Specs 2011 04 01.pdf

USMA West Point Bldg 753 Final Design 14576751

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 41 00 BID SCHEDULES

00 80 00.00 18 SPECIAL CONTRACT REQUIREMENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 00.00 18 DESIGN AND RECORD DRAWING REQUIREMENTS

01 20 00.00 20 PRICE AND PAYMENT PROCEDURES

01 23 13 OPTIONS

01 32 01.00 18 PROJECT SCHEDULE

01 33 00.00 18 SUBMITTAL PROCEDURES

01 33 29 LEED(TM) DOCUMENTATION

01 35 29.00 18 SAFETY AND OCCUPATIONAL HEALTH REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 02.00 18 QUALITY CONTROL SYSTEM (QCS)

01 45 04.00 18 CONTRACTOR QUALITY CONTROL

01 45 20.00 18 TESTING FOR MECHANICAL AND ELECTRICAL SYSTEMS

01 45 30.00 18 CONTRACTOR WARRANTY MANAGEMENT

01 45 35 SPECIAL INSPECTION FOR SEISMIC-RESISTING SYSTEMS

01 52 60.00 18 CONSTRUCTION INDOOR AIR QUALITY (IAQ) MANAGEMENT

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 62 35 RECYCLED / RECOVERED MATERIALS

01 73 19 INSTALLATION OF GOVERNMENT-FURNISHED CLASSROOM,

LABORATORY AND OFFICE EQUIPMENT

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 75 00 STARTING AND ADJUSTING

01 78 00 CLOSEOUT SUBMITTALS

01 78 23.00 18 OPERATION AND MAINTENANCE DATA

01 91 00 GENERAL COMMISSIONING REQUIREMENTS (TO BE PROVIDED BY

JACOBS/AMMAN & WHITNEY, JOINT VENTURE)

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION AND DECONSTRUCTION

02 41 01 DEMOLITION AND DECONSTRUCTION

02 42 91 REMOVAL AND SALVAGE OF HISTORIC BUILDING MATERIALS

02 81 00 TRANSPORTATION AND DISPOSAL OF HAZARDOUS MATERIALS

02 82 14.00 10 ASBESTOS HAZARD CONTROL ACTIVITIES

02 82 33.13 20 REMOVAL/CONTROL AND DISPOSAL OF PAINT WITH LEAD

02 84 16 HANDLING OF LIGHTING BALLASTS AND LAMPS CONTAINING PCBs

AND MERCURY

02 84 33 REMOVAL AND DISPOSAL OF POLYCHLORINATED BIPHENYLS (PCBs)

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 37 13 SHOTCRETE

03 45 00 PRECAST ARCHITECTURAL CONCRETE

DIVISION 04 - MASONRY

04 01 40 RESTORATION AND CLEANING OF MASONRY IN HISTORIC STRUCTURES

04 20 00 MASONRY

04 42 00 EXTERIOR STONE CLADDING

PROJECT TABLE OF CONTENTS Page 1

11 APRIL 2011 - 90% SUMBITTAL

04 43 00 STONE MASONRY

DIVISION 05 - METALS

05 05 23 WELDING, STRUCTURAL

05 12 00 STRUCTURAL STEEL

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

05 51 34 ALTERNATING TREAD STEEL STAIRS

05 52 00 METAL RAILINGS

05 72 00 DECORATIVE METAL SPECIALTIES

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 20 00 FINISH CARPENTRY

06 40 23 INTERIOR ARCHITECTURAL WOODWORK

06 41 16.00 10 LAMINATE CLAD ARCHITECTURAL CASEWORK

06 42 00 WOOD PANELING

06 60 00 PLASTIC FABRICATIONS

06 61 16 SOLID POLYMER (SOLID SURFACING) FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 11 13 BITUMINOUS DAMPPROOFING

07 21 13 BOARD AND BLOCK INSULATION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 42 43 COMPOSITE WALL PANELS

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 62 10 LEAD-COATED COPPER SHEET METAL FLASHING

07 81 00 SPRAY-APPLIED FIREPROOFING

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 14 00 WOOD DOORS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL AND DOOR LOUVERS

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 00 CERAMIC TILE AND QUARRY TILE

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 67 23.13 STANDARD RESINOUS FLOORING

09 67 23.14 CHEMICAL RESISTIVE RESINOUS FLOORING

09 68 00 CARPET

09 69 13 RIGID GRID ACCESS FLOORING

PROJECT TABLE OF CONTENTS Page 2

09 69 19 STRINGERLESS ACCESS FLOORING

09 75 00 STONE FACING

09 82 00 SOUND ABSORPTION MATERIALS

09 83 16 SPRAY ON ACOUSTICAL FINISH

09 90 00 PAINTS AND COATINGS

09 97 30 PREPARATION OF HISTORIC WOOD AND METAL SURFACES FOR PAINT

AND STAIN

DIVISION 10 - SPECIALTIES

10 10 00 VISUAL COMMUNICATIONS SPECIALTIES

10 14 02 INTERIOR SIGNAGE

10 21 13 TOILET COMPARTMENTS

10 22 26.43 SLIDING PARTITIONS

10 26 13 WALL AND CORNER GUARDS

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 51 13 METAL LOCKERS

DIVISION 11 - EQUIPMENT

11 24 29 FACILITY FALL PROTECTION EQUIPMENT

11 53 00 LABORATORY EQUIPMENT AND FUME HOODS

11 56 23 TELESCOPE DOMES

DIVISION 12 - FURNISHINGS

12 21 00 WINDOW BLINDS

12 24 13 ROLLER WINDOW SHADES

12 30 00 LABORATORY CASEWORK AND OTHER FURNISHINGS

12 30 10 LABORATORY SERVICE FITTINGS AND FIXTURES

12 65 00 FIXED SEATING

12 93 00 SITE FURNISHINGS

DIVISION 14 - CONVEYING EQUIPMENT

14 10 00 DUMBWAITERS

14 21 23 ELECTRIC TRACTION PASSENGER ELEVATORS

DIVISION 21 - FIRE SUPPRESSION

21 12 00 STANDPIPE SYSTEMS

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 07 19 PLUMBING PIPING INSULATION

22 10 00.00 10 VERTICAL PUMPS, AXIAL-FLOW AND MIXED-FLOW IMPELLER-TYPE

22 13 36 PNEUMATIC SEWAGE EJECTORS

22 14 29 SUMP PUMPS

22 15 09 GENERAL SERVICE COMPRESSED-AIR SYSTEMS CLEANING PROCEDURES

22 15 14 GENERAL SERVICE COMPRESSED-AIR SYSTEMS, LOW PRESSURE

22 20 00 LABORATORY PLUMBING

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

PROJECT TABLE OF CONTENTS Page 3

23 05 15 COMMON PIPING FOR HVAC

23 05 16 EXPANSION FITTINGS AND LOOPS FOR HVAC PIPING

23 05 48 VIBRATION AND SEISMIC CONTROLS FOR HVAC PIPING AND

EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 08 00.00 10 COMMISSIONING OF HVAC SYSTEMS

23 09 23 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 11 25 FACILITY GAS PIPING

23 15 10 LABORATORY AIRFLOW CONTROL SYSTEMS (LACS) - ELECTRONIC

23 15 13 LABORATORY EXHAUST FANS WITH ENERGY RECOVERY

23 21 23 HYDRONIC PUMPS

23 22 13.35 40 STEAM TRAPS

23 22 23 STEAM CONDENSATE PUMPS

23 22 26.00 20 STEAM SYSTEM AND TERMINAL UNITS

23 23 00 REFRIGERANT PIPING

23 25 00 TREATMENT OF WATER FOR MECHANICAL SYSTEMS

23 29 23 VARIABLE FREQNECY DRIVE SYSTEMS UNDER 600 VOLTS

23 34 16 CENTRIFUGAL HVAC FANS

23 34 23 HVAC POWER VENTILATORS

23 41 13.00 40 PANEL FILTERS

23 57 00 HEAT EXCHANGERS FOR HVAC

23 64 10 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 65 00 COOLING TOWERS

23 73 13 MODULAR INDOOR CENTRAL-STATION AIR-HANDLING UNITS

23 81 23.00 20 COMPUTER ROOM AIR CONDITIONING UNITS

23 82 19 FAN COIL UNITS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 08 00 APPARATUS INSPECTION AND TESTING

26 09 23.00 40 LIGHTING CONTROL DEVICES

26 11 16 SECONDARY UNIT SUBSTATIONS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 23 00.00 40 GENERATOR SWITCHBOARD

26 23 00 LOW VOLTAGE SWITCHGEAR

26 24 16.00 40 PANELBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

26 32 15.00 10 DIESEL-GENERATOR SET STATIONARY 100-2500 KW, WITH

AUXILIARIES

26 33 53.00 20 UNINTERRUPTIBLE POWER SUPPLY (UPS)

26 36 00.00 10 AUTOMATIC TRANSFER SWITCH AND BY-PASS/ISOLATION SWITCH

26 51 00 INTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 05 14.00 10 CABLE TELEVISION PREMISES DISTRIBUTION SYSTEM

27 05 28.36 40 CABLE TRAYS FOR COMMUNICATIONS SYSTEMS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 15 19.00 10 WIRE LINE DATA TRANSMISSION SYSTEM

27 21 10.00 40 FIBER OPTIC DATA TRANSMISSION SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 05 26.00 40 GROUNDING AND BONDING FOR ELECTRONIC SAFETY AND SECURITY

PROJECT TABLE OF CONTENTS Page 4

28 20 02 CENTRAL MONITORING SERVICES FOR ELECTRONIC SECURITY

SYSTEMS

28 20 03 ELECTRONIC SECURITY SYSTEMS - ACCESS CONTROL

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

31 48 00 UNDERPINNING

31 50 00 EXCAVATION SUPPORT AND PROTECTION

31 63 26 MINIPILES

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 28 PATCHING OF RIGID AND FLEXIBLE PAVEMENTS

32 11 23 AGGREGATE BASE COURSE

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 16 15 CONCRETE BLOCK PAVEMENTS

32 93 00 EXTERIOR PLANTS

DIVISION 33 - UTILITIES

33 11 00 WATER DISTRIBUTION

33 30 00 SANITARY SEWERS

33 40 00 STORM DRAINAGE UTILITIES

33 51 13.00 30 NATURAL-GAS METERING

33 70 02.00 10 ELECTRICAL DISTRIBUTION SYSTEM, UNDERGROUND

33 71 02.00 20 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 5

SECTION 00 41 00

BID SCHEDULES

01/07

PART 1 GENERAL

1.1 BASIS OF BIDS

1.1.1 Options

This contract will be solicited with options. A description of the options is contained in Standard Form 1442, "Solicitation, Offer and Award."

List of Options

Solicitation Number: __________

a) Option 1: Not Used.

Option 1 $______

b) Option 2: Not Used Option 2 $______

c) Option 3: Not Used Option 3 $______

d) Option 4

Provided borrowed lights in the physics and chemistry administrative office areas.

Generally, these areas will have acoustical lay-in ceilings at approximately ten feet above finish floor, with hollow metal borrowed lights extending from seven feet to ten feet at selected locations, as noted on the Borrowed Lights Schedule.

