B08_140P2026R0093_CUVA_224822_Solicitation_0001.pdf

Date 06/23/2026

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

Page

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKAGING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-4 INSPECTION OF SERVICES-FIXED-PRICE (AUG 1996)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING

PLATFORM SYSTEM (FEB 2021)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT : KEY TRADES

SPECIAL REQUIREMENT: PUBLICITY

(End of clause)

CONSTRUCTION CONTRACT ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B)

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.204-2 [RESERVED]

52.204-23 [RESERVED]

52.204-25 [RESERVED]

52.204-30 [RESERVED]

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEVIATION JAN 2026)

52.222-55 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER

14026. DEVIATION (DEVIATION MAY 2026)

52.223-2 REPORTING OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2024) (DEVIATION FEB 2025)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA

(DEVIATION MAY 2026)

52.223-10 [RESERVED]

52.223-11 OZONE-DEPLETING SUBSTANCES (DEVIATION MAY 2026)

52.223-23 SUSTAINABLE PRODUCTS (DEVIATION MAY 2026)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

52.228-11 INDIVIDUAL SURETY - PLEDGE OF ASSETS (FEB 2021) (DEVIATION MAY 2023

SEE DOI-AAAP-0165, V02)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020) (DEVIATION

MAY 2023 SEE DOI-AAAP-0165, V02)

52.236-2 DIFFERING SITE CONDITIONS (DEVIATION JAN 2026)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (DEVIATION JAN

2026)

52.236-5 MATERIAL AND WORKMANSHIP (DEVIATION JAN 2026)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (DEVIATION JAN 2026)

52.236-7 PERMITS AND RESPONSIBILITIES (DEVIATION JAN 2026)

52.236-8 OTHER CONTRACTS (DEVIATION JAN 2026)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (DEVIATION JAN 2026)

52.236-10 OPERATIONS AND STORAGE AREAS (DEVIATION JAN 2026)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (DEVIATION JAN 2026)

52.236-12 CLEANING UP (DEVIATION JAN 2026)

52.236-13 ACCIDENT PREVENTION (DEVIATION JAN 2026)

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (DEVIATION JAN 2026)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR

1984)

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF

OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.201-1 ACQUISITION 360: VOLUNTARY SURVEY (SEP 2023)

52.204-8 [RESERVED]

52.204-24 [RESERVED]

52.204-26 [RESERVED]

52.204-29 [RESERVED]

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2025)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION

(DEVIATION MAY 2026)

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (DEVIATION JAN 2026)

52.223-1 BIOBASED PRODUCT CERTIFICATION MAY 2024 (DEVIATION MAY 2026)

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS—NOTICE AND REPRESENTATION

(JUN 2020)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.216-1 TYPE OF CONTRACT (APR 1984)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY

2014)

52.228-1 BID GUARANTEE (SEP 1996)

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

52.228-17 INDIVIDUAL SURETY – PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.232-38 SUBMISSION OF ELECTRONIC FUNDS TRANSFER INFORMATION WITH OFFER

(JUL 2013)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996) (DEVIATION)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

SPECIAL INSRTUCTION: SITE VISIT

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION –

COMPETITIVE SOURCE SELECTION – TWO PHASE PROCESS

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

End of Section A

SECTION B – BID SCHEDULE

CONTRACT BID SCHEDULE

SOLICITATION NUMBER: 140P2026R0093

PARK - PMIS: CUVA 224822

PROJECT TITLE: Riverbank Stabilization

Offerors are required to submit, at a minimum, one (1) Firm-Fixed-Price (FFP) offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Please complete Attachment 26 Contract Price Schedule Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only.

For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs.

In case of summation error, the total corrected amounts govern. Round totals and extended prices to whole dollars.

Refer to section “H” of this solicitation for additional information regarding contract options.

Contract

Line Item

Number

(CLIN)

Contract Line Item (CLI) Title Quantity Unit of Measure Unit Price Total

Price

1 Design 1 LS

2 CUVA MM20 Construction 1 LS

TOTAL PROPOSED PRICE - (Contract Line-Item Number 1 through 2 --------------------------

***SHALL BE SUBMITTED WITH PHASE II PROPOSALS

End of Section B

SECTION C – SPECIFICATIONS / DRAWINGS

This project will stabilize the Cuyahoga Riverbank along Towpath Trail near MM 20. Stabilization will utilize natural rock rip rap and bioengineering techniques. This project also includes clearing the banks, placing rip rap, rebuilding banks, planting native vegetation to stabilize the soil, and remediation of the construction site and equipment access routes.

