Amendment_0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

See Block #2

PAGE OF PAGES

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

4. REQUISITION/PURCHASE REQ.NO.

5. PROJECT NO. (If applicable)

6. ISSUED BY AFLCMC/PZIEB CODE FA8604 7. ADMINISTERED BY (If other than Item 6) CODE

USAF/AFMC/AFLCMC

AF LIFE CYCLE MANAGEMENT CENTER

2275 D STREET, BLDG 16, RM 128

WRIGHT-PATTERSON AFB OH 45433-7228

JULIA A. KEMP 937-656-7470

JULIA.KEMP@US.AF.MIL

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NO.

FA860419R8111000

X

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, X is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATION OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(X )

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: ( ) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. ITEM

10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor X is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

NON-ACAT Elevating Transfer Vehicle, Dover AFB DE SUBJECT: Amend Section J, Atch 4 Contractor Information (REV 1) dated 15 July 2019

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print).

16A. NAME AND TITLE OF SIGNER (Type or print)

DIANE M. CHONG

15B. CONTRACTOR/OFFEROR

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

16C. DATE SIGNED

(Signature of person authorized to sign)

BY________________________________________

(Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV.10-83)

PREVIOUS EDITION UNUSABLE Prescribed by GSA ConWrite Version 7.1.3.5 FAR (48 CFR) 53.243 Created 16 Jul 2019 11:18 AM

SCHEDULE

FA860419R81110003

1. Subject RFP is hereby amended as follows:

a. Amend Section J to include the following revised Attachments:

(1) Attachment 4, Contractor Information, (REV 1) dated 15 July 2019 attached hereto.

CONTRACTOR INFORMATION

DOVER AFB, ELEVATING TRANSFER REPLACEMENT

30 JANUARY 2019

Revision 1: 15 July 2019

1. SERVICES AVAILABLE TO THE CONTRACTOR

A. Work Schedule for the System:

Normal Working Hours Days Of The Week

1st Shift 0700 to 1700 Monday thru FridaySaturday

2nd Shift 1700 to 2100 Monday thru FridaySaturday

3rd Shift N/A to N/A N/A

Work on Saturdays, Sundays, Federal Holidays, and other than normal working hours may be arranged if requested in writing three working days in advance and if approved.

C. Nearest Sea Port

Location: Baltimore Maryland

D. Office space available? Yes X No

Location: N/A

E. Classroom space available?

(For number required to be trained)

X Yes No

(1) Location: Building 550

(2) Dry erase board? X Yes No

(3) DVD player? X Yes No

(4) Computer? X Yes No

F. Staging space available? X Yes No

(1) Under roof square feet: North ETV Maintenance Bay

(2) Outside square feet: 2,000 Sq Feet

Location: Installation site and pallet storage yard.

Secured area? Yes X No

G. Restrooms available? Yes X No

FA8604-19-R-8111 0003 Attachment 4 Page 1 of 2

H. Utilities available:

(1) Electrical outlets available in area? X Yes No

Voltage: 120 Hertz: 60 Phase: Single

The number of 60 Hz outlets is limited. Long extension cords may be required.

(2) Water available? X Yes No

Location: Building 550

2. SERVICES NOT AVAILABLE TO THE CONTRACTOR

A. Forklifts. Government forklifts are not available for the Contractor's use.

B. Tools. Government tools or equipment are not available for the Contractor's use.

C. Loading/unloading. Government personnel will not load or unload any Contractor equipment, tools, and system components shipped under this contract.

3. JOINT OCCUPANCY

The Contractor will be installing the equipment in close proximity to normal Government operations. The Contractor must minimize interference with base personnel.

Five Government caused delay days have been built into the scheduled time on site. For each Government caused delay day (greater than 6 continuous hours of delay per 14-hour period) over five delay days will add an allowable day to the onsite time. Each Government caused day shall be reported to the Contracting Officer within 72 hours from the conclusion of the Government caused delay. If the Government caused delay lasts longer than two continuous days the contracting Officer shall be notified immediately. The Contracting Officer will determine what is or is not a Government caused delay day.

4. SITE VISIT

To acquaint bidders/offerers with this project, arrangements may be made to visit the site by contacting:

Name: Mr. Bryan Mohr or Mike Williams

Phone: 302 677-4329, 302 677-2319

E-mail: bryan.mohr@us.af.mil, mike.williams.50@us.af.mil

Field Code Changed

Field Code Changed

FA8604-19-R-8111 0003 Attachment 4 Page 2 of 2 mailto:bryan.mohr@us.af.mil mailto:mike.williams.50@us.af.mil