Option 4 $_______

e) Option 5

Provide floor plaques at selected locations for the Phase II areas, as noted on the architectural plans.

Plaques are to be approximately three feet by three feet, with custom images/text. Plaques are to be made of bronze and recessed into the floor slab so that they are level with the adjacent floor finish.

Option 5 $_______

f) Option 6

Provide a new modified built-up roofing system with rooftop pavers and photovoltaic cell components for teaching purposes at the roof level of the south end of Building 753 East, adjacent the chemistry labs.

The photovoltaic cell components may be installed at an alternate location, depending upon planned use times and other operational parameters yet to be determined. The electrical component of this option includes four

DOCUMENT 00 41 00 Page 1

List of Options

200-watt photovoltaic panels, framing, interconnection wiring, inverter, DC disconnect, and power feeder from the nearest 480V panel, as required.

Option 6 $_______

g) Option 7: Not Used Option 7 $______

h) Option 8

Provide electrically-charged vision glazing for translucent windows at selected borrowed light vision windows (in Rooms B-102 and B-211).

The electrical component of this option calls for a 20A, 120V power connection.

Option 8 $_______

i) Option 9

Provide Motorized operation and associated controls with all projection screens.

This option calls for a four-inch-square junction box above the ceiling and a connection to the nearest 120V circuit. A junction box will be provided on the wall near the instructor's laboratory bench, and there will be a single, three-quarter-inch conduit to the space above each ceiling for controls.

Option 9 $_______

j) Option 10

Provide electrified locksets and associated proximity card readers at all laboratory doors.

In addition to Doors C-B15, C-B16, C-B12, C-B17, C-B02, D-B09, D-B01, E-B07, E-B04, E-B05, E-B03, E-B06, E-B01, and B-305, electrified locksets and associated proximity card readers will be provided at all other laboratory doors.

Option 10 $______

k) Option 11

Provide electrified roller shades and associated wall-mounted controls at selected exterior windows.

Refer to Window Treatment Plans and Schedule for the windows that will have electrified roller shades in Option #11 and in the base bid.

The electrical component of this option includes a junction box above the ceiling for each motorized roller shade. A final connection from the junction box to each roller shade motor will be made in accordance with the manufacturer's specifications. Each connection will be in a concealed conduit and will be coordinated with the general contractor.

The roller shade control switch will be furnished by the general contractor and installed by the electrical subcontractor. Conduit and wire from the roller shade control switch to every motor will be provided, with the final connection made in accordance with the manufacturer's specifications.

DOCUMENT 00 41 00 Page 2

Switches will be located at the nearest entrance, 42 inches above the finish floor. There will be one 20A, 120V circuit from the nearest panelboard for each individual room.

Option 11 $______

l) Option 12: Not Used Option 12 $______

m) Option 13: Not Used Option 13 $______

n) Option 14

Clean by way of high-pressure water method, the existing masonry at each wall in the courtyard from the basement to the second floor levels.

Option 14 $_____

o) Option 15

Remove the existing terrazzo floor topping at the first floor level of Building 753 West to expose the existing slate and granolithic flooring units.

If removal of the terrazzo topping without damaging the existing slate and field stone beneath is not feasible, then new slate and field stone matching existing units will be provided, following removal of the existing terrazzo topping and slate/granolithic beneath.

Option 15 $______

p) Option 16: Not Used Option 16 $______

q) Option 17: Not Used Option 17 $______

r) Option 18

Provide a skid-mounted emergency power generator.

This option calls for an emergency power generator with a belly tank and a weatherproof enclosure, with a 100-gallon fuel overflow tank and a fuel oil transfer/fill box. Mechanical and electrical controls, wiring, valves, and surface-mounted piping above the roof will be in accordance with the plans and specifications.

Option 18 $______

s) Option 19

Provide one (1) copy in a CD media of updated Building Information Model (BIM) in Autodesk Revit Version 2008 and AutoCAD MEP 2009 (or a newer version of Revit / AutoCAD MEP), with BIM IFC two by three dimensional files. The as-built BIM will reflect field changes from the Final Design Submittal.

NOTE: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008/AutoCAD MEP 2009).

The contractor will be responsible for incorporating as-built data to reflect field changes from final design submittal and resubmitting the updated

DOCUMENT 00 41 00 Page 3 as-built BIM in digital format. The digital files will be provided to the government in both Revit/AutoCAD MEP model files and IFC files as one complete set in a CD/DVD media. As-built BIM requirements pertain to elements already modeled in final design BIM.

Option 19 $______

t) Option 20

Provide one (1) copy in a CD media of updated BIM in Autodesk Revit Version 2008 and AutoCAD MEP 2009 (or a newer version of Revit / AutoCAD MEP) with BIM IFC two by three dimensional files will be provided. The as-built BIM will contain Installed Manufacturer Information installed manufacturer information.

NOTE: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008 / AutoCAD MEP 2009).

The contractor will be responsible for incorporating as-built data to include installed manufacturer information; reflecting changes from final design submittal; and resubmitting the updated as-built BIM in digital format. This responsibility includes updating the BIM elements and related schedules to include installed manufacturer information. Manufacturer information shall include Manufacturer Name, Model, and Serial Number as applicable, based on elements already modeled in final design BIM including:

1) Architecture Models - Windows, doors and related hardware, reflected ceiling, manufactured casework, restroom partitions, and accessories.

(a) Restroom / kitchen fixtures: sinks, faucets, toilets.

(b) Shower equipment: Drinking fountains.

2) Mechanical Models - Scheduled equipment.

3) Plumbing Models - Scheduled equipment

4) Electrical - Power (generator/UPS/unit substation/transformers/ switchboards/overcurrent protection devices);

(a) Lighting (occupancy sensors/fixtures);

(b) Fire Alarm (entire system minus cabling - all devices and panels);

(c) Access Control (card readers / control pa/ power supplies / access control door hardware);

(d) Telecommunications (racks / patch panels / 110 blocks / jacks).

5) Fire Protection - Mains and standpipes two inches or greater.

6) Laboratory Equipment Models - Scheduled Equipment - Group I Equipment (Spec 11 53 00), piping valves, laboratory service fittings and emergency fixtures - custom built lab furnishings manufacturer.

The digital files will be provided to the government in both Revit / AutoCAD MEP model files and IFC files as one complete set in a CD / DVD media. As-built BIM requirements pertain to elements already modeled in the final design BIM.

Option 20 $______

DOCUMENT 00 41 00 Page 4

u) Option #21

Provide one (1) copy in a CD media of a completed as-built Construction Operations Building Information Exchange Spreadsheet (COBIE) spreadsheet will be provided in Microsoft Excel format.

NOTE: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008 / AutoCAD MEP 2009). The contractor will be responsible for incorporating as-built data relating to final design / construction identified in the COBIE spreadsheets for all required columns, including the optional data for each column as follows:

1) Contact Worksheet, Column 1

2) Design Worksheets, Columns 2, 3, 4, 5, 6, and 7

3) Installation Worksheets, Column 14 Contractor shall complete COBIE spreadsheets relating to final design/construction information by using Final Construction Set schedules and specs, O&M Manuals, shop drawings, as-built record drawings, as-built BIM schedules and manufacturer information as applicable. The COBIE spreadsheet shall be a Microsoft Excel spreadsheet as provided by:

4) http://www.wbdg.org/tools/cobiex.php.

Option 21 $______

1.1.2 Asbestos Removal

The Bidder shall include in his bid an allowance in the amount of $_________ to address unforeseen abatement of ACM above the ACM abatement identified on the Bidding Documents. The expenditure of this allowance shall be executed by the Contractor upon receipt of written concurrence from the Contracting Officer's Representative and based upon the following unit costs included in the Bidder's quote.

Asbestos Removal List

Item Description Unit Unit Rate

ASBESTOS REMOVAL

1 Decontamination Unit (Small Project) Each ____________

2 Decontamination Unit (Large Project) Each ____________

3 ASBESTOS FLOOR TILE COVERING THE BACKING/ADHESIVE

3a Floor Tile, Single Layer with Mastic S.F. ____________

DOCUMENT 00 41 00 Page 5

Asbestos Removal List

3b Floor Tile, each Additional S.F. ____________ Layer with Mastic

4 ASBESTOS THERMAL SYSTEM INSULATION (TENT & GLOVEBAG)

4a Asbestos Pipe Insulation Including L.F. ____________ Fittings, Joints, and Elbows

4b Up to and including 8" pipe insulation L.F. ____________ size O.D. (<260 LF)

4c Up to and including 8" pipe insulation L.F. ____________ size O.D. (>=260 LF)

4d Greater than 8" pipe insulation size L.F. ____________

O.D. (<160 LF)

4e Greater than 8" pipe insulation size L.F. ____________

O.D. (>=160 LF)

5 ASBESTOS CONTAINING ROOFING MATERIALS

5a Less than or equal to 3" thickness S.F. _____________ (including ballast) (<160 SF)

5b Less than or equal to 3" thickness S.F. _____________ (without ballast) (>=160 SF)

5c Each additional 1" thickness S.F _____________

5d Flashing S.F. _____________

5e Parapet Wall Caulking L.F. _____________

6 ASBESTOS CAULKING/GLAZING, SEALANT MATERIALS (EXCEPT WINDOWS)

6a Asbestos Cauling L.F. _____________

6b Asbestos Gaskets/Vibration Dampers S.F. ________

7 WINDOW

7a Window Unit with Asbestos Glazing S.F. _____________

7b Asbestos Caulking L.F. ______

7c Asbestos Glazing L.F. ____________

8 ELECTRICAL

8a Electrical Boxes Each ______________

DOCUMENT 00 41 00 Page 6

Asbestos Removal List

8b Asbestos Wire Insulation in Conduit L.F. ______________ (Based on length of Conduit)

8c Asbestos Braided Wire Insulation (Exposed) L.F. ______________

REPLACEMENT / INSTALLATION

9 PIPE INSULATION (FIBERGLASS 1") INCLDUING FITTINGS, JOINTS, & ELBOWS

9a Up to and including 4" pipe size O.D. L.F. _______________

9b Greater than 4" up to and including L.F. _______________ 8" pipe size O.D.

10 PIPE INSULATION (FIBERGLASS 3") INCLUDING FITTINGS, JOINTS, & ELBOWS

10a Greater than 8" up to and including L.F. _______________ 12" pipe size O.D.

10b Grater than 12" pipe size O.D. L.F. _______________

11 FLOOR TILE, BASE MOLDING AND MASTIC

11a Floor Tile and Mastic S.F. _______________

11b Base cove Molding and Mastic (Vinyl) L.F. _______________

12 ROOFING SYSTEM

12a Membrane Waterproofing S.F. _______________

12b Built-Up S.F. _______________

12c Adhered EPDM Roof S.F. _______________

13 MISCELLANEOUS

13a Window Glazing L.F. _______________

13b Window Caulking L.F. ______________

At the completion of the Project, any unused funds shall be addressed in a Deduct Construction Change Order.

-- End of Document --

DOCUMENT 00 41 00 Page 7

SECTION 00 80 00.00 18

SPECIAL CONTRACT REQUIREMENTS

NYD rev 10/08

PART 1 GENERAL

1.1 REFERENCES

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2008) Safety and Health Requirements Manual

1.2 DEFINITIONS

Placeholder Section - Replace with Section prepared by Jeff Friese in Word.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Submit the following in accordance with Section 01 33 00.00 18 SUBMITTAL PROCEDURES:

1.4 WARRANTY

1.5 MAINTENANCE

PART 2 PRODUCTS

2.1 MANUFACTURED UNITS

PART 3 EXECUTION

-- End of Section --

DOCUMENT 00 80 00.00 18 Page 1

SECTION 01 11 00

SUMMARY OF WORK

01/08

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes renovations of existing Science Center Building 757 and incidental related work.

1.1.2 Location

The work shall be located at the United States Military Academy at West Point, NY, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.2 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND FACILITIES

Obtain digging permits prior to start of excavation. Scan the construction site with electromagnetic or sonic equipment, and mark the surface of the ground where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

SECTION 01 11 00 Page 1

1.4.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work.

1.5 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged shall remain the property of the Government.

The salvaged property shall be segregated, itemized, delivered, and off-loaded at the Government designated storage area.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 2

SECTION 01 12 00.00 18

DESIGN AND RECORD DRAWING REQUIREMENTS

PART 1 GENERAL

1.1 GENERAL

All RECORD DRAWINGS (or "as-builts") to be provided under this contract shall be accomplished and developed using computer-aided design and drafting (CADD) software and procedures conforming to the following criteria.

Record Drawing Submission: The following options may be taken:

a. As-Built BIM (Option #19): Reflect Field Changes From Final Design Submittal.

1. One (1) copy in a CD media of updated Building Information Model (BIM) in Autodesk Revit Version 2008 and AutoCAD MEP 2009 (or a newer version of Revit / AutoCAD MEP), with BIM IFC two by three dimensional files. The as-built BIM will reflect field changes from the Final Design Submittal.

2. Note: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008 / AutoCAD MEP 2009). The contractor will be responsible for incorporating as-built data to reflect field changes from final design submittal and resubmitting the updated as-built BIM in digital format. The digital files will be provided to the government in both Revit / AutoCAD MEP model files and IFC files as one complete set in a CD / DVD media.

As-built BIM requirements pertain to elements already modeled in final design BIM.

b. As-Built BIM (Option #20): Installed Manufacturer Information

1. One (1) copy in a CD media of updated BIM in Autodesk Revit Version 2008 and AutoCAD MEP 2009 (or a newer version of Revit / AutoCAD MEP) with BIM IFC two by three dimensional files will be provided. The as-built BIM will contain installed manufacturer information.

2. Note: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008 / AutoCAD MEP 2009). The contractor will be responsible for incorporating as-built data to include installed manufacturer information; reflecting changes from final design submittal; and resubmitting the updated as-built BIM in digital format. This responsibility includes updating the BIM elements and related schedules to include installed manufacturer information. Manufacturer information shall include Manufacturer Name, Model, and Serial Number as applicable, based on elements already modeled in final design BIM including:

a) Architecture Models - Windows, doors and related hardware, reflected ceiling, manufactured casework, restroom partitions, and accessories.

b) Restroom / kitchen fixtures: sinks, faucets, toilets.

SECTION 01 12 00.00 18 Page 1

c) Shower equipment: Drinking fountains.

d) Mechanical Models - Scheduled equipment.

e) Plumbing Models - Scheduled equipment.

f) Electrical - Power (generator/UPS/unit substation/ transformers / switchboards / overcurrent protection devices);

g) Lighting (occupancy sensors / fixtures);

h) Fire Alarm (entire system minus cabling - all devices and panels);

i) Access Control (card readers / control panels / power supplies / access control door hardware);

j) Telecommunications (racks / patch panels / 110 blocks / jacks).

k) Fire Protection - Mains and standpipes two inches or greater.

l) Laboratory Equipment Models - Scheduled Equipment - Group I Equipment (Spec 11 53 00), piping valves, laboratory service fittings and emergency fixtures - custom built lab furnishings manufacturer.

3. The digital files will be provided to the government in both Revit / AutoCAD MEP model files and IFC files as one complete set in a CD / DVD media. As-built BIM requirements pertain to elements already modeled in the final design BIM.

c. As-Built COBIE (Option #21)

1. Provide one (1) copy in a CD media of a completed as-built Construction Operations Building Information Exchange Spreadsheet (COBIE) spreadsheet will be provided in Microsoft Excel format.

2. Note: The contractor will be given the final design and issued-for-construction set of AutoCAD drawings and BIM (Revit 2008 / AutoCAD MEP 2009). The contractor will be responsible for incorporating as-built data relating to final design / construction identified in the COBIE spreadsheets for all required columns, including the optional data for each column as follows:

a) Contact Worksheet, Column 1

b) Design Worksheets, Columns 2, 3, 4, 5, 6, and 7

c) Installation Worksheets, Column 14

3. Contractor shall complete COBIE spreadsheets relating to final design / construction information by using Final Construction Set schedules and specs, O&M Manuals, shop drawings, as-built record drawings, as-built BIM schedules and manufacturer information as applicable. The COBIE spreadsheet shall be a Microsoft Excel spreadsheet as provided by:

http://www.wbdg.org/tools/cobiex.php

SECTION 01 12 00.00 18 Page 2

1.2 GRAPHIC FORMAT

All CADD data shall be supplied in AutoCAD version 2006 native electronic digital format (i.e., .dwg). The contractor shall ensure that all digital files and data (e.g., model files, sheet files, reference files, cell libraries) are compatible with the Government's target CADD system (i.e., basic and advanced CADD software, platform, database software), and adhere to the standards and requirements specified herein. The term "compatible" means that data can be accessed directly by the target CADD system without translation, preprocessing, or postprocessing of the electronic digital data files. It is the responsibility of the contractor to ensure this level of compatibility.

