Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground, pier deck or paved surface where existing underground utilities or utilities encased in pier structures are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.6 GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

Pursuant to Contract Clause FAR 52.245-1 Government Property, the Government will furnish the following materials and equipment for installation by the Contractor:

DESIGNATION NO. DESCRIPTION QUANTITY

Quantities indicated for the above-listed items marked with an asterisk are estimates. It is the intention of the Government to furnish all quantities of the asterisk items required to complete the work as specified, and the various quantities will be adjusted when necessary.

Quantities stated for the above items not marked with an asterisk are all that will be furnished by the Government. Provide any additional quantities that are required.

1.6.1 Delivery Schedule

Notify the Contracting Officer in writing at least 30 calendar days in advance of the date on which the materials and equipment are required.

Pick up materials and equipment no later than 30 calendar days after such date.

Materials and equipment will be available on or after 30 calendar days after the award of contract.

SECTION 01 11 00 Page 2

1.6.2 Delivery Location

The materials and equipment will be delivered to the job site.

1.7 NAVY AND MARINE CORPS (NMCI) COORDINATION REQUIREMENTS

1.7.1 NMCI Contractor Access

Allow the NMCI Contractor access to the facility towards the end of construction (finishes 90 percent complete, rough-in 100 percent complete, Inside Plant (ISP)/Outside Plant (OSP) infrastructure in place) to provide equipment in the telecommunications rooms and make final connections.

Coordinate efforts with the NMCI Contractor to facilitate joint use of building spaces during the final phases of construction. After the Contracting Officer has facilitated coordination meetings between the two contractors, within one week, incorporate the effort of additional coordination with the NMCI Contractor into the construction schedule to demonstrate a plan for maintaining the contract duration.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 3

SECTION 01 14 00

WORK RESTRICTIONS

11/22

PART 1 GENERAL

SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

1.1 SPECIAL SCHEDULING REQUIREMENTS

a. The adjacent navigation channel must not be blocked.

b. The existing UEMMS and DCS Tower will remain in operation during the construction period. The Contractor must conduct his operations so as to cause the least possible interference with normal operations of the activity.

c. The construction of the new UEMMS range will be taking place at the same time. The Contractor must conduct his operations so as to cause the least possible interference.

d. Contractor contractually required milestone dates:

Installation:

1) Phase 1 - Construction:

a. All New Construction Complete (tower, transformer, cable, etc.):

6/24/24

NOTE: (365-day duration from award, end date will improve or extend depending on actual award date)

2) Phase 2 - Demolition (Bid Option:

a. Demolition Start: 5/15/2024

b. Above Mudline Demo Complete: 7/15/2024. Work includes, but is not limited to the following:

i. DCS Tower

ii. Pilings above mudline

NOTE: Upon completion of the above-the-mudline demolition work, the Contractor must be prepared to stop work and vacate his personnel and equipment from the site within 48 hours of notification by the Contracting Officer's representative: The Construction Manager (CM).

For bidding purposes, expect that the duration of this stoppage will last no more than 1 (8 hour) work day.

c. Below Mudline Demo Complete: 8/30/2024. Work includes, but is not limited to the following:

i. Pilings below mudline

ii. Retrieval of sensors

SECTION 01 14 00 Page 1

iii. Cut up of cables

iv. Retrieval of cut cable pieces

e. EXWC & EXWC Contractors will come in and do the following tasks during the P-1097 contract:

1) EXWC will finish their install after completion of P-1097 DCS Building (3 months of work).

2) EXWC will remove all of their equipment from existing DCS Building by 5/25/2024 to allow for P-1097 demolition of existing DCS.

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

1.2.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.2.1.2 Installation Access

Obtain access to Navy installations through participation in the Defense Biometrics Identification System (DBIDS). No fees are associated with obtaining a DBIDS credential.

Participation in the DBIDS is not mandatory, and Contractor personnel may apply for One-Day Passes at the Base Visitor Control Office to access an installation.

1.2.1.2.1 Registration for DBIDS

Registration for DBIDS is available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/ .

Procedure includes:

a. Present a letter or official award document (i.e. DD Form 1155 or SF 1442) from the Contracting Officer, that provides the purpose for access, to the base Visitor Control Center representative.

b. Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

c. Provide completed SECNAV FORM 5512/1 to the base Visitor Control Center representative to obtain a background check. This form is available for download at

SECTION 01 14 00 Page 2 https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/ .

d. Upon successful completion of the background check, the Government will complete the DBIDS enrollment process, which includes Contractor employee photo, fingerprints, base restriction and several other assessments.

e. Upon successful completion of the enrollment process, the Contractor employee will be issued a DBIDS credential, and will be allowed to proceed to worksite.

1.2.1.2.2 DBIDS Eligibility Requirements

Throughout the length of the contract, the Contractor employee must continue to meet background screen standards. Periodic background screenings are conducted to verify continued DBIDS participation and installation access privileges. DBIDS access privileges will be immediately suspended or revoked if at any time a Contractor employee becomes ineligible.

An adjudication process may be initiated when a background screen failure results in disqualification from participation in the DBIDS, and Contractor employee does not agree with the reason for disqualification.

The Government is the final authority.

1.2.1.2.3 DBIDS Notification Requirements

a. Immediately report instances of lost or stolen badges to the Contracting Officer.

b. Immediately collect DBIDS credentials and notify the Contracting Officer in writing under the following circumstances:

(1) An employee has departed the company without having properly returned or surrendered their DBIDS credentials.

(2) There is a reasonable basis to conclude that an employee, or former employee, might pose a risk, compromise, or threat to the safety or security of the Installation or anyone therein.

1.2.1.2.4 One-Day Passes

Personnel applying for One-Day passes at the Base Visitor Control Office are subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government is not responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections incurred by non-participants in the DBIDS.

1.2.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

SECTION 01 14 00 Page 3

1.2.2 Working Hours

Regular working hours will consist of an 8 1/2 hour period established by the Contracting Officer, between 6.30 a.m. and 5:00 p.m., Monday through Friday, excluding Government holidays.

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.2.4 Occupied Building[s]

The Contractor shall be working in and around an existing building which is occupied. Do not enter the building without prior approval of the Contracting Officer.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

The Government will remove and relocate other Government property in the areas of the building scheduled to receive work.

1.2.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, are considered utility cutovers pursuant to the paragraph WORK

OUTSIDE REGULAR HOURS.

d. Operation of Station Utilities: The Contractor must not operate nor disturb the setting of control devices in the station utilities system, including water, sewer, electrical, and steam services. The Government will operate the control devices as required for normal conduct of the work. The Contractor must notify the Contracting Officer giving reasonable advance notice when such operation is required.

SECTION 01 14 00 Page 4

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 5

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

11/ 20, CHG 2: 08/ 21

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP 1110-1-8 (2021) Engineering and Design -- Construction Equipment Ownership and Operating Expense Schedule

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Earned Value Report; G

1.3 EARNED VALUE REPORT

1.3.1 Data Required

This Contract requires the use of a cost-loaded Network Analysis Schedule (NAS). Schedule of Prices must not be used with cost-loaded Network Analysis Schedule (NAS). Use Earned Value Report derived from cost-loaded NAS. Within 15 calendar days of notice of award, prepare and deliver to the Contracting Officer a Earned Value Report (construction Contract) as directed by the Contracting Officer. Schedule of Prices must have cost summarized and totals provided for each construction category. Provide a detailed breakdown of the Contract price, giving quantities for each of the various kinds of work, unit prices and extended prices. Contractor overhead and profit including salaries for field office personnel, if applicable, must be proportionately spread over all pay items and not included as individual pay items.

1.3.2 Payment Schedule Instructions

Payments will not be made until the Earned Value Report from the cost-loaded NAS has been submitted to and accepted by the Contracting Officer.

1.4 CONTRACT MODIFICATIONS

In conjunction with the Contract Clause DFARS 252.236-7000 Modification Proposals-Price Breakdown, and where actual ownership and operating costs of construction equipment cannot be determined from Contractor accounting

SECTION 01 20 00 Page 1 records, base equipment use rates upon the applicable provisions of the

EP 1110-1-8 .

