Solicitation Amendment FA485525R00010003 SF 30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

1) Upload all timely RFIs. Majority of RFIs have been answered. Remainder will be answered via Block 14 (Description of Amendment/Modification):

Amendment 0004 NLT COB Friday, 28 March.

2) Performance Work Statement / Attachment 01: Updated per RFIs and corresponding response(s). Updated to V3.8.

3) Exhibit A-001 DD1423 CDRL for Mgmt Plan / Attachment 05: Updated per RFIs and corresponding response(s).

4) Price Proposal Workbook / Attachment 07: Updated per RFIs and corresponding response(s). Updated to V2.

5) Small Business Participation Commitment Document / Attachment 16: Updated per RFIs and corresponding response(s). Latest revised date is 20 March 2025.

6) Past Performance Info Sheet & Questionnaire / Attachment 18: Updated per RFIs and corresponding response(s). Latest revised date is 20 March 2025.

7) FAR 52.212-1 / Attachment 20: Updated per RFIs and corresponding response(s). Latest revised date is 24 March 2025.

8) See Summary of Changes for additional updates incorporated in this Amendment.

Solicitation/Contract Form

The following modifications were made:

INFORMATION FROM TO

Reference Description North American Industry Classification System (NAICS) North American Industry Classification System

(NAICS)

561210

Contract Clauses

Additional Information/Notes

The following Clauses were added:

FAR Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

52.249-8 Default (Fixed-Price Supply and Service). Apr 1984

The following Clauses modifications were made:

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. Sep 2000 hereby reads as follows:

As prescribed in , insert the following clause in solicitations and contracts:11.503(a)

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, (a) pay to the Government liquidated damages of per calendar day of delay.$661.21

If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated (b) damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence (c) of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

FA485525R00010003

110 E ALISON AVE BLDG 600, CP 575 785 2321

CANNON AFB, NM 88103-5321

UNITED STATES

MICHAEL BOYD, Email: michael.boyd.9@us.af.mil AdminBy:

SCD: PAS: