Amendment 0007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

SOLICITATION NO. N40085-23-R-2516: Relocate Underw ater Electromagnetic Measurement System, Naval Submarine Base New London, New London, CT

Contract POC: Jonathan Durham; Email: jonathan.m.durham.civ@us.navy.mil

See Continuation Page(s)

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 13-Jul-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008523R2516

X 9B. DATED (SEE ITEM 11)

08-Feb-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

13-Jul-2023

CODE

NAVFACSYSCOM MID-ATLANTIC

CONTRACTING CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008523R2516

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0007

The purpose of this amendment is to:

1. Establish due date for revised proposal for those invited to participate in discussions as 24 July 2023, NLT 1400 local time via email to jonathan.m.durham.civ@us.navy.mil

2. Incorporate revisions to Specification 01 14 00

3. Incorporate revisions to Factor 2 – Management Approach and Schedule

4. Incorporate revised Wage Determination

5. Remove clause 52.211-10 and incorporate 52.211-10 Alternate I (APR 1984)

6. Revise clause 52.211-12

7. Incorporate revised Attachment I – Price Proposal Form updated (attached separately)

1. PROPOSAL DUE DATE IS REVISED AS FOLLOWS:

The due date for the submission of a revised proposal for those invited to participate in discussions is 24 July 2023, NLT 1400 local time via email to jonathan.m.durham.civ@us.navy.mil

2. SPECIFICATION SECTION 01 14 00 IS REVISED AS FOLLOWS:

SECTION 01 14 00

1.1 SPECIAL SCHEDULING REQUIREMENTS

d. Contractor contractually required milestone dates:

Milestone 1 – Above Mudline Construction

a. Above Mudline Construction Complete (tower, transformer, etc.): 06/24/2024

Milestone 2 – Demolition and Below Mudline Cable Installation

a. Demolition Start: 05/15/2024

b. Above Mudline Demo Complete: 07/15/2024. Work includes, but is not limited to the following:

i. DCS Tower

ii. Pilings above mudline

NOTE: Upon completion of the above-the-mudline demolition work, the Contractor must be prepared to stop work and vacate his personnel and equipment from the site within 48 hours of notification by the Contracting Officer's representative: The Construction Manager (CM). For bidding purposes, expect that the duration of this stoppage will last no more than 1 (8 hour) work day.

c. Below Mudline Work Complete: 08/30/2024. Work includes, but is not limited to the following:

i. Demo Pilings below mudline

ii. Retrieval of sensors

iii. Cut up existing cables

iv. Retrieval of cut cable pieces

v. Installation new of cable

3. INSTRUCTIONS TO OFFERORS, EVALUATION FACTORS FOR AWARD, FACTOR 2 –

MANAGEMENT APPROACH AND SCHEDULE IS REVISED AS FOLLOWS (CHANGES

DENOATED IN RED:

1. INSTRUCTIONS TO OFFERORS

3. EVALUATION FACTORS FOR AWARD

(2) Factor 2 – Management Approach and Schedule

(i) Solicitation Submittal Requirements

Submit a narrative work plan and summary level project schedule that describe your approach to managing the project and ensuring adherence to the project schedule. Both the schedule and narrative must address the execution of the base project and all options, as defined in the RFP.

The narrative work plan shall address major elements of work and demonstrate understanding of the scope, all phases and major milestones, technical complexities, and construction schedule required to achieve the work as identified in the specifications. Identify activities that may affect the project timeline, including other/off site work activities. In addition, the plan shall address the following technical complexities:

a) Strategy for procuring long lead equipment, to include composite cable and transformers; and

b) In-water work, specifically including pile installation and pile extraction;

The project schedule shall illustrate the offeror’s ability to achieve or improve on the contract completion date for the two project Milestones as follows:

Milestone 1 – Above Mudline Construction

a. Above Mudline Construction Complete (tower, transformer, etc.): 06/24/2024

Milestone 2 – Demolition and Below Mudline Cable Installation

a. Demolition Start: 05/15/2024

b. Above Mudline Demo Complete: 07/15/2024. Work includes, but is not limited to the following:

c. Below Mudline Work Complete: 08/30/2024. Work includes, but is not limited to the following:

i. Demo Pilings below mudline

ii. Retrieval of sensors

iii. Cut up existing cables

v. Installation of new cable

Identify the overall completion time for this project, as well as interim completion times (including each sequence of work as identified in the RFP) and key milestones for sequences as required to complete construction. If a realistic duration shorter than specified in the RFP is proposed, the proposed duration will be incorporated into the resultant contract. The schedule shall demonstrate an understanding of the work, a logical sequence of events to accomplish the work, and contain enough information to identify all of the major milestones, as defined in the RFP.

The schedule shall be based on a contract award date of August 24, 2023. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 24 August 2023. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

The narrative shall not exceed five (5) double-sided (or ten (10) single-sided) 8-1/2" x 11" pages. Provide the summary level schedule, documenting any multiple critical paths, in 11" x 17" pages and in an Adobe PDF file.

There is no page limit on the summary level schedule.

4. Incorporate revised Wage Determination:

From:

CT20230024 01/27/2023 Building

To:

CT20230024 06/16/2023 Building

"General Decision Number: CT20230024 06/16/2023

Superseded General Decision Number: CT20220024

State: Connecticut

Construction Type: Building

County: New London County in Connecticut.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $16.20 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2023. | |If the contract was awarded on|. Executive Order 13658 |

|or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $12.15 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2023. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2023 1 01/13/2023 2 01/27/2023 3 05/12/2023 4 05/26/2023 5 06/02/2023 6 06/09/2023 7 06/16/2023

ASBE0033-002 06/01/2023

Rates Fringes

HEAT & FROST INSULATOR

(Includes Duct, Pipe and Mechanical Systems)..............$ 45.56 32.65

BRCT0001-001 01/02/2023

Rates Fringes

BRICKLAYER.......................$ 39.40 34.62

BRCT0001-005 01/02/2023

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 39.40 34.62

CARP0326-024 05/01/2023

Rates Fringes

FLOOR LAYER: Carpet Only.........$ 37.61 27.61

CARP0326-027 05/02/2022

Rates Fringes

CARPENTER (Scaffold Builder).....$ 37.61 27.61

CARP0326-028 05/01/2023

Rates Fringes

CARPENTER (Includes Acoustical Ceiling Installation, Drywall Hanging, Form Work, and Metal Stud Installation)...............$ 37.61 27.61

ELEC0090-012 06/01/2023

Rates Fringes

ELECTRICIAN......................$ 42.60 3%+33.21

ELEV0091-002 01/01/2023

Rates Fringes

ELEVATOR MECHANIC................$ 61.42 37.335+a+b

FOOTNOTE:

a.Vacation: 6%/under 5 years based on regular hourly rate for all hours worked. 8%/over 5 years based on regular hourly rate for all hours worked.

b. PAID HOLIDAYS: New Year's Day; Memorial Day; Independence Day; Labor Day; Veterans' Day; Thanksgiving Day; the Friday after Thanksgiving Day; and Christmas Day.

ENGI0478-004 04/02/2023

Rates Fringes

POWER EQUIPMENT OPERATOR

(Backhoe/Excavator/Trackhoe).....$ 47.10 27.80

PAID HOLIDAYS: New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, provided the employee works 3 days during the week in which the holiday falls, if scheduled, and if scheduled, the working day before and the working day after the holiday.

ENGI0478-005 04/02/2023

Rates Fringes

POWER EQUIPMENT OPERATOR

(Bulldozer) Finegrade (Slopes, Shaping, laser or GPS, etc.).......................$ 47.10 27.80 Rough Grade Dozer...........$ 45.55 27.80

PAID HOLIDAYS: New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, provided the employee works 3 days during the week in which the holiday falls, if scheduled, and if scheduled, the working day before and the working day after the holiday.