1.5 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.5.1 Content of Invoice

Requests for payment will be processed in accordance with the Contract Clause FAR 52.232-27 Prompt Payment for Construction Contracts and FAR 52.232-5 Payments Under Fixed-Price Construction Contracts. Invoices not completed in accordance with contract requirements will be returned to the Contractor for correction of the deficiencies. The requests for payment shall include the documents listed below.

a. The Contractor's invoice, on NAVFAC Form 7300/30 furnished by the Government, showing in summary form, the basis for arriving at the amount of the invoice. Form 7300/30 must include certification by Quality Control (QC) Manager as required by the Contract.

b. The Estimate for Voucher/ Contract Performance Statement on NAVFAC Form 4330/54 furnished by the Government. Use NAVFAC Form 4330, unless otherwise directed by the Contracting Officer, on NAVFAC Contracts when a Monthly Estimate for Voucher is required.Earned Value Report from the cost-loaded NAS.]

c. Contractor's Monthly Estimate for Voucher and Contractors Certification (NAVFAC Form 4330) with Subcontractor and supplier payment certification. Other documents, including but not limited to, that need to be received prior to processing payment include the following submittals as required. These items are still required monthly even when a pay voucher is not submitted.

d. Monthly Work-hour report.

e. Updated Construction Progress Schedule and tabular reports required by the contract.

f. Contractor Safety Self Evaluation Checklist.

g. Updated submittal register.

h. Solid Waste Disposal Report.

i. Certified payrolls.

j. Updated testing logs.

k. Other supporting documents as requested.

1.5.2 Submission of Invoices

If DFARS Clause 252.232-7006 Wide Area WorkFlow Payment Instructions is included in the Contract, provide the documents listed in above paragraph CONTENT OF INVOICE in their entirety as attachments in Wide Area Work Flow (WAWF) for each invoice submitted. The maximum size of each WAWF attachment is two megabytes, but there are no limits on the number of attachments. If a document cannot be attached in WAWF due to system or size restriction, provide it as instructed by the Contracting Officer.

SECTION 01 20 00 Page 2

Monthly invoices and supporting forms for work performed through the anniversary award date of the Contract must be submitted to the Contracting Officer within 5 calendar days of the date of invoice. For example, if Contract award date is the 7th of the month, the date of each monthly invoice must be the 7th and the invoice must be submitted by the 12th of the month.

1.5.3 Final Invoice

a. A final invoice must be accompanied by the certification required by DFARS 252.247.7023 Transportation of Supplies by Sea, and the Contractor's Final Release. If the Contractor is incorporated, the Final Release must contain the corporate seal. An officer of the corporation must sign and the corporate secretary must certify the Final Release.

b. For final invoices being submitted via WAWF, the original Contractor's Final Release Form and required certification of Transportation of Supplies by Sea must be provided directly to the respective Contracting Officer prior to submission of the final invoice. Once receipt of the original Final Release Form and required certification of Transportation of Supplies by Sea has been confirmed by the Contracting Officer, the Contractor must then submit final invoice and attach a copy of the Final Release Form and required certification of Transportation of Supplies by Sea in WAWF.

c. Final invoices not accompanied by the Contractor's Final Release and required certification of Transportation of Supplies by Sea will be considered incomplete and will be returned to the Contractor.

1.6 PAYMENTS TO THE CONTRACTOR

Payments will be made on submission of itemized requests by the Contractor which comply with the requirements of this section, and will be subject to reduction for overpayments or increase for underpayments made on previous payments to the Contractor.

1.6.1 Obligation of Government Payments

The obligation of the Government to make payments required under the provisions of this Contract will, at the discretion of the Contracting Officer, be subject to reductions and suspensions permitted under the FAR and agency regulations including the following in accordance with FAR

32.103 Progress Payments Under Construction Contracts:

a. Reasonable deductions due to defects in material or workmanship;

b. Claims which the Government may have against the Contractor under or in connection with this Contract;

c. Unless otherwise adjusted, repayment to the Government upon demand for overpayments made to the Contractor; and

d. Failure to maintain accurate "as-built" or record drawings in accordance with FAR 52.236.21.

