Exhibit_A_DD1423s.pdf

N00173-14-R-VH01

Exhibit A 5-13-14

CONTRACT DATA REQUIREMENTS LIST

(1 Data Item)

Form Approved OMB No. 0704-0188

The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.

A. CONTRACT LINE ITEM NO.

B. EXHIBIT

A

C. CATEGORY:

TDP TM OTHER X

D. SYSTEM/ITEM

TVAC Shroud Replacement

E. CONTRACT/PR NO.

F. CONTRACTOR

1. DATA ITEM NO.

A0010

2. TITLE OF DATA ITEM

Project Schedule

3. SUBTITLE

4. AUTHORITY (Data Acquisition Document No.)

DI-MGMT-81650

(Integrated Master Schedule - T)

5. CONTRACT REFERENCE

SOW Paragraph 3.5.4

6. REQUIRING OFFICE

CODE 8212

7. DD 250 REQ

LT

9. DIST

STATEMENT

F

10. FREQUENCY

AS REQD / MONTHLY

12. DATE OF 1ST SUBMISSION

SEE BLK 16

14. DISTRIBUTION

a. ADDRESSEE

b. COPIES

8. APP CODE

A

11. AS OF DATE

N/A

13. DATE OF SUBSEQUENT

SUBMISSION SEE BLK 16 Draft

Final Reg Repro

16. REMARKS

BLOCK 4: Contractor devised and Government approved format. Electronic submission shall be made using Microsoft Office Products.

The contractor shall produce and maintain a project schedule. The schedule shall at a minimum, detail the projects major milestones, key tasks/activities, critical path, and contain in sufficient detail the networked tasks and associated progress necessary to ensure successful program execution.

The schedule will be used to verify attainability of project objectives, to evaluate progress toward meeting objectives, and to integrate the activities with all related components.

BLOCK 8: Code 8212 review and approval (or disapproval) and comments will be within three (3) business days of submission. Contractor shall submit an updated version, incorporating comments, for Code 8212 approval no less than two (2) business days after Code 8212 comments received, unless otherwise specified.

BLOCK 10: For each design review. Minimum requirement to support project status reviews.

BLOCK 12: Contractor shall submit to Code 8212 the initial submission of at the Concept Design Review (CoDR), or as agreed to by the Contracting Officer. No Government response within 5 days of submission constitutes acceptance.

BLOCK 13: Contractor shall submit subsequent versions of the project schedule on an as-required basis in support of BLOCK 10, minimum frequency is monthly.

BLOCK 14: Electronic submission required. Hard copies will be made available upon request. CDRLs due on weekends and holidays shall be due the morning of the next business day. Upon electronic delivery of data the contractor shall notify by electronic notification in lieu of transmittal letter, all CDRL Block 6 and 14 addressees of such delivery.

COR 1

15. TOTAL

G. PREPARED BY

H. DATE

I. APPROVED BY

J. DATE

DD Form 1423-1, FEB 2001 PREVIOUS EDITION MAY BE USED Page _1_ of _1_