1.3 CADD STANDARDS

CADD drawings shall be prepared in accordance with the "Architectural/ Engineering/Construction (A/E/C) Computer-Aided Design and Drafting (CADD) Standard, Release 3.0." standard drawing size shall be ANSI-D CADD drawings shall be prepared using inch-pound units.

All model files and sheet files shall include the following project code in their A/E/C CADD Standard file-name_.

The Contractor shall submit a written request for approval of any deviations from the Government's established A/E/C CADD standard. No deviations from the Government's established A/E/C CADD standard will be permitted unless prior written approval of such deviation has been received from the Government.

1.4 DELIVERY MEDIA AND FORMAT

All CADD data and files developed under this contract shall be delivered to the Government on electronic digital media as discussed at the pre-construction meeting or during progress meetings. The electronic digital data and files shall be provided on CD-ROM (compact disc, read only memory). Each CD-ROM shall be delivered to the Government in a separate container, commonly referred to as a "jewel box." The electronic digital media shall be in a format that can be read and processed by the Government's target CADD system.

Model files, sheet files, and other associated files shall not be device-dependent, nor shall the directory structure of the CD-ROM require any reconfiguration or other manipulation on the Government's part to view, print, and plot the files directly from the CD-ROM. The directory structure of the CD-ROM shall be configured such that a complete download of the CD-ROM's contents to an electronic folder on a Government computer's hard drive will not require any reconfiguration or other manipulation on the Government's part to view, print, and plot the files.

A portable document format (.pdf) file containing the set of full-sized plotted Sheet Files shall be included on each CD-ROM.

Each CD-ROM shall be labeled with a printed label and each printed CD-ROM label shall contain, as a minimum, the following information:

(1) The Project's Name, Contract Number (and Delivery Order Number if applicable), date, and version and/or submission number.

(2) The format and version of operating system software.

SECTION 01 12 00.00 18 Page 3

(3) The name of the preparer's firm and the name and phone number of the preparer's Point-of-Contact for the project.

(4) The name and office symbol of the Government's Point-of-Contact for the project.

(5) The sequence number of the digital media.

(6) A description of the contents of the CD-ROM (e.g., "Architectural Plans," etc.).

An .html file named README_ PROJECT NAME_.html containing the CD-ROM's labeling information indicated above as well as any other information as required shall be included on each CD-ROM.

The jewel box label for each CD-ROM shall be printed and each printed jewel box label shall contain, as a minimum, the following information:

(1) The Project's Name, Contract Number (and Delivery Order Number if applicable), date, and version and/or submission number.

(2) The name of the preparer's firm and the name and phone number of the preparer's Point-of-Contact for the project.

(3) The name and office symbol of the Government's Point-of-Contact for the project.

(4) The sequence number of the digital media.

(5) A description of the contents of the CD-ROM (e.g., "Architectural Plans," etc.).

(6) A tabular listing of all files on the CD-ROM.

(7) A chart clearly showing the directory structure of the CD-ROM.

(8) For multiple-CD-ROM packages, a tabular listing of all files in the package with clear indication of the total number of CD-ROMs in the package, and a listing of the contents of, as per item (5) above, of each of the CD-ROMs.

(9) A complete listing of the project's version and/or submission history.

1.5 DRAWING DEVELOPMENT DOCUMENTATION

The following information for each model file shall be included in the nonplot level, *-ANNO-NPLT:

(1) How the data were input (e.g., keyed in, downloaded from a survey total station instrument (include name and model)).

(2) Brief drawing development history (e.g., date started, modification date(s) with brief description of item(s) modified, author's name).

(3) The names of the reference files, cells, symbols, details, tables, and schedule files required for the finished drawing.

(4) Level assignments and lock settings.

SECTION 01 12 00.00 18 Page 4

(5) Text fonts, line styles used, and pen settings.

1.6 HARD COPY TRANSMITTALS

A transmittal letter shall accompany each electronic digital media submittal to the Government. The transmittal letter shall be dated and signed by the appropriate Contractor's representative. The transmittal letter shall be provided to the Government on 8-1/2-inch by 11-inch paper.

An electronic copy of the transmittal letter in .pdf format shall also be provided on the electronic digital media submitted to the Government. The transmittal letter shall contain, as a minimum, the following information:

(1) The information included on the external label of each CD-ROM, along with the total number being delivered, and a list of the names and descriptions of the files on each media unit.

(2) Brief instructions for transferring the files from the media.

(3) Certification that all delivery media are free of known computer viruses. A statement including the name(s) and release date(s) of the virus-scanning software used to analyze the delivery media, the date the virus scan was performed, and the operator's name shall also be included with the certification. The release or version date of the virus-scanning software shall be the current version which has detected the latest known viruses at the time of delivery of the digital media.

(4) A statement indicating that the A-E will retain a copy of all delivered electronic digital media (with all files included) for at least one year and, during this period of time, will provide up to 2 additional copies of each to the Government, if requested, at no additional cost.

In addition, the Contractor shall provide the following "Plot File Development and Project Documentation Information" as an enclosure or attachment to the transmittal letter provided with each electronic digital media submittal. The "Plot file Development and Project Documentation Information" shall be provided to the Government on 8-1/2-inch by 11-inch paper. An electronic copy of this information in .pdf format shall also be provided on the electronic digital media submitted to the Government.