The eroded areas along the Towpath Trail are negatively impacting the park’s most important trail, adversely affecting park visitors. Repair of the eroded riverbank areas, in turn, will have direct positive visitor impacts. An estimate 1.5 million visitors use the trail each year, it is a critical asset that visitors rely on for an enjoyable and safe trail experience. By reducing erosion of the riverbanks and providing increased riparian habitat, water quality and aquatic habitat will also improve.

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

The to be completed is being solicited as a design build construction contract which will consist of stabilization of the Cuyahoga Valley riverbank MM 20 Towpath Trail. Stabilization efforts will include utilization of natural rock riprap and bioengineering techniques. Project includes clearing the riverbanks, placing rip rap, rebuilding banks, planting native vegetation to stabilize the soil and remediation of the construction site and the equipment access routes as necessary.

The selected Offeror will provide the following services as part of this design build effort.

1.Review Schematic Design preferred alternative for site MM 22 which will be provided by the NPS.

2.Upon award, determine and provide an overall Project Schedule, including design and construction work and proposed meetings.

3.Submit DB Design Development and DB Construction documents for review and approval.

4.Construction of the project.

5.Provide as-constructed drawings.

The Contractor shall be responsible for providing professional design services unless this responsibility is expressly excluded from the Contract. In the performance of such work, the Contractor shall be responsible for retaining licensed design professionals, who shall sign and seal all drawings, calculations, specifications and other submittals that the licensed professional prepares. The Contractor shall be responsible for, and DSC shall be entitled to rely upon the adequacy and completeness of all professional design services provided under this contract.

The Contractor is responsible for coordinating all activities of subcontractors. This responsibility includes coordination of preparation of shop drawings produced by different subcontractors where their work interfaces or may potentially conflict or interfere, and the installation of such work; scheduling of work by subcontractors; and use of the Project site for staging and logistics.

If the Contractor performs any of the work prior to notifying and receiving direction from the Contracting Officer, the Contractor shall assume full responsibility for correction of such work, and any fees or penalties that may be assessed for non-compliance.

The Contractor shall immediately bring to the Contracting Officer’s attention any hazardous materials or conditions not disclosed in the Contract Documents discovered by or made known to the Contractor during the performance of the contract.

The Contractor shall not proceed with work or procure products or materials described or shown in submittals until the Contracting Officer has indicated approval of the submittal. Any work or activity undertaken prior to approval shall be at the Contractor’s risk; should the Contracting Officer subsequently determine that the work or activity does not comply with the Contract, the Contractor shall be responsible for all cost and time required to comply with the Contracting Officer’s determination.

The Contracting Officer shall have the right to order the Contractor to cease execution of work for which submittals have not been approved. The Government shall not be liable for any cost or delay incurred by the Contractor attributable to the proper exercise of this right.

The contractor shall direct to the Contracting Officer’s attention, in writing, all deviations or changes in resubmitted submittals. In the absence of such written notice, the Contracting Officer’s approval of a resubmission shall not include or apply to such deviations or changes.

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

End of Section C

SECTION D – PACKAGING AND MARKING

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

Section Does Not Apply

End of Section D

SECTION E – INSPECTION AND ACCEPTANCE

52.246-4 INSPECTION OF SERVICES-FIXED-PRICE (AUG 1996)

(a) Definition. "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount.

When the defects in services cannot be corrected by reperformance, the Government may-

(1) Require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and

(2) Reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may-

(1) By contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service; or

(2) Terminate the contract for default.

(End of clause)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

The quality standards detailed on the Denver Service Center Workflow website:

https://www.nps.gov/dscw/index.htm .

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

(ii) Attention to such factors as organization, planning work instructions, documentation control, and advanced metrology.

(End of clause)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its Subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

End of Section E

SECTION F – DELIVERIES OR PERFORMANCE

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

(a)

(1) Within five days after the work commences on the contract or another period of time determined by the Contracting Officer, the Contractor shall prepare and submit to the Contracting Officer for approval a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the work (including acquiring materials, plant, and equipment).

(2) The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period.

(3) If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall continually update the actual progress in the schedule and shall submit it to the

Contracting Officer by the means prescribed in the contract for transmittals or as directed by the

Contracting Officer.

(c)

(1) If the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to recover lost time and execute in accordance with the approved schedule, without additional cost to the

Government.

(2) Such steps may include increasing the number of shifts, overtime operations, days of work, and/or the amount of construction plant.

(3) The Contractor shall submit, for approval, supplementary schedule(s) that demonstrate how the lost time will be recovered.