ENGI0478-012 04/02/2023

Rates Fringes

POWER EQUIPMENT OPERATOR

(Crane under 100 ton rated capacity)).......................$ 51.51 27.80

PAID HOLIDAYS: New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, provided the employee works 3 days during the week in which the holiday falls, if scheduled, and if scheduled, the working day before and the working day after the holiday.

ENGI0478-016 04/02/2023

Rates Fringes

POWER EQUIPMENT OPERATOR

(Loader - 7 cubic yards or over)............................$ 48.37 27.80

PAID HOLIDAYS: New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, provided the employee works 3 days during the week in which the holiday falls, if scheduled, and if scheduled, the working day before and the working day after the holiday.

IRON0015-010 06/05/2023

Rates Fringes

IRONWORKER (Reinforcing, Structural, Ornamental)..........$ 42.37 40.02

* LABO0230-001 04/03/2022

Rates Fringes

LABORER

Common or General...........$ 33.50 25.59 Mason Tender- Cement/Concrete.............$ 34.00 25.59

* PAIN0011-021 06/01/2023

Rates Fringes

PAINTER (Brush and Roller).......$ 37.62 24.55

* PAIN0011-023 06/01/2023

Rates Fringes

DRYWALL FINISHER/TAPER...........$ 38.37 24.55

PLUM0777-001 06/01/2023

Rates Fringes

PLUMBER..........................$ 48.28 35.50

PLUM0777-003 06/01/2023

Rates Fringes

PIPEFITTER.......................$ 48.28 35.50

ROOF0009-001 06/01/2023

Rates Fringes

ROOFER

Composition.................$ 41.70 22.35 Slate and Tile..............$ 41.20 22.35

SHEE0040-002 07/01/2021

Rates Fringes

SHEET METAL WORKER (Metal Flashing and HVAC Duct Installation Only)...............$ 40.08 40.53

SHEE0040-006 07/01/2021

Rates Fringes

SHEET METAL WORKER...............$ 40.08 40.53

SHEE0040-008 07/01/2021

Rates Fringes

SHEET METAL WORKER (Metal Roofs Installation)..............$ 40.08 40.53

TEAM0191-001 04/02/2023

Rates Fringes

TRUCK DRIVER (Dump Truck)........$ 32.39 30.51

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISIO"

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 31-Mar-2023 02:00 PM to 24-Jul-2023 02:00 PM.

The Issued By organization has changed from

NAVFACSYSCOM MID-ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

to

NAVFACSYSCOM MID-ATLANTIC

CONTRACTING CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been added by full text:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 (fifteen) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than . The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 24 August 2023. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

Milestone 1 – Above Mudline Construction

a. Above Mudline Construction Complete (tower, transformer, etc.): 06/24/2024

Milestone 2 – Demolition

a. Demolition Start: 05/15/2024

b. Above Mudline Demo Complete: 07/15/2024. Work includes, but is not limited to the following:

NOTE: Upon completion of the above-the-mudline demolition work, the Contractor must be prepared to stop work and vacate his personnel and equipment from the site within 48 hours of notification by the Contracting Officer's representative: The Construction Manager (CM). For bidding purposes, expect that the duration of this stoppage will last no more than 1 (8 hour) work day.

c. Below Mudline Work Complete: 08/30/2024. Work includes, but is not limited to the following:

i. Demo Pilings below mudline

ii. Retrieval of sensors

iii. Cut up existing cables

v. Installation of new cable

(End of clause)

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,385.01 for Milestone 1 – Construction and $3,500.85 for Milestone 2 – Demolition for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

The following have been deleted:

52.211-10 Commencement, Prosecution, and Completion of Work APR 1984

(End of Summary of Changes)