W50S84-22-B-0008-0001.pdf

MBMV222321

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is to update FAR Caluse 52.211-12 Liquidated Damages amount to $704.67

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 30-Aug-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W50S8422B0008

X 9B. DATED (SEE ITEM 11)

10-Aug-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

30-Aug-2022

CODE

USPFO MI 110 MISSION SUPPORT CONTRACTING

50 SABER ST

BATTLE CREEK MI 49015-5515

W50S84 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W50S8422B0008

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00100 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

The following have been modified:

SECTION 00100

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. Instructions to Bidders:

1.1 You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled) W50S84-22-B-0008 entitled: Project#: MBMV212809, Repair Emergency Power

1.2 As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price. This solicitation is set-aside 100% for small businesses.

1.3 Facsimile transmission of a bid is not authorized. Electronic submission of bids will not be accepted. Bids must be hand carried to the bid opening or mailed to:

110 MISSION SUPPORT CONTRACTING

150 LIGHTNING AVE

BATTLE CREEK ANGB

MI 49037

Subject: W50S84-22-B-0008 Project#: MBMV212809, Repair Emergency Power

2. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

2.1 A pre-bid conference will be conducted on 17 August 2022 at 2:00 PM local time for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at 110 Civil Engineering Squadron, 150 Canberra Street, Bldg 7020, Battle Creek, MI 49037.

Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit at the job site will be held following the conference.

2.2 Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to Michael Kitchell at the following addresses:

Site Visit - Points of Contact (POC) Taylor Jamieson AND Major Robert Loniewsky Address: jamieson.taylor@us.af.mil / robert.loniewsky.2@us.af.mil Telephone: (269) 969-3347 / (269) 969-3363

Courtesy copy: michael.kitchell.1@us.af.mil

Battle Creek ANGB “Pre-Authorization Access Request List” must be completed and received by Major Robert Robert Loniewsky, and Mr. Jamieson Taylor 3 business days prior to the Scheduled Site Visit. Please see the Solicitation. The pre access list is found on www.sam.gov.SAM.gov Attachments within www.sam.gov OR email the POC’s below to retrieve the “Base Access Request Form” and “Access Form Directions” files.

Be aware that the following information will be needed to fill out the “Base Access Request Form”:

Last Name, First Name, Middle Name Sr/Jr:

Date of Birth:

Driver’s License # or State / Federal ID #:

State of Issue:

Gender:

Race:

Nationality:

Company:

Foreign Visitors: Must reach out for further guidance / information.

Firm Name and Telephone Number Visitor’s Name and Social Security No.

Drivers License Citizenship

2.3 This information must be provided on the INCLUDED BASE ACCESS FORM in advance, 3 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.4 Visitors must pick up their passes at the Installation’s Main Entry Gate prior to arrival. You will be required to present the following information upon arrival: (1) Vehicle Registration, (2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Safety Inspection and Car Rental agreement if applicable.

Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.5 Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.6 A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.sam.gov The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

3.1 Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W50S84-22-B-0008 MBMV212809, Repair Emergency Power

Email: michael.kitchell.1@us.af.mil

127WG.MSC.ConstructionOrg@us.af.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

3.2 Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

3.3 All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to bid opening. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS

EARLY IN THIS PROCESS.

3.4 Any changes to the drawings, specifications, etc. will be issued in the form of an amendment. However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on www.sam.gov at http://www.sam.gov.

3.5 Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

3.6 For security reasons, all technical and engineering data related to this solicitation will be distributed using the Contract Opportunities (www.sam.gov) system. Plans and specifications are locked on www.sam.gov and require Contractors to request explicit access from the Contracting Officer OR export controlled access through DLA. See complete instructions on www.sam.gov. www.sam.gov is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with www.sam.gov before accessing the system.

3.6.1 Amendments, if/when issued will be posted to http://www.sam.gov for electronic downloading. This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation.

Websites are occasionally inaccessible due to various reasons.

4. BID REPOSITORY AND BID OPENING:

4.1 A bid repository is provided for hand carried bids and is located at. Bldg. 6913 110 MISSION SUPPORT CONTRACTING 150 LIGHTNING AVE BATTLE CREEK ANGB MI 49037. Hand carried bids must be deposited in the repository prior to the time established for opening of bids. Bidders are cautioned that they will be required to sign-in and obtain a visitor’s pass to enter the facility and should allow time to accomplish this. See instructions for obtain access to the base in the Site Visit instruction. However, the Battle Creek ANGB Base Access form must be used for access to Battle Creek Air National Guard Base.

Follow the same instruction for obtaining entry to hand carry bid. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with

FAR 14.304.

4.2 The bid opening will occur at the time and date specified in Block 13 of the SF1442 at insert Bldg. 6913

110 MISSION SUPPORT CONTRACTING 150 LIGHTNING AVE BATTLE CREEK ANGB MI 49037.

All interested offerors and their major subcontractors are encouraged to attend the bid opening.

5. WAGE DETERMINATION:

5.1 Construction Wage Rates are applicable to this project are Building - MI20200079 08/5/2022 as shown in Section 00800.

6. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS: This IFB does not commit the

Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

7. CLAUSES:

7.1 Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

8. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bond.

9. OFFERORS QUALIFICATIONS:

9.1 To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

10. Brand Name/Sole Source Justification Requirements: N/A

END SECTION 00100

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $704.67 for each calendar day of delay until the work is completed or accepted. There is also a one-time charge of $153.00 for legal services that will apply.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)