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

(d) If the Contractor does not recover the lost time, the Contracting Officer may determine that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20-days before the Contractor shall have notified the

Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

End of Section F

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the Contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3-days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30-days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT

REPORTING SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in CPARS for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30-days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

5. Within 60-days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60-calendar days after receipt of the CPAR. On day 15, the evaluation will become available in CPARS marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60-days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the Contractor on (date).

The Contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven (7)-days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING

PLATFORM SYSTEM (FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

The Contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the Contractor. If the CMR

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization recommends acceptance, the Contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP);

2. Completed copy of the Pay Estimate Form (including signed certification of Subcontractor payments);

3. Completed copy of the Limitations on Subcontracting Report

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts;

5. A copy of the current construction schedule (refer to project specification section 013216); and

6. A copy of the current Schedule of Values. (refer to project specification section 013216).

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date.

Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email Invoice Processing Platform - Contact Us (treasury.gov) or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause)

End of Section G

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT: COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK

The Contractor shall be required to (a) commence work under this contract within 10 after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 260 Days.* The time stated for completion shall include final cleanup of the premises.

(End of Local Clause)

SPECIAL REQUIREMENT : KEY PERSONNEL

(a)The Contractor shall assign to this contract the following key personnel:

Architect/Engineering:

Structural Engineer Water Engineer Civil Engineer Project Engineer

Construction:

Project Manager Superintendent Quality Control Manager Safety Manager

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

(b)During the first 120 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 120-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c)The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

SPECIAL REQUIREMENT : KEY TRADES

(a)The Contractor shall identify firms that will perform the following KEY TRADES under this contract. If Key Trades will be self-performed, note “self-performed” in the appropriate trade; otherwise provide the name(s) of assigned subcontractors.

Other:__________________________________________ (b)The assignments above are permanent for the contract duration. The Contractor shall make no substitutions of the above listed Key Trade assignments unless the substitution is approved or directed by the Contracting Officer. The Contractor shall send requests for substitutions to the Contracting Officer a minimum of 15 calendar days prior to any substitution and provide the information required by paragraph (c) below.

(c)The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete qualification statements for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes shall have comparable qualifications to the firm being replaced. The Contracting Officer will approve or deny substitution requests within 15 calendar days after receipt of all required information. This clause will be modified to reflect any approved changes.

(End of clause) .

(End of Local Clause)

SPECIAL REQUIREMENT: PUBLICITY

(a)Except with the prior approval of the Contracting Officer, the consultant shall not release for publication any drawing, rendering, perspective, sketch, photograph, report, specification, cost estimate, or other material of any nature pertaining to the facilities for which services are performed under the terms of this contract.

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

(b)The provision of this article shall extend also to the release of any such material to any person not so authorized by the Contracting Officer.

(End of clause)

SPECIAL REQUIREMENT: ORGANIZATIONAL CONFLIECTS OF INTEREST

(a)Purpose. The purpose of this clause is to ensure that the contractor and its subcontractors:(1)Are not biased because of their financial, contractual, organizational, or other interests which relate to the work performed under this contract, and (2)Do not obtain any unfair competitive advantage over other parties by virtue of their performance of this contract.

(b)Scope. The restrictions described herein shall apply to performance or participation by the contractor, its parents, affiliates, divisions and subsidiaries, and successors in interest (hereinafter collectively referred to as “contractor”) in the activities covered by this clause as a prime contractor, subcontractor, co-sponsor, joint venturer, consultant, or in any similar capacity. For the purpose of this clause, affiliation occurs when a business concern is controlled by or has the power to control another or when a third party has the power to control both.

(c)No contract for the construction of a project shall be awarded to the firm (including its subsidiaries or affiliates) that designed the project (except with the approval of the head of the agency or authorized representative).

(d)Warrant and Disclosure. The warrant and disclosure requirements of this paragraph apply with full force to both the contractor and all subcontractors. The contractor warrants that, to the best of the contractor's knowledge and belief, there are no relevant facts or circumstances which would give rise to an organizational conflict of interest, as defined in FAR Subpart 9.5, and that the contractor has disclosed all relevant information regarding any actual or potential conflict. The contractor agrees it shall make an immediate and full disclosure, in writing, to the Contracting Officer of any facts that may cause a reasonably prudent person to question the contractor's impartiality because of the appearance or existence of bias or an unfair competitive advantage. Such disclosure shall include a description of the actions the contractor has taken or proposes to take in order to avoid, neutralize, or mitigate any resulting conflict of interest.

(e)Remedies. The Contracting Officer may terminate this contract for convenience, in whole or in part, if the Contracting Officer deems such termination necessary to avoid, neutralize or mitigate an actual or apparent organizational conflict of interest. If the contractor fails to disclose facts pertaining to the existence of a potential or actual organizational conflict of interest or misrepresents relevant information to the Contracting Officer, the Government may terminate the contract for default, suspend or debar the contractor from Government contracting, or pursue such other remedies as maybe permitted by law or this contract.

(f)Subcontracts. The contractor shall include a clause substantially similar to this clause, including paragraphs (f) and(g), in any subcontract or consultant agreement at any tier expected to exceed the simplified acquisition threshold. The terms “contract,” “contractor,” and “Contracting Officer” shall be appropriately modified to preserve the Government's rights.

(End of Clause)

CONSTRUCTION CONTRACT ADMINISTRATION - FEDERAL ACQUISITION

REGULATIONS 36.211(B).

FAR 36.211(b) requires agencies provide description of policies and procedures that apply to defeminization of equitable adjustments for change orders under construction contracts and data on the time required to definitize

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization equitable adjustments for change orders under construction contracts. This information can be found at:

https://www.doi.gov/pam/acquisition/policy/constructioncontract.

End of Section H

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

Federal Acquisition Regulation: https://www.acquisition.gov/far/ Department of the Interior Acquisition Regulation (CFR, Title 48, Chapter 14): http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER

ACTIVITY (MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020) 52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUN

2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (DEVIATION APR 2026)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (DEVIATION APR 2026)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH

CONTRACTOR’S DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (DEVIATION

MAY 2026)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS

(DEVIATION MAY 2026)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (DEVIATION

MAY 2026)

52.215-2 AUDIT AND RECORDS-NEGOTIATIONS (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—MODIFICATIONS

(JUN 2020)

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (JUN 2020)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER

THAN PENSIONS (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (DEVIATION JAN 2026)

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (DEVIATION JAN 2026)

52.222-3 CONVICT LABOR (DEVIATION MAY 2026)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION

(DEVIATION MAY 2026)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (DEVIATION MAY 2026)

52.222-7 WITHHOLDING OF FUNDS (DEVIATION MAY 2026)

52.222-8 PAYROLLS AND BASIC RECORDS (DEVIATION MAY 2026)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (DEVIATION MAY 2026)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (DEVIATION MAY 2026)

52.222-12 CONTRACT TERMINATION - DEBARMENT (DEVIATION MAY 2026)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIRMENTS AND RELATED

REGULATIONS (MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (DEVIATION MAY 2026)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES (DEVIATION MAY 2026) 52.222-20 CONTRACTS FOR MATERIALS, SUPPLIES, ARTICLES AND EQUIPMENT EXCEEDING $15,000

(DEVIATION MAY 2026)

52.222-30 CONSTRUCTION WAGE RATE REQUIREMENTS – PRICE ADJUSTMENT (NONE OR

SEPARATELY SPECIFIED (PRICING METHOD) (AUG 2018)

52.222-31 CONSTRUCTION WAGE RATE REQUIREMENTS – PRICE ADJUSTMENT (PERCENTAGE

METHOD) (AUG 2018)

52.222-32 CONSTRUCTION WAGE RATE REQUIREMENTS – PRICE ADJUSTMENT (ACTUAL METHOD)

(DEVIATION MAY 2026)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (DEVIATION MAY 2026)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (DEVIATION MAY 2026)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (DEVIATION MAY 2026)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT

(DEVIATION MAY 2026)

52.222-50 COMBATING TRAFFICKING IN PERSONS (DEVIATION MAY 2026)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (DEVIATION MAY 2026)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (DEVIATION MAY 2026)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2024)

52.223-7 NOTICE OF RADIOACTIVE MATERIALS (DEVIATION MAY 2026)

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.226-7 DRUG-FREE WORKPLACE (MAY 2024)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (MAY

2024)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (DEVIATION SEP 2025)

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

Solicitation No.

140P2026R0093

National Park Service (NPS) – Denver Service Center (DSC) Design-Build CUVA 224822 Riverbank Stabilization

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT (OCT

2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS CONTRACTORS (MAR 2023)

52.233-1 DISPUTES (MAY 2014) – ALTERNATE 1 (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.236-24 WORK OVERSIGHT IN ARCHITECT-ENGINEER CONTRACTS (APR 1984)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (DEVIATION SEP 2025)

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (DEVIATION

MAY 2026)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING – CONSTRUCTION (OCT 2025)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012),

ALT 1 (SEP 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) ALTERNATE I (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (DEVIATION MAY 2026)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

(a) Definition.

United States, as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)

(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites-

(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

(3) Any required posters may be obtained as follows: Downloadable hotline posters as well as instructions for obtaining a hard copy poster are available at http://www.doioig.gov/hotline.

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the threshold specified in Federal Acquisition…