B.08_W9127N21B00180002-Bids Due 12May21 & 52.211-10 Revision.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to:

1. Extend the bid due date to 12 May 2021.

2. Change block 12B. to require that performance and payment bonds be submitted no later than 5 days after aw ard.

3. Revise FAR clause 52.211-10.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 05-May-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9127N21B0018

X 9B. DATED (SEE ITEM 11)

07-Apr-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

05-May-2021

CODE

USACE, PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204

W9127N 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127N21B0018

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 07-May-2021 02:00 PM to 12-May-2021 02:00 PM.

The performance payment bonds calendar days has decreased by 2 from 7 to 5.

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

Commencement of work under this contract as follows, after receiving Notice to Proceed:

(a) Commence work at CLIN 0002, and if exercised, optional CLINs 0005, 0006, and 0007 Rogue River Entrance Channel no earlier than 1 June 2021

(b) Commence work at CLIN 0003 Rogue River Boat Basin Access Channel no earlier than 15 June 2021

(c) Commence work at CLIN 0004 Rogue River Gravel Bar no earlier than 15 June 2021

(d) Prosecute the work diligently, and

(e) Complete all work ready for use prior to the FINAL CONSTRUCTION PHYSICAL COMPLETION

DATE.

FINAL CONSTRUCTION PHYSICAL COMPLETION DATE is 31 October 2021.

FINAL CONSTRUCTION PHYSICAL COMPLETION includes physical completion of all site work, site cleanup, and demobilization.

CONTRACT END DATE 90 days following the FINAL CONSTRUCTION PHYSICAL COMPLETION DATE.

CONTRACT END DATE includes submission and approval of all final remaining work documents.

The FINAL CONSTRUCTION PHYSICAL COMPLETION DATE is based on the assumption that the successful offeror will receive the notice to proceed by 31 May 2021. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the solicitation.

NOTES:

*Definition: Commence work means having dredge on site and ready to dredge.

**The Government intends to award a contract no later than 24 May 2021 and issue NTP no later than 31 May

2021.

(End of clause)

(End of Summary of Changes)

W9127N21B0018