1.6.2 Payment for Onsite and Offsite Materials

Progress payments may be made to the Contractor for materials delivered on

SECTION 01 20 00 Page 3 the site, for materials stored off construction sites, or materials that are in transit to the construction sites under the following conditions:

a. FAR 52.232-5(b) Payments Under Fixed Price Construction Contracts.

b. Materials delivered on the site but not installed, including completed preparatory work, and off-site materials to be considered for progress payment must be major high cost, long lead, special order, or specialty items, not susceptible to deterioration or physical damage in storage or in transit to the construction site. Examples of materials acceptable for payment consideration include, but are not limited to, structural steel, non-magnetic steel, non-magnetic aggregate, equipment, machinery, large pipe and fittings, precast/prestressed concrete products, plastic lumber (e.g., fender piles/curbs), and high-voltage electrical cable. Materials not acceptable for payment include consumable materials such as nails, fasteners, conduits, gypsum board, glass, insulation, and wall coverings.

c. Materials to be considered for progress payment prior to installation must be specifically and separately identified in the Contractor's estimates of work submitted for the Contracting Officer's approval in accordance with Schedule of Prices requirement of this Contract.

Requests for progress payment consideration for such items must be supported by documents establishing their value and that the title requirements of the clause at FAR 52.232-5 Payments Under Fixed-Price Construction Contracts have been met.

d. Materials are adequately insured and protected from theft and exposure.

e. Provide a written consent from the surety company with each payment request for offsite materials.

f. Materials to be considered for progress payments prior to installation must be stored either in Hawaii, Guam, Puerto Rico, or the Continental United States. Other locations are subject to written approval by the Contracting Officer.

g. Materials in transit to the job site or storage site are not acceptable for payment.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 20 00 Page 4

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/ 20, CHG 2: 05/ 22

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety -- Safety and Health Requirements Manual

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map; G

Progress and Completion Pictures; G

1.3 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.4 PROGRESS AND COMPLETION PICTURES

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600x1200x24 bit true color minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of 20 digital photographs each week throughout the entire project from a minimum of ten different viewpoints selected by the Contractor unless otherwise directed by the Contracting Officer. Submit with the monthly invoice two sets of digital photographs, each set on a separate compact disc (CD) or data versatile disc (DVD), cumulative of all photos to date. Indicate photographs demonstrating environmental procedures.

Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Also provide the view location sketch on the CD or DVD as a digital file.

Include a date designator in file names. Photographs provided are for unrestricted use by the Government.

1.5 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, SECTION 01 30 00 Page 1 during the entire period of performance under this contract. Provide other insurance coverage as required by Connecticut law.

1.6 SUPERVISION

1.6.1 Superintendent Qualifications

Provide project superintendent with a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

For projects where the superintendent is permitted to also serve as the Quality Control (QC) Manager as established in Section 01 45 00.00 20 QUALITY CONTROL, the superintendent must have qualifications in accordance with that section.

1.6.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract work.In addition, if a Quality Control (QC) representative is required on the Contract, then that individual must also have fluent English communication skills.

1.6.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent is required to attend partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.6.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.7 PRECONSTRUCTION MEETING

Immediately after award , prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Meeting . The meeting must take place within 35 calendar days after award of the contract, but prior to commencement of any work at the site. The purpose of this meeting is to discuss and develop a mutual

SECTION 01 30 00 Page 2 understanding of the administrative requirements of the Contract including but not limited to: daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, quality control, schedule of prices or earned value report, shop drawings, submittals, cybersecurity, prosecution of the work, government acceptance, final inspections and contract close-out. Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.7.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), Quality Control Manager and major subcontractors.

1.8 PARTNERING

To most effectively accomplish this Contract, the Contractor and Government must form a cohesive partnership with the common goal of drawing on the strength of each organization in an effort to achieve a successful project without safety mishaps, conforming to the Contract, within budget and on schedule. The partnering team must consist of personnel from both the Government and Contractor including project level and corporate level leadership positions. Key Personnel from the supported command, end user, Contractor, key subcontractors and the Designer of Record are required to participate in the Partnering process.

