Amnd 0005 20R0008 FINAL.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 11)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

1 2

AMENDMENT NO. 0005 01/03/20 1634034

ACQ1

NAVAL FACILITIES ENGINEERING COMMAND,

MID-ATLANTIC

9742 MARYLAND AVENUE

NORFOLK, VA 23511-3095

See Item 6

✘ N4008520R0008

10/15/19

N4008520R0008 Design Build Administrative and Warehouse Facility Repairs

The date and the hour for the receipt of proposals remains 10 January 2020 no later than 2:00 pm (EDT).

See continuation page(s).

19-0145 DB Administrative and Warehouse Facility Repairs Solicitation N40085-20-R-0008 Marine Corps Base Camp Lejeune, North Carolina Amendment 0005

Block 14. DESCRIPTION OF AMENDMENT (cont.)

A. The following provides the Government’s responses to preaward inquiries:

REFERENCE

Page Section Para.

QUESTION GOVERNMENT

RESPONSE

There are 4 buildings that may be in construction simultaneously. Is there to be a QC and SSHO on each building or can one SSHO and one QC be allowed to work on all 4 buildings?

One person may fill the roles of Superintendent and Safety and Health Officer (SSHO), if duly qualified for both positions as defined in the project specification.

However, the Quality Control (QC) Manager must be a stand-alone position. Where construction is actively being performed on a building site, the contractor shall provide a Superintendent / SSHO and QC Manager at each site.

RFP Letter The current liquidated damages value of $13,950/calendar day is significantly higher than those we typically encounter on recent Government projects. The perceived risk/cost of the liquidated damages affects our ability to engage multiple qualified subcontractors, whether small business or large business.

Additionally, costs for this perceived risk from subcontractors that are willing to submit proposals, may be included as contingency costs in their final pricing. In order to facilitate more competitive pricing, please consider reducing the liquidated damages amounts.

Liquidated damages are updated to $2,156/calendar day.

B. Replace the language in the RFP under “Liquidated Damages” to state the following:

“In accordance with FAR 52.211-12 Liquidated Damages, if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,156/calendar day for each calendar day of delay until the work is completed or accepted.”

C. All other contract terms and conditions remain unchanged.