(1) Documentation of the plot file for each drawing which will be needed to be able to duplicate the creation of the plot file by the Government at a later date. This documentation shall include the plotter configuration (e.g., name and model of plotter), pen settings, drawing orientation, drawing size, and any other special instructions.

(2) Instructions concerning how to generate plotted, or hard copy, drawings from the provided plot files.

(3) List of any deviations from the Government's standard level scheme and file-naming conventions and a copy of the Government's signed and dated approval letter allowing these exact deviations from the A/E/C CADD Standards.

(4) List of all new symbol cells created for the project, which were not provided to the Contractor with the Government-furnished materials.

(5) List of all new figures, symbols, tables, schedules, details, and other cells created for the project, which were not provided to the Contractor

SECTION 01 12 00.00 18 Page 5 with the Government-furnished materials, and any associated properties.

(6) List of all database files associated with each drawing, as well as a description and documentation of the database format and schema design.

(7) Recommended modifications which will be necessary to make the data available for GIS use.

The Contractor shall also provide paper copies of drawings as indicated in the paragraph entitled "Record Drawings" in Section 00 80 00.00 18 SPECIAL

CONTRACT REQUIREMENTS.

1.7 OWNERSHIP

The Government, for itself and such others as it deems appropriate, will have unlimited rights under this contract to all information and materials developed under this contract and furnished to the Government and documentation thereof, reports, and listings, and all other items pertaining to the work and services pursuant to this agreement including any copyright. Unlimited rights under this contract are rights to use, duplicate, or disclose text, data, drawings, and information, in whole or in part in any manner and for any purpose whatsoever without compensation to or approval from the Contractor. The Government will at all reasonable times have the right to inspect the work and will have access to and the right to make copies of the above-mentioned items. All text, electronic digital files, data, and other products generated under this contract shall become the property of the Government. By reference, the following DFAR clauses are included in this contract as a part of the requirements herein:

a. DFAR 252.227-7013, "Rights in Technical Data - Noncommercial Items."

b. DFAR 252.227-7017, "Identification and Assertion of Use, Release, or Disclosure Restrictions."

c. DFAR 252.227-7020, "Rights in Special Works."

d. DFAR 252.227-7028, "Technical Data or Computer Software Previously Delivered to the Government."

e. DFAR 252.227-7037, "Validation of Restrictive Markings on Technical Data."

f. DFAR 252.227-7025, "Limitations on the Use or Disclosure of Government-Furnished Information Marked with Restrictive Legends."

g. DFAR 252.227-7014, "Rights in Noncommercial Computer Software and Noncommercial Computer Software Documentation."

1.8 GOVERNMENT-FURNISHED MATERIALS

1. Electronic (.pdf) copy of latest version of A/E/C CADD Standard.

2. Model files containing the project files and the Government's standard border sheets.

PART 2 PRODUCTS

Not Used.

SECTION 01 12 00.00 18 Page 6

PART 3 EXECUTION

Not Used.

-- End of Section --

SECTION 01 12 00.00 18 Page 7

SECTION 01 20 00.00 20

PRICE AND PAYMENT PROCEDURES

07/06

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP-1110-1-8 (2005) Construction Equipment Ownership and Operating Expense Schedule, Vol 1-12

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00.00 18 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Schedule of prices; G

1.3 SCHEDULE OF PRICES

1.3.1 Data Required

Within 15 calendar days of notice of award, prepare and deliver to the Contracting Officer a schedule of prices (construction contract) on the forms furnished by the Government. Provide a detailed breakdown of the contract price, giving quantities for each of the various kinds of work, unit prices, and extended prices therefor.

1.3.2 Schedule Instructions

Payments will not be made until the Schedule of Prices has been submitted to and accepted by the Contracting Officer. Identify the cost for site work, and include incidental work to the 5 foot line. Identify costs for the building(s), and include work out to the 5 foot line. Work out to the 5 foot line shall include construction encompassed within a theoretical line 5 feet from the face of exterior walls and shall include attendant construction, such as cooling towers, placed beyond the 5 foot line.

1.3.3 Schedule Requirements for HVAC TAB

The field work Section 23 05 93, HVAC TESTING/ADJUSTING/BALANCING FOR HVAC shall be broken down in the Schedule of Prices and in the Construction Progress Documentation by separate line items which reflect measurable deliverables. Specific payment percentages for each line item shall be determined on a case by case basis for each contract. The line items shall be as follows:

SECTION 01 20 00.00 20 Page 1

a. Approval of Design Review Report: The TABS Agency is required to conduct a review of the project plans and specifications to identify any feature, or the lack thereof, that would preclude successful testing and balancing of the project HVAC systems. The resulting findings shall be submitted to the Government to allow correction of the design. The progress payment shall be issued after review and approval of the report.

b. Approval of the pre-field engineering report: The TABS Agency submits a report which outlines the scope of field work. The report shall contain details of what systems will be tested, procedures to be used, sample report forms for reporting test results and a quality control checklist of work items that must be completed before TABS field work commences.

c. Season I field work: Incremental payments are issued as the TABS field work progresses. The TABS Agency mobilizes to the project site and executes the field work as outlined in the pre-field engineering report. The HVAC water and air systems are balanced and operational data shall be collected for one seasonal condition (either summer or winter depending on project timing).

d. Approval of Season I report: On completion of the Season I field work, the data is compiled into a report and submitted to the Government. The report is reviewed, and approved, after ensuring compliance with the pre-field engineering report scope of work.

e. Completion of Season I field QA check: Contract QC and Government representatives meet the TABS Agency at the jobsite to retest portions of the systems reported in the Season I report. The purpose of these tests are to validate the accuracy and completeness of the previously submitted Season I report.

f. Approval of Season II report: The TABS Agency completes all Season II field work, which is normally comprised mainly of taking heat transfer temperature readings, in the season opposite of that under which Season I performance data was compiled. This data shall be compiled into a report and submitted to the Government.

On completion of submittal review to ensure compliance with the pre-field engineering report scope, progress payment is issued.

Progress payment is less than that issued for the Season I report since most of the water and air balancing work effort is completed under Season I.

1.4 CONTRACT MODIFICATIONS

In conjunction with the Contract Clause "DFARS 252.236-7000, Modification Proposals-Price Breakdown," and where actual ownership and operating costs of construction equipment cannot be determined from Contractor accounting records, equipment use rates shall be based upon the applicable provisions of the EP-1110-1-8.

1.5 PAYMENTS TO THE CONTRACTOR

Payments will be made on submission of itemized requests by the Contractor which comply with the requirements of this section, and will be subject to reduction for overpayments or increase for underpayments made on previous payments to the Contractor.

SECTION 01 20 00.00 20 Page 2

1.5.1 Obligation of Government Payments

The obligation of the Government to make payments required under the provisions of this contract will, at the discretion of the Contracting Officer, be subject to reductions and/or suspensions permitted under the FAR and agency regulations including the following in accordance with "FAR 32.503-6:

a. Reasonable deductions due to defects in material or workmanship;

b. Claims which the Government may have against the Contractor under or in connection with this contract;

c. Unless otherwise adjusted, repayment to the Government upon demand for overpayments made to the Contractor; and

d. Failure to provide up to date record drawings not current as stated in Contract Clause "FAC 5252.236-9310, Record Drawings."

1.5.2 Payment for Materials Offsite

Payments may be made to the Contractor for materials stored off construction sites under the following conditions:

a. Conditions described in the paragraph entitled "Payments to the Contractor";

b. Material within a distance of 50 miles by streets and roads to the construction site;

c. Materials adequately insured and protected from theft and exposure;

d. Materials not susceptible to deterioration or physical damage in storage or in transit to the job site are acceptable for progress payments. Items such as steel, machinery, pipe and fittings, precast/prestressed concrete piles, and electrical cable are acceptable; items such as gypsum wallboard, glass, insulation, and wall coverings are not;

e. Materials in transit to the job site or storage site are not acceptable for payment; and

f. Conditions specified in "FAR 52.232-5(b) Payments Under Fixed Price Construction Contracts."

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 20 00.00 20 Page 3

SECTION 01 23 13

OPTIONS

03/09

PART 1 GENERAL

1.1 SUMMARY

Section includes administrative and procedural requirements for Options.

1.2 DEFINITIONS

"Option" means a unilateral right in a contract by which, for a specified time, the Government may elect to purchase additional supplies or services called by the contract, or may elect to extend the term of the Contract.

Notice To Proceed of individual options as noted below shall not affect the Completion Date of the base Contract as determined by the base Contract Notice to Proceed.

1.3 GENERAL

The extent of work for each Option is indicated on the drawings. In the event of any differences between the drawings and the Options described below, the descriptions below shall govern.

1.4 COORDINATION

The Contractor shall coordinate related work and modify or adjust adjacent work as necessary to ensure that work affected by each exercised Option is complete and fully integrated into the project. The Contractor shall provide appropriate detailing to properly terminate or transition from Option to base bid work and Option to Option work. The Contracting Officer will review and approve in writing any and all Contractor generated documents. The Contracting Officer will review and approve in writing any and all Contractor generated documents.

1.5 SCHEDULE

A "SCHEDULE OF OPTIONS" is included as part of this section. Drawings referenced in the schedule contain requirements for materials and methods necessary to achieve the work described under each Option.

Include as part of each Option, miscellaneous devices, accessory objects and similar items incidental to or required for a complete installation whether or not mentioned as part of the Option.

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION

3.1 SCHEDULE OF OPTIONS

3.1.1 OPTION NO. 1: HEAT RECOVERY SYSTEM

Furnish and install heat recovery system, and associated testing, balancing, and commissioning in accordance with the plans and specifications.

SECTION 01 23 13 Page 1

Specifically, refer to Mechanical Drawings M-209, M-301, M-407, M-409, M-504, M-507, M-508 and M-603, and specification Section 23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS for information and details related to the Energy Recovery System.

3.1.2 OPTION NO. 2: SCREEN WALLS

Furnish and install the screen walls in accordance with the plans and specifications.

Specifically, install the screen walls at the roof top level of the lower fifth floor Mechanical Room #A-502, as shown on the following Drawings: A-109.1 (Coded note #5), A-206, A-523 (Details B1, C1, and C3), A-528 (Details C3 and C5), A-529 (Detail C4), S-110 (Detail 3), S-111 (Detail 3), and other related reference details. The screen wall shall be constructed of structural steel framing, reinforced CMU back-up, granite veneer, and precast concrete trim units as detailed.

3.1.3 OPTION NO. 3: WINDOW TREATMENTS

Furnish and install motorized rolling shades at selected windows in accordance with the plans and specifications, but excluding all work associated with furnishing and installing window blinds and shades included in the base bid.

Specifically, replace the manual horizontal window blinds with motorized roller shades at all windows scheduled to receive window blinds on the following Drawings: A103.9, A-104.9, A-105.9, A-106.9 and A-641. Note that only rooms A-204 (Sheet A-104.9) and A-407 (Sheet A-106.9) receive motorized roller shades in the base bid. Other scheduled exterior openings shall receive manual horizontal window blinds in the base bid.