Y26-720-EB Seidel Road at Summerlake Park Boulevard Roundabout Improvements
Closed State & local contract opportunity
- Solicitation number
- Y26-720
- State
- Florida
- Responses due
Opportunity facts
- Jurisdictions
- NIGP codes
- 790 Seed, Sod, Soil, And Inoculants
- 909 Building Construction Services, New, Including Maintenance And Repair Services
- 910 Building Maintenance, Installation And Repair Services
- 912 Construction Services, General, Including Maintenance And Repair Services)
- 913 Construction Services, Heavy, Including Maintenance And Repair Services
- 914 Construction Services, Trades, New Construction
- 959 Marine Construction And Related Services; Marine Equipment Maintenance And Repair
- 968 Public Works And Related Services
- 988 Roadside, Grounds, Recreational And Park Area Services
- UNSPSC codes
- 11110000 Earth and stone
- 95120000 Permanent buildings and structures
- 10150000 Seeds and bulbs and seedlings and cuttings
- 70170000 Water resources development and oversight
- 72000000 Building and Facility Construction and Maintenance Services
- 76000000 Industrial Cleaning Services
- 72140000 Heavy construction services
- 72141200 Marine construction services
- 70110000 Horticulture
- Point of contact
-
- Elia Batista elia.batista@ocfl.net (407) 836-5635
Opportunity details come from procurement.opengov.com. Updated .
About this opportunity
Orange County, Florida is accepting sealed bids for the Y26-720-EB Seidel Road at Summerlake Park Boulevard Roundabout Improvements project, a construction procurement with an estimated cost of $1,512,000. The project involves converting a three-legged stop-controlled intersection into a two-lane roundabout, including roadway construction with westbound two-lane and single-lane eastbound and northbound approaches, drainage infrastructure compliant with FDOT and South Florida Water Management District standards, sidewalk connections, storm sewer systems, utility coordination and adjustments, traffic control design, signage and pavement markings, and pedestrian-level LED lighting. Qualified respondents must have completed at least three similar projects within the past ten years as a prime contractor or subcontractor, with at least one project demonstrating intersection improvements including roundabout installation and roadway signing, incorporating at least four of the following elements: asphalt paving, drainage, sidewalk, pavement marking, roadway signing, or lighting installation to FDOT standards. The contractor must possess all applicable state and federal licenses, secure a bid bond equal to at least 10 percent of the estimated contract amount, complete substantial construction within 218 days and final completion within 248 days from the Notice to Proceed, maintain a qualified on-site superintendent, coordinate all utility relocations, submit weekly work progress schedules and monthly aerial photographs, and comply with all environmental regulations, NPDES permits, stormwater pollution prevention planning, and ADA accessibility requirements. Electronic bid submissions are required through the OpenGov e-Procurement Platform with a deadline of 4:00 pm EST on Thursday, March 12, 2026; a non-mandatory pre-bid meeting and site visit are scheduled for February 16, 2026 at 10:30 am, and questions must be submitted by Friday, February 27, 2026 at 5:00 pm EST. Awards will be made to the lowest responsive and responsible bidder, with payment and performance bonds required upon contract award and 5 percent retainage withheld from progress payments on contracts exceeding $200,000, payable within 20 business days of invoice approval at 95 percent of earned amounts.
Service Disabled Veteran businesses may be eligible for a price preference of up to 8 percent depending on bid amount thresholds, though no reciprocal preference will be applied. All respondents must provide compliance documentation including conflict of interest disclosures, felony conviction statements, civil litigation history, drug-free workplace certification, E-Verify registration confirmation, and anti-human trafficking affidavits. The contractor bears all costs associated with site investigation, subsurface condition verification, groundwater testing, survey work, permit acquisition, NPDES land clearing permits, dewatering permits, and environmental compliance, with liquidated damages assessed at $200 per day for failure to meet substantial or final completion dates. No additional compensation is provided for permit delays, utility coordination issues, or unforeseen subsurface conditions; however, a geotechnical engineering report, drainage analysis, lighting design calculations, construction plans spanning 91 sheets, and an Environmental Resource Permit Exemption from the South Florida Water Management District for minor roadway safety construction are available to support bidder cost estimations and construction planning.
Opportunity text
NOTICE IS HEREBY GIVEN that Orange County, Florida, henceforth referred to as the County is accepting sealed bids for Y26-720-EB Seidel Road at Summerlake Park Boulevard Roundabout Improvements (Y26-720)
Sealed offers for furnishing the above will be accepted up to 4:00 pm EST on Thursday, March 12, 2026.
The Estimated Cost for this project is $1,512,000
NOTE: Respondents are required to submit responses electronically via the OpenGov e-Procurement Platform. Respondents shall not be permitted to hand-deliver, mail, telephone, fax or email offers.
Responses received after the submission deadline and/or transmitted outside of the designated OpenGov e-Procurement Platform shall be rejected.
Important Instructions for Electronic Submittal
The County is ONLY accepting electronic bid submissions using the OpenGov e-Procurement Platform. Respondents shall create a FREE account with OpenGov by signing up at https://procurement.opengov.com/login Once you have completed account registration, browse back to this page, click on "Submit Response", and follow the instructions to submit the electronic bid.
It is the respondent's responsibility to ensure they commence their upload efforts timely to meet the submission deadline. The County shall not be responsible for delays caused by any occurrence, including the respondent's network delays, bandwidth issues, internet outages, or technical difficulties.
OpenGov Technical Support
For Technical Support, respondent's can reach the OpenGov Service Desk:
Chat (preferred): Click the button in the lower right hand corner of the portal
Email: procurement-support@opengov.com
Phone: 1 (650) 336-7167
Hours: Mon-Fri 7am - 10pm EST
Timely Questions Regarding this Solicitation
The question and answer module of OpenGov IS being utilized for this solicitation. Timely questions concerning this solicitation shall be submitted in accordance with the deadline for questions: Friday, February 27, 2026 at 5:00 pm EST. Respondents are instructed not to contact the initiating division directly.
Consideration for modification or alteration of the documents contained in this solicitation shall be requested during the specified question period, before the applicable deadline. No oral interpretation of the meaning of the plans, specifications, or other Contract documents shall be considered binding. The County shall be bound by information and statements only when such statements are written and executed under the authority of the Manager, Procurement Division.
Answers for timely questions will be addressed in the OpenGov question and answer module or as an addenda to this solicitation depending on volume, participants are encouraged to subscribe as a follower and monitor all notifications. Beyond questions and answers, any and all modifications, clarifications, interpretations and supplemental instructions will be in the form of a written addendum which, if issued, will be available for download. All addenda and questions/answers so issued shall become part of the Contract Documents and receipt shall be acknowledged as specified herein.
This provision exists solely for the convenience and administrative efficiency of Orange County. No respondent or other third party gains any rights by virtue of this provision or the application thereof, nor shall any respondent or third party have any standing to sue or cause of action arising there from.
Untimely questions are unable to be submitted in the question and answer module, thereafter respondents raising critical concerns must email elia.batista@ocfl.net. Critical clarifications may be made via addenda, however, untimely questions may not be considered.
Files
Show all 30
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity