Mod_03_Rev_1_-_Contractor_Information_-_2019-07-15.pdf

CONTRACTOR INFORMATION

DOVER AFB, ELEVATING TRANSFER REPLACEMENT

30 JANUARY 2019

Revision 1: 15 July 2019

1. SERVICES AVAILABLE TO THE CONTRACTOR

A. Work Schedule for the System:

Normal Working Hours Days Of The Week

1st Shift 0700 to 1700 Monday thru FridaySaturday

2nd Shift 1700 to 2100 Monday thru FridaySaturday

3rd Shift N/A to N/A N/A

Work on Saturdays, Sundays, Federal Holidays, and other than normal working hours may be arranged if requested in writing three working days in advance and if approved.

C. Nearest Sea Port

Location: Baltimore Maryland

D. Office space available? Yes X No

Location: N/A

E. Classroom space available?

(For number required to be trained)

X Yes No

(1) Location: Building 550

(2) Dry erase board? X Yes No

(3) DVD player? X Yes No

(4) Computer? X Yes No

F. Staging space available? X Yes No

(1) Under roof square feet: North ETV Maintenance Bay

(2) Outside square feet: 2,000 Sq Feet

Location: Installation site and pallet storage yard.

Secured area? Yes X No

G. Restrooms available? Yes X No

FA8604-19-R-8111 0003 Attachment 4 Page 1 of 2

H. Utilities available:

(1) Electrical outlets available in area? X Yes No

Voltage: 120 Hertz: 60 Phase: Single

The number of 60 Hz outlets is limited. Long extension cords may be required.

(2) Water available? X Yes No

Location: Building 550

2. SERVICES NOT AVAILABLE TO THE CONTRACTOR

A. Forklifts. Government forklifts are not available for the Contractor's use.

B. Tools. Government tools or equipment are not available for the Contractor's use.

C. Loading/unloading. Government personnel will not load or unload any Contractor equipment, tools, and system components shipped under this contract.

3. JOINT OCCUPANCY

The Contractor will be installing the equipment in close proximity to normal Government operations. The Contractor must minimize interference with base personnel.

Five Government caused delay days have been built into the scheduled time on site. For each Government caused delay day (greater than 6 continuous hours of delay per 14-hour period) over five delay days will add an allowable day to the onsite time. Each Government caused day shall be reported to the Contracting Officer within 72 hours from the conclusion of the Government caused delay. If the Government caused delay lasts longer than two continuous days the contracting Officer shall be notified immediately. The Contracting Officer will determine what is or is not a Government caused delay day.

4. SITE VISIT

To acquaint bidders/offerers with this project, arrangements may be made to visit the site by contacting:

Name: Mr. Bryan Mohr or Mike Williams

Phone: 302 677-4329, 302 677-2319

E-mail: bryan.mohr@us.af.mil, mike.williams.50@us.af.mil

Field Code Changed

Field Code Changed

FA8604-19-R-8111 0003 Attachment 4 Page 2 of 2 mailto:bryan.mohr@us.af.mil mailto:mike.williams.50@us.af.mil