N00024-16-R-4403-0012.pdf

N0002415NR93019

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to 1) request Final Proposal Revisions (FPR); 2) establish FPR due date of 15 March 2016 by 3:00PM EST;

3) revise the USS MCFAUL FY16 EDSRA end of availability date from 3 FEB 2017 to 10 MAR 2017; and 4) update Sections C, F, I, and J of the solicitation. Accordingly, the solicitation is hereby amended as follow s:

1. CONTRACT ID CODE PAGE OF PAGES

J 1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 08-Mar-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N00024-16-R-4403

X 9B. DATED (SEE ITEM 11)

05-Nov-2015

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Mar-2016

CODE

NAVAL SEA SYSTEMS COMMAND (HQ)

1333 ISAAC HULL AVE SE

WASHINGTON NAVY YARD DC 20376-2030

N00024 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N00024-16-R-4403

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SUMMARY OF CHANGES

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

SCOPE OF WORK

Paragraph 3. SCHEDULE is herbey restated as follows:

“3. SCHEDULE: USS McFaul must be delivered, mission-ready, no later than 10 March 2017Amendment 0012.”

Paragraph 3.1 MILESTONES is herbey restated as follows:

“3.1: MILESTONES: In addition to the contract completion date of 10 March 2017 Amendment 0012, the Government has established execution dates for the following milestones:

Milestone Date A+ Dates

TRANSIT TO KTR Facility **** **** Enter Dock **** ****

25% CONFERENCE **** ****

TURNOVER 1 **** ****

TURNOVER 2 **** ****

TURNOVER 3 **** ****

TURNOVER 4 **** ****

TURNOVER 5 **** ****

TURNOVER 6 **** ****

50% CONFERENCE **** ****

TURNOVER 7 **** ****

VCHT **** ****

Undock **** ****

FIREMAIN/AFFF/HALON **** ****

SEA WATER SERVICE **** ****

75% CONFERENCE **** ****

POTABLE WATER **** ****

LP/HP AIR **** ****

VENT SYSTEM **** ****

CHILL WATER/AIR CONDITIONING PLANTS **** ****

400HZ AVAILABLE **** ****

Start testing of 77052 temp ac Fwd aft IC **** **** Turnover 1 (PER DDG MOD MS CHART) **** **** Fiber Testing begins **** ****

HABTURNOVER / MOVE ABOARD COMMENCE **** ****

AEGIS LIGHT OFF **** ****

PCD **** ****

LOA **** ****

DOCK TRIALS **** ****

FAST CRUISE **** ****

SEA TRIALS STARTS **** ****

SEA TRIALS ENDS **** ****

END OF AVAIL **** **** ”

SECTION F - DELIVERIES OR PERFORMANCE

The “DELIVERY INFORMATION” is hereby restated as follows:

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 10-MAR-2017 1 N/A

FOB: Destination

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 10-MAR-2017 1 N/A

0005 10-MAR-2017 1 N/A

0006 10-MAR-2017 1 N/A

0007 10-MAR-2017 1 N/A

0008 10-MAR-2017 1 N/A

0009 10-MAR-2017 1 N/A

0010 10-MAR-2017 1 N/A

0011 10-MAR-2017 1 N/A

0012 10-MAR-2017 1 N/A

0013 10-MAR-2017 1 N/A

0014 10-MAR-2017 1 N/A

0015 10-MAR-2017 1 N/A

0016 10-MAR-2017 1 N/A

0017 10-MAR-2017 1 N/A

0018 10-MAR-2017 1 N/A

0019 10-MAR-2017 1 N/A

0020 10-MAR-2017 1 N/A

0021 10-MAR-2017 1 N/A

0022 10-MAR-2017 1 N/A

0023 10-MAR-2017 1 N/A

SECTION I - CONTRACT CLAUSES

The following have been added by reference:

52.245-1 Alt I Government Property (Apr 2012) Alternate I APR 2012 52.245-9 Use And Charges APR 2012 252.211-7007 Reporting of Government-Furnished Property AUG 2012 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012 252.245-7003 Contractor Property Management System Administration APR 2012 252.245-7004 Reporting, Reutilization, and Disposal MAR 2015

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

The following have been modified:

EXHIBITS AND ATTACHMENTS

The following document(s), exhibit(s), and other attachment(s) form a part of this solicitation:

No. Document

Attachment S-1 Technical Capabilities Data Sheet Attachment S-2 Past Performance Questionnaire

Attachment S-3 Pre-Proposal Information (PPI) Form Attachment S-4 Past Performance References Attachment S-5 Eligibility Criteria Data Sheet Attachment S-6 Pricing Workbook updated 29 DEC 15 (Amendment 0008)

The following document(s), exhibit(s), and other attachment(s) also form a part of this solicitation and will form a part of the contract resulting from this solicitation:

No. Document Attachment J-1 USS MCFAUL EDSRA Specification Package No. SSP NSSA-501-16 updated 31

DEC 15 (Amendment 0009) Attachment J-2 USS MCFAUL FY16 EDSRA Work Item Plans, Drawings, and Other References Attachment J-3 USS MCFAUL (DDG-74) Execution Milestone and Key Event Dates updated 8

MAR 16 (Amendment 0012) Attachment J-4 Award Fee Intra-Availability Milestones Attachment J-5 Subcontracting Plan (to be incorporated upon award)

Exhibit A Contract Data Requirements List (CDRL) (DD Form 1423) A001-A014* Exhibit B Contract Data Requirements List (CDRL) (DD Form 1423) B001-B009 Exhibit C Contract Data Requirements List (CDRL) (DD Form 1423) C001-C002

*CDRLs A004, A010, and A013 are reserved.

(End of Summary of Changes)