Amendment 1_SEC F_FAR 52.211-10_Page 14 of 48.doc
FAR Clause Amendment 1 DOC document 29 KB Posted
- Solicitation number
- AG-0355-S-09-0004
About this file
Amendment 1, Section F, FAR 52.211-10 Change
View the file
Other versions and copies of FAR 52.211-10
| File | Revision | Posted | Attached to |
|---|---|---|---|
| B.08_W9127N21B00180002-Bids Due 12May21 & 52.211-10 Revision.pdf | May 12, 2021 | Rogue River Mechanical Dredging 2021 | |
| Attachment_1_F.1_52.211-10.pdf | Revision not stated | NGWSP Block 9 through 11 | |
| Revised Clause F.1 52.211-10.doc | Revision not stated | Mitchelson Wetlands Restoration |
Who attaches FAR 52.211-10
Other files
Show all 46
On GovTribe
Work with this file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Amendment 1
AG-0355-S-09-0004
April 15, 2009
Custer National Forest, Beartooth Ranger District
Recovery – FY09 Cascade West Fork Rock Creek Road #2071 Phases III & IV Road Reconstruction
SECTION D--PACKAGING AND MARKING
{For this Solicitation, there are NO clauses in this Section}
SECTION E--INSPECTION AND ACCEPTANCE
FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)
This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.arnet.gov/far/
FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES
52.246-12 Inspection of Construction (AUG 1996)
SECTION F--DELIVERIES OR PERFORMANCE
FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES
52.242-14 Suspension of Work (APR 1984)
FAR 52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than for use not later than September 11, 2009 (Phase III with exception of Seeding) and July 30, 2010 (Phase IV with exception of Seeding). The time stated for completion shall include final cleanup of the premises.
52.211-12 -- Liquidated Damages – Construction (Sep 2000)
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $573.36 for the first day of delay
File details come from the government source that posted it. Updated .