1.8.1 Facilitated (Formal) Partnering

a. Within 35 calendar days after award and prior to the start of work, host a Formal Partnering session with key personnel from the project team including both Contractor and Government personnel. All costs associated with the Partnering session including the third-party independent Facilitator Consultant, meeting room and other incidental items are the responsibility of the Contractor.

b. Before the Facilitated (Formal) Partnering session, coordinate with the Facilitator all requirements for incidental items (such as audio-visual equipment, easels, flipchart paper, colored markers, note pads, pens/pencils, colored flash cards) and have these items available at the Partnering session. Provide copies of any documents required for distribution to all attendees. Participants will bear their own costs for meals, lodging and transportation associated with Partnering .

c. The Initial Partnering Session must be a duration of one day and be held at a location off base as agreed to by the Contracting Officer.

Partnering session may take place concurrently with the Pre-Construction Meeting.

d. Facilitator must be experienced in conducting corporate Partnering sessions and must be a third-party independent facilitating consultant

- not an employee of the Contractor. The Facilitator is responsible for leading all aspects of the Partnering session necessary to achieve the Partnering goal.

e. An outcome of the Partnering session must be an escalation matrix agreed upon by both the Government and Contractor, which identifies key Government and Contractor decision makers by name and anticipated

SECTION 01 30 00 Page 3 decision durations.

f. Host follow-on Partnering Sessions at three- to six-month intervals or more frequently if needed and lasting generally a half day or less.

Attendees need only be those required to resolve current issues. The same Facilitator used in the Initial Partnering session must lead the follow-on sessions unless an alternative is permitted by the Contractor Officer. All costs associated with follow-on Partnering sessions are the responsibility of the Contractor.

1.9 MOBILIZATION

Contractor shall mobilize to the jobsite within 60 calendar days after contract award. Mobilize is defined as having equipment AND having a physical presence of at least one person from the contractor's team on the jobsite.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 4

SECTION 01 31 23.13 20

ELECTRONIC CONSTRUCTION AND FACILITY SUPPORT CONTRACT MANAGEMENT SYSTEM

05/ 17, CHG 7: 11/ 21

PART 1 GENERAL

1.1 CONTRACT ADMINISTRATION

Utilize the Naval Facilities Engineering Command's (NAVFAC's) Electronic Construction and Facility Support Contract Management System (eCMS) for the transfer, sharing, and management of electronic technical submittals and documents. The web-based eCMS is the designated means of transferring technical documents between the Contractor and the Government. Paper media or e-mail submission, including originals or copies, of the documents identified in Table 1 are not permitted, except where eCMS is unavailable, non-functional, or specifically requested in addition to electronic submission.

1.1.1 Format Naming Convention for Files Uploaded Into eCMS

Include the identification number of the document, the type of document, the name/subject or title, and for daily reports, the date (day of work) with format YYYY/MM/DD in the filename. For example, for RFI's, 0011_RFI_Roof_Leaking.doc; for submittals, 0032a_Submittals_Light_Fixture.pdf; for Daily Reports, 0132_Daily_Report_20190504.xls. Contact the Contracting Officer's Representative (COR) regarding availability of eCMS training and reference materials.

1.1.2 Uploading Documents Processed Outside of eCMS

When specifically requested to provide documents outside of eCMS, upload all final project documentation (e.g., documents that are signed and/or adjudicated by the Government) mentioned in Table 1 into eCMS by creating a record in the module associated with that document type and uploading the document(s). Subject/title of the record should include the type of record i.e., RFI/Submittal/Other, the identification number(s), and the statement "Processed Outside of eCMS". For example, "RFI 001-012 Processed Outside of eCMS".

1.2 USER PRIVILEGES

The Contractor will be provided access to eCMS. All technical submittals and documents must be transmitted to the Government via the COR. Project roles and system roles will be established to control each user's menu, application, and software privileges, including the ability to create, edit, or delete objects.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

SECTION 01 31 23.13 20 Page 1

List of Contractor's Personnel; G

1.4 SYSTEM REQUIREMENTS AND CONNECTIVITY

1.4.1 General

The eCMS requires a web-browser (platform-neutral) and Internet connection. Obtain from an approved vendor an External Certification Authority (ECA), Primary Key Infrastructure (PKI) certificate, or other similar digital identification to support two-factor authentication and access to eCMS. Provide and maintain computer hardware and software for the eCMS access throughout the duration of the contract for all Contractor-designated users. Provide connectivity, speed, bandwidth, and access to the Internet to ensure adequate functionality. 70 mbps download speed recommended, 40 mbps minimum for loading large files. Neither upgrading of the Contractor's computer system nor delays associated from the usage of the eCMS will be justification or grounds for a time extension or cost adjustment to the Contract.

1.4.2 Contractor Personnel List

Within 20 calendar days of contract award, provide to the Contracting Officer a list of Contractor's personnel who will have the responsibility for the transfer, sharing and management of electronic technical submittals and documents and will require access to the eCMS. Project personnel roles to be filled in the eCMS include the Contractor's Project Manager, Superintendent, Quality Control (QC) Manager, and Site Safety and Health Officer (SSHO). Personnel must be capable of electronic document management. Notify the COR immediately of any personnel changes to the project. The Contracting Officer reserves the right to perform a security check on all potential users. Provide the following information:

First Name Last Name E-mail Address Office Address Project Role (e.g. Project Manager, QC Manager, Superintendent)

1.4.3 Field Administration

Within 30 days of Contract Award, provide a tablet computer with a Common Access Card (CAC) reader at the job site for Government use only. The tablet computer must have a minimum 10-inch (measured diagonally) screen size, Windows or Apple Operating System, 16 GB Internal Memory (RAM), 256GB Hard Drive, GPS, WIFI, web-browser, built-in camera, and cellular data connectivity. Manufacturer date on the tablet should be within 2 years of contract award. Provide tablet computer with a rugged case suitable for use in a construction environment. The tablet computer must be fully charged and made available at all times for Government use to facilitate the input of construction data at the job site. The tablet will be given back to the contractor prior to leaving the jobsite for charging, maintaining and securing. After completion of the work, reset the tablet computer to factory default settings. The tablet computer remains the property of the Contractor and must be removed from the site.

There are restrictions on use of WIFI on military bases. Cellular data connectivity and availability, and use of WIFI requires coordination with and approval by the Contracting Officer.

SECTION 01 31 23.13 20 Page 2

1.5 SECURITY CLASSIFICATION

In accordance with Department of Navy guidance, all military construction contract data are unclassified, unless specified otherwise by a properly designated Original Classification Authority (OCA) and in accordance with an established Security Classification Guide (SCG). Refer to the project's OCA when questions arise about the proper classification of information.

The eCMS and tablet computer must only be used for the transaction of unclassified information associated with construction projects. In conformance with the Freedom of Information Act (FOIA), DoD INSTRUCTION

5200.48 CONTROLLED UNCLASSIFIED INFORMATION (CUI), and DoD requirements, any unclassified project documentation uploaded into the eCMS must be designated either "U - UNCLASSIFIED" (U) or "CUI - CONTROLLED UNCLASSIFIED

INFORMATION"

(CUI).

1.6 ECMS UTILIZATION

Establish, maintain, and update data and documentation in the eCMS throughout the duration of the contract.

Personally Identifiable Information (PII) transmittal is not permitted in the eCMS.

1.6.1 Information Security Classification/Identification

The eCMS must be used for the transmittal of the following documents.

This requirement supersedes conflicting requirements in other sections, however, submittal review times in Section 01 33 00 SUBMITTAL PROCEDURES remain applicable. Table 1 - Project Documentation Types provides the appropriate U and CUI designations for various types of project documents. Construction documents requiring CUI status must be marked accordingly. Apply the appropriate markings before any document is uploaded into eCMS. Markings are not required on U documents.

Table 1 also identifies which eCMS application is to be used in the transmittal of data (these are subject to change based on the latest software configuration). If a designated application is not functional within 4 hours of initial attempt, defer to the Submittal application and submit the required data as an uploaded portable document (e.g. PDF), word processor, spreadsheet, drawing, or other appropriate format. Hard copy or e-mail submission of these items is acceptable only if eCMS is documented to be not available or not functional or specifically requested in addition to electronic submission. After uploading documents to the Submittal application, transmit the submittals and attachments to the COR via the Transmittal application. For Submittals, select the following:

Preparation by = Contractor personnel assigned to prepare the submittal Approval by = Contracting Officer Representative (COR) Returned by = Design Lead/Manager Forwarded to = Contractor project manager

Table 1 - Project Documentation Types

SECTION 01 31 23.13 20 Page 3

SUBJECT/NAME DESIG REMARKS ECMS APPLI CATI ON

As-Built Drawings U Locations of sensitive areas must be labeled as either "Controlled Area" or "Restricted Area" and may be shown on unclassified documents with the approval from Site Security Manager

Submittals and Transmittals

Building Information Modeling (BIM)

U 1. Locations of sensitive areas must be labeled as either "Controlled Area" or "Restricted Area" and may be shown on unclassified documents with the approval from Site Security Manager

2. Design reviews will be performed in existing "Dr Checks"

Submittals and Transmittals

Construction Permits U Refer to rules of the issuing activity, state or jurisdiction

Submittals and Transmittals

Construction Schedules (Activities and Milestones)

U After the schedule submittal is approved by the COR, import the schedule file into the scheduling application, and select "Approve" to establish a new schedule baseline

Submittals, Transmittals and Scheduling App

Construction Schedules (Cost-Loaded)

CUI After the schedule submittal is approved by the COR, import the schedule file into the scheduling application, and select "Approve" to establish a new schedule baseline

Submittals, Transmittals and Scheduling App

Construction Schedules (3-Week Lookahead)

U Import the schedule file into the scheduling application, and select "Approve" to establish a new schedule baseline

Scheduling App

DD 1354 Transfer of Real Property

U Submittals and Transmittals

Daily Production Reports

CUI Provide weather conditions, crew size, man-hours, equipment, and materials information

Daily Report

Daily Quality Control (QC) Reports

CUI Provide QC Phase, Definable Features of Work Identify visitors

Daily Report

SECTION 01 31 23.13 20 Page 4

Designs and Specifications

U 1. Locations of sensitive areas must be labeled as either "Controlled Area" or "Restricted Area" and may be shown on unclassified documents with the approval from Site Security Manager

2. Design reviews will be performed in existing "Dr Checks"

Submittals and Transmittals

Environmental Notice of Violation (NOV), Corrective Action Plan

U Refer to rules of the issuing activity, state or jurisdiction

Submittals and Transmittals

Environmental Protection Plan

(EPP)

CUI Submittals and Transmittals

Invoice (Supporting Documentation)

CUI Applies to supporting documentation only. Invoices are submitted in Wide-Area Workflow (WAWF)

Submittals and Transmittals

Jobsite Documentation, Bulletin Board, Labor Laws, SDS

U Submittals and Transmittals

Meeting Minutes CUI Meeting Minutes

Modification Documents

CUI Provide final modification documents for the project. Upload into "Modifications - RFPs

Document Management

Operations & Maintenance Support Information (OMSI/eOMSI), Facility Data Worksheet

U 1. Locations of sensitive areas must be labeled as either "Controlled Area" or "Restricted Area" and may be shown on unclassified documents with the approval from Site Security Manager

2. Design reviews will be performed in existing "Dr Checks"

Submittals and Transmittals

Photographs U Subject to base/installation restrictions

Submittals and Transmittals

QCM Initial Phase Checklists

CUI Checklists (Site Management)

SECTION 01 31 23.13 20 Page 5

QCM Preparatory Phase Checklists

CUI Checklists (Site Management)

Quality Control Plans

CUI Submittals and Transmittals

QC Certifications U Submittals and Transmittals

QC Punch List U Punch Lists (Testing Logs)

Red-Zone Checklist U Checklists (Site Management)

Rework Items List CUI Punch Lists (Testing Logs)

Request for Information (RFI) Post-Award

CUI RFIs

Safety Plan CUI Daily Report

Safety - Activity Hazard Analyses

(AHA)

CUI Daily Report

Safety - Mishap Reports

CUI Daily Report

SCIF/SAPF

Accreditat…