A.02 Amendment One Attachement Spec Revision 21R4003 4.21.21.pdf
PDF 115 KB Posted
- Solicitation number
- W912HP21R4003
About this file
This document contains an amendment to construction documents and safety requirements for a federal contract opportunity to expand parking facilities at the Veterans Affairs Medical Center in Columbia, South Carolina. Liquidated damages of $2,565 per calendar day will be assessed if the contractor exceeds the allowed 14-day temporary closure of an access road during construction phasing. Safety training and certifications are mandatory, including OSHA 10-hour training for all on-site workers and OSHA 30-hour training for competent persons. Infection control protocols must be followed to minimize the spread of airborne particles during interior and exterior construction work. The related federal contract opportunity from the Department of the Army Corps of Engineers has a solicitation number W912HP21R4003 and involves proposals due no later than May 3, 2021 for the parking expansion project at the Columbia VA Medical Center.
View the file
Other files
Show all 27
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Columbia VAMC –Correct Parking Site Deficiencies Columbia, SC VA Project No. 544-330
20210119 Construction Documents
01 00 00 -3
SECTION 01 00 00
GENERAL REQUIREMENTS
Any reference in the contract documents to “Department of Veterans Affairs”, “VA Contracting Officer”, “VA” or similar is to be interpreted by the construction contractor as equivalent to USACE Contracting Officer, or their designated representative (i.e. Contracting Officer’s Representative (COR) or Administrative Contracting Officer (ACO)).
Liquidated damages of $2,565.00 per calendar day will be assessed in accordance with the contract drawing CC002, Construction Phasing, Phase 3 note regarding temporary road closure, “Contractor may utilize E. Woodlands Trail Rd. for construction staging to construct the final floor of the existing parking garage. Temporary road closure of only 14 days is allowed during this phase for precast erection and upon approval by the COR.
Liquidated Damages shall be assessed per day for failure to complete road closure on time.”
1.1 SAFETY REQUIREMENTS
TRAINING.
1) Site-specific SOH orientation training at the time of initial hire or assignment to the project for every employee before working on the project site is required.
2) Mandatory training and certifications that are applicable to this project (e.g., explosive actuated tools, crane operator, rigger, crane signal person, fall protection, electrical lockout/NFPA 70E, machine/equipment lockout, confined space, etc…) and any requirements for periodic retraining/recertification are required.
3) Procedures for ongoing safety and health training for supervisors and employees shall be established to address changes in site hazards/conditions.
4) OSHA 10-hour training is required for all workers on site and the OSHA
30-hour training is required for Trade Competent Persons (CPs)
INFECTION CONTROL
A. Infection Control is critical in all medical center facilities.
Interior construction activities causing disturbance of existing dust, or creating new dust, must be conducted within ventilation-controlled areas that minimize the flow of airborne particles into patient areas.
Exterior construction activities causing disturbance of soil or creates dust in some other manner must be controlled.
B. Infection Control Risk Assessment, Control Measures and Construction
File details come from the government source that posted it. Updated .