Solicitation W912WJ26RA003.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section 00 00 00 - Procurement and Contracting Requirements

Cape Cod Space Force Station Power Generation Microgrid

BIDDING SCHEDULE

Item No. Description Quantity Unit Amount

0001 Power Generation Microgrid 1 Job $______________

0002 HEMP Shielding Improvements 1 Job $______________

0003 Uninterruptible Power Supplies Systems with Bypass 1 Job $______________

0004 Facility Security Improvements 1 Job $______________

TOTAL AMOUNT $____________________

NOTE 1: Offerors must submit an amount for all Item Nos. The work will be awarded as a whole to one offeror. Offers will be evaluated, and the Best Value to the Government will be awarded.

NOTE 2: All work shall be completed within the time period specified in the Contract documents.

NOTE 3: The point of contact e-mail for all correspondence related to this solicitation: tyler.s.maryak@usace.army.mil.

: FAR Clause 52.222-34 - Project Labor Agreement is applicable to this solicitation and award.NOTE 4

W912WJ26RA003

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Section 00 21 00 - Instructions

Submission requirements (including proposal submission requirements) and evaluation approach (including basis for award and evaluation criteria) are included as an attachment to the solicitation.

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-7 System for Award Management. Nov 2024 52.204-16 Commercial and Government Entity Code Reporting. Aug 2020 52.204-22 Alternative Line Item Proposal. Jan 2017 52.211-6 Brand Name or Equal. Aug 1999 52.215-1 Instructions to Offerors-Competitive Acquisition. Nov 2021 52.215-22 Limitations on Pass-Through Charges-Identification of Subcontract Effort. Oct 2009 52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. May 2014 52.225-12 Notice of Buy American Requirement-Construction Materials Under Trade Agreements. May 2014

FAR Clauses Incorporated by Full Text

52.211-14 Notice of Priority Rating for National Defense, Emergency Preparedness, and Energy Program Use.

(Apr 2008)

Notice of Priority Rating for National Defense, Emergency Preparedness, and Energy Program Use (Apr 2008)

Any contract awarded as a result of this solicitation will be ____ DX rated order; _ _ DO rated order certified for national defense, emergency X preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR700), and the Contractor will be required to follow all of the requirements of this regulation.

(End of provision)

52.216-1 Type of Contract. (Apr 1984)

Type of Contract (Apr 1984)

The Government contemplates award of a contract resulting from this solicitation.FIRM FIXED PRICE

(End of provision)

52.228-1 Bid Guarantee. (Sep 1996)

Bid Guarantee (Sept 1996)

Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.(a)

The bidder shall furnish a bid guarantee in the form of a firm commitment, bid bond supported by good and sufficient surety or sureties (b) e.g., acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

To unsuccessful bidders as soon as practicable after the opening of bids; and(1)

To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as (2) required by the bid as accepted.

The amount of the bid guarantee shall be percent of the bid price or $ , whichever is less.(c) TWENTY (20%) 3,000,000

If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual (d) documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

1.

2.

3.

4.

5.

6.

In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the (e) bid guarantee is available to offset the difference.

(End of clause)

52.233-2 Service of Protest. (Sep 2006)

Service of Protest (Sept 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that (a) are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

ATTN: Contracting Officer US Army Corps of Engineers, New England District 696 Virginia Road Concord, MA 01742

The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.(b)

(End of provision)

52.236-27 Site Visit (Construction). (Alternate I) (Feb 1995) Alternate I (Feb 1995)

a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-

08 January 2026 at 9:00 AM ET 15 January 2026 at 9:00 AM ET

(c) Participants will meet at-

Cape Cod Space Force Station (see directions below)

All pre-bid visits will be held on 08 January 2026 and 15 January 2026 from 9:00 AM to 2:00 PM ET. Each interested offeror is allowed a maximum of 6 personnel to attend and is only permitted to enter the Restricted Area (RA) during your assigned time.

Carpooling is strongly advised. Each offeror is permitted to drive up to 2 vehicles past the security check point. Each assigned time will allow for 60 minutes of escorted access within RA. All personnel attending the pre-bid site visit must provide the required information to Tyler.S.Maryak@usace.army.mil by COB 02 January 2026. USACE will notify firms of their assigned date and time of pre-bid site visit once all required information has been received.

Compile all personnel info in a single email with "PII - CCSFS Pre-Bid Visit" included in subject line.

First, Last, MI Date of Birth Last 4 of SSN Drivers License Number/State of Issue

Arrival Instructions:

GPS Address is 1 Factory Outlet Rd., Bourne, MA Must present a valid form of identification.

Check in at the security checkpoint; a Security Forces team member will verify identification with provided information.

Proceed up the hill to the base (1/4 mile) Park vehicle in the designated parking area Proceed to a USACE representative to check-in

W912WJ26RA003

https://www.acquisition.gov/far/part-52#FAR_52_236_2 https://www.acquisition.gov/far/part-52#FAR_52_236_3 mailto:Tyler.S.Maryak@usace.army.mil

1.

2.

3.

4.

Site Restrictions During Pre-Bid Site Visit:

No photography is permitted.

Do not park in any undesignated areas or block thru traffic.

No congregating in areas except in/around Light House Building (Gazebo area is OK).

Limited availability of restrooms on base.

Offerors shall comply with the requirements set forth in the attached Site Security Requirements and provide the information requested on the Visitor Request Sheet for the members of the Offeror's party.

52.252-1 Solicitation Provisions Incorporated by Reference. (Feb 1998)

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

(End of provision)

52.252-5 Authorized Deviations in Provisions. (Nov 2020)

Authorized Deviations in Provisions (Nov 2020)

The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the (a) addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any DFARS (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements. Nov 2023 252.204-7024 Notice on the Use of the Supplier Performance Risk System. Mar 2023

252.209-7008 Notice of Prohibition Relating to Organizational Conflict of Interest-Major Defense Acquisition Program.

Dec 2010

252.215-7009 Proposal Adequacy Checklist. Mar 2023 252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors. Jan 2023 252.215-7016 Notification to Offerors-Postaward Debriefings. Oct 2025

DFARS Clauses Incorporated by Full Text

252.215-7008 Only One Offer. (Dec 2022)

ONLY ONE OFFER (DEC 2022)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable (10 U.S.C. 3705) or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 3702 and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.S. Contracting Officer that the proposed price is fair and reasonable ____[U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

(End of provision)

Section 00 22 00 - Supplementary Instructions

Technical inquiries and questions relating to this solicitation are to be submitted via "Bidder Inquiry" in ProjNet at ( ) No Later Than (NLT) . To submit and review https://www.projnet.org 1:00 PM ET on 04 February 2026 inquiring items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment/question will receive acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

BIDDER INQUIRY KEY: 3PBVYC-J2Y24R

Specific Instructions for Initial ProjNet Bid Inquiry Access:

1. From the ProjNet home page, click on "Quick Add" on the upper right side of the screen.

2. Identify the Agency as USACE.

3. Key - Enter the Bidder Inquiry Key listed above.

4. Email - Enter the email address you would like to use for communication.

5. Click "Continue." A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click "Add User." Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access:

Steps 1 through 3: Same as Above.

4. Enter the email address you used to register previously in ProjNet.

5. Click "Continue." A page will then open asking for the answer to your Secret Question.

6. Enter your Secret Answer and click "Login." Once this is completed, you are logged into the system.

W912WJ26RA003

https://www.projnet.org

Section 00 45 00 - Representations and Certifications

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.209-7 Information Regarding Responsibility Matters. Oct 2018 52.209-13 Violation of Arms Control Treaties or Agreements-Certification. Nov 2021

FAR Clauses Incorporated by Full Text

52.204-29 Federal Acquisition Supply Chain Security Act Orders-Representation and Disclosures. (Dec 2023)

Federal Acquisition Supply Chain Security Act Orders-Representation and Disclosures (Dec 2023)

(a) Definitions. As used in this provision, Covered article, FASCSA order, Intelligence community, National security system, Reasonable inquiry, Sensitive compartmented information, Sensitive compartmented information system, and Source have the meaning provided in the clause 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition.

(b) Prohibition. Contractors are prohibited from providing or using as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the prohibition is set out in an applicable Federal Acquisition Supply Chain Security Act (FASCSA) order, as described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition.

(c) Procedures.

(1) The Offeror shall search for the phrase "FASCSA order" in the System for Award Management (SAM)( https://www.sam.gov) for any covered article, or any products or services produced or provided by a source, if there is an applicable FASCSA order described in paragraph (b)(1) of FAR 52.204-30, Federal Acquisition Supply Chain Security Act Orders-Prohibition.

(2) The Offeror shall review the solicitation for any FASCSA orders that are not in SAM, but are effective and do apply to the solicitation and resultant contract (see FAR 4.2303(c)(2)).

(3) FASCSA orders issued after the date of solicitation do not apply unless added by an amendment to the solicitation.

(d) Representation. By submission of this offer, the offeror represents that it has conducted a reasonable inquiry, and that the offeror does not propose to provide or use in response to this solicitation any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA order in effect on the date the solicitation was issued, except as waived by the solicitation, or as disclosed in paragraph (e).

(e) Disclosures. The purpose for this disclosure is so the Government may decide whether to issue a waiver. For any covered article, or any products or services produced or provided by a source, if the covered article or the source is subject to an applicable FASCSA order, and the Offeror is unable to represent compliance, then the Offeror shall provide the following information as part of the offer:

(1) Name of the product or service provided to the Government;

(2) Name of the covered article or source subject to a FASCSA order;

(3) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied the covered article or the product or service to the Offeror;

(4) Brand;

(5) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(6) Item description;

(7) Reason why the applicable covered article or the product or service is being provided or used;

(f) Executive agency review of disclosures. The contracting officer will review disclosures provided in paragraph (e) to determine if any waiver may be sought. A contracting officer may choose not to pursue a waiver for covered articles or sources otherwise subject to a FASCSA order and may instead make an award to an offeror that does not require a waiver.

(End of provision)

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials. Sep 2022 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. Oct 2016

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation.

May 2021

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

Jun 2023

DFARS Clauses Incorporated by Full Text

252.204-7007 Alternate A, Annual Representations and Certifications. (Oct 2024) Alternate A (Oct 2024)

ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2024)

Substitute the following paragraphs (b), (d), and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (e) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) Paragraph (e) applies.

(ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation. Applies to all solicitations.

(ii) 252.216-7008, Economic Price Adjustment-Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services-Representations. Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)-Representation. Applies to solicitations and contracts when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)-Representation. Applies to solicitations and contracts when contract performance will be in Spain.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

(ii) 252.225-7000, Buy American-Balance of Payments Program Certificate.

(iii) 252.225-7020, Trade Agreements Certificate.

Use with Alternate I.

(iv) 252.225-7031, Secondary Arab Boycott of Israel.

(v) 252.225-7035, Buy American-Free Trade Agreements-Balance of Payments Program Certificate.

Use with Alternate I.

Use with Alternate II.

Use with Alternate III.

Use with Alternate IV.

Use with Alternate V.

(vi) 252.226-7002, Representation for Demonstration Project for Contractors Employing Persons with Disabilities.

(vii) 252.232-7015, Performance-Based Payments-Representation.

(e) The Offeror has completed the annual representations and certifications electronically via the SAM website at . After https://www.sam.gov reviewing the SAM database information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below . These amended representation(s) and/or [ ]Offeror to insert changes, identifying change by provision number, title, date certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Provision # Title Date Change

Any changes provided by the Offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

Section 00 70 00 - Conditions of the Contract

CONTRACTOR COMPLIANCE WITH THE CYBERSECURITY MATURITY MODEL CERTIFICATION (CMMC) LEVEL REQUIREMENT

Offerors are required to obtain Level 2 CMMC certification prior to award. Per Defense Federal Acquisition Regulation Supplement (DFARS) Case 2019-D041 Final Rule, published 10 September 2025, and in accordance with DFARS 252.204-7021, Offerors must have the CMMC level required by the solicitation to be eligible for award, as determined by the needs of the acquisition. (See https://dodcio.defense.gov/cmmc /About/ for more information.)

Level 2 self-assessments and contracted third party assessing officials (C3PAO) are applicable to new solicitations containing controlled unclassified information (CUI) without national security implications. As such, Offerors shall obtain Level 2 CMMC certification prior to award in order to be eligible for award. The certification will be verified through Supplier Performance Risk System (SPRS). Offeror compliance with CMMC certification requirements will be determined as part of the Government's responsibility determination prior to contract award. If the apparent awardee is not compliant within a reasonable time, the Government will determine the offeror non-responsible.

PROJECT LABOR AGREEMENTS

Offerors shall submit Project Labor Agreements (PLAs) in accordance with FAR 52.222-34 and FAR 22.504(b).

Incomplete, non-binding, or unsigned agreements will not be accepted. Proposals that lack PLAs or provide PLAs that are not compliant with FAR Subpart 22.5 will be ineligible for award.

52.236-4004 INSURANCE REQUIRED

In accordance with CONTRACT CLAUSE titled "INSURANCE - WORK ON A GOVERNMENT INSTALLATION" the Contractor shall procure and maintain during the entire period of his performance under this contract the following kinds and minimum amounts of insurance:

TYPE AMOUNT

Workmen's Compensation and Employers' Liability Insurance

The Contractor shall comply with all applicable Workmen's Compensation Statutes and shall furnish evidence of Employers' Liability Insurance.

Not less than $100,000

General Liability Insurance

Bodily injury liability insurance on the comprehensive form of policy.

Minimum limits of $500,000 per accident

Automobile Liability Insurance

Damage liability insurance on the comprehensive form of policy and shall cover the operation of all automobiles used in performance of the contract.

Minimum limits of:

$200,000 per person and $500,000 per accident

$20,000 per accident for property damage

W912WJ26RA003

https://dodcio.defense.gov/cmmc/About/ https://dodcio.defense.gov/cmmc/About/

AT-OPSEC

General Security Requirements and Guidance (DoD Components Only) The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). The Department of Defense (DoD) and Service-specific security requirements specified below, if applicable, are performance requirements. All contract personnel shall complete applicable initial training within 30 days of contract award, or the date new contract personnel begin performance on the contract. The Contractor shall maintain security training records in accordance with applicable RA policies.

Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated security in accordance with applicable RA plans and procedures - this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

General Security Requirements and Guidance (Other Federal Agencies) The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with all security requirements and any others promulgated by the Requiring Activity (RA). Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), RA representative, or Contracting Officer (if a COR or other RA representative is not appointed)). In circumstances where access to a DoD installation or facility is necessary to meet contract performance requirements, contractor personnel shall comply with that agency's security requirements (e.g., access control procedures, etc.). Contractor personnel entering federal buildings and non-DoD installations shall follow applicable access control procedures and are subject to search in accordance with Interagency Security Committee (ISC) regulations.

Physical Security and Access Control Requirements (DoD Components Only) All contract personnel requiring physical access to a DoD installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access on a DoD installation in the US to meet contract performance requirements shall be vetted by the installation/facility Provost Marshal /Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to DoD-owned facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA. Reference: DoDM 5200.08, Volume 3, "Physical Security Program: Access to DoD Installations."

Training Requirements for the Protection of Sensitive Information (DoD Components Only) All contract personnel with access to critical information (as identified in the RA's Operations Security (OPSEC) Program) shall complete initial and annual refresher OPSEC Level I Awareness training, which is available at the following websites: https://www.iad.gov/ioss/, or http://www.cdse.edu/catalog/operations-security.html (websites subject to change). Reference (DoD Only): DoDM 5205.02, "DoD Operations Security (OPSEC) Program Manual." All contract personnel with access to Controlled Unclassified Information shall complete training in accordance with applicable DoD or other federal agency policy. Reference (DoD Only):

DoDD 5200.48, "Controlled Unclassified Information (CUI)."

Contract Personnel Requiring Access to Government Information Systems Contractor personnel shall be granted access to DoD or other Federal agency government information systems only when required to meet contract performance requirements. For DoD contracts, contract personnel shall complete DoD Information Assurance Awareness training prior to accessing information systems, and annually thereafter. For other federal agency contracts, contract personnel shall comply with applicable agency policies.

Escorting in Classified and/or Sensitive Areas In accordance with RA policies and procedures, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or other restricted areas.

Pre-Screen Candidates Using E-Verify Program Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the RA's COR or similar point of contact no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

CONTRACTOR EVALUATION

CONTRACTOR PERFORMANCE EVALUATIONS (CPARS)

In accordance with the provisions of Subpart 36.20 l (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction Contractor's performance shall be evaluated throughout the performance of the contract.

The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $900,000.00, the USACE will evaluate contractor's performance annually and at completion and prepare a performance report using the Contractor Performance Assessment Reporting System (CP ARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the Contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. Accessing and using CP ARS typically requires specific software, called PK.I certification, which is installed on the user's computer.

However, although users are encouraged to use PK.I certificates whenever possible, a waiver has been approved to allow industry users to access the system without a PK.I certificate.

Contractors wishing to log on without a PK.I certificate should select the "Contractor (pending PK.I)" logon option. The certification is a Department of Defense item and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PK.I certification process and for http://www.cpars.gov/.contacting vendors can be found on the web site: lf the Contractor wishes to participate in the performance evaluation process, access to CP ARS and PK.I certification is the sole responsibility of the Contractor.

WEATHER DELAYS

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled "DEFAULT (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY (WORK DAYS BASED ON 5 DAY WORK WEEK)

JANUARY FEBRUARY MARCH APRIL MAY JUNE

9 7 5 3 1 1

JULY AUGUST SEPTEMBER OCTOBER NOVEMBER DECEMBER

1 1 1 2 5 7

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a DEFAULT (FIXED PRICE CONSTRUCTION)."

VETERANS EMPLOYMENT INFO

Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.22238, FAR Clause 52.22235, FAR Clause 52.22237, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

-U.S. Department of Labor Veterans' Employment and Training Service (VETS): https://www.dol.gov/vets/

-Federal Veteran Employment Information: https://www.fedshirevets.gov/

-Veterans Opportunity to Work (VOW) Program: https://www.benefits.va.gov/vow/

-U.S. Army Warrior Transition Command Employment Index: https://wct.army.mil/modules/employers/index.html

-Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

W912WJ26RA003

https://www.dol.gov/vets/ https://www.fedshirevets.gov/ https://www.benefits.va.gov/vow/ https://wct.army.mil/modules/employers/index.html https://www.uschamberfoundation.org/hiring-our-heroes

WAGE DETERMINATION

The Wage Determination for this project can be found at: https://sam.gov/wage-determination/MA20250001/17

WAGE DETERMINATION NO.: MA20250001

MODIFICATION NO.: 17

DATE PUBLISHED: December 12, 2025

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data -- Modifications

(DEVIATION 2022-O0001)

Jun 2020 Deviation 2022-O0001 Oct 2021

52.215-13 Subcontractor Certified Cost or Pricing Data -- Modifications (Deviation 2022- O0001)

Jun 2020 Deviation 2022-O0001 Oct 2021

52.222-3 Convict Labor. Jun 2003 52.222-7 Withholding of Funds. May 2014 52.222-9 Apprentices and Trainees. (DEVIATION 2025-O0003) Jul 2005 Deviation 2025-O0003 Mar 2025

52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities.

Nov 2024

FAR Clauses Incorporated by Full Text

52.204-8 Annual Representations and Certifications. (DEVIATION 2025-O0003 and 2025-O0004)

(Jan 2025) Deviation 2025-O0004 (Mar 2025)

Annual Representations and Certifications (MAR 2025)(DEVIATION 2025-O0003 and 2025-O0004)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is .237130

(2) The small business size standard is .$45,000,000

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519 if the acquisition-

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) Paragraph (d) applies.

(ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

W912WJ26RA003

https://sam.gov/wage-determination/MA20250001/17

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless-

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) [Reserved]

(xv) [Reserved]

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) [Reserved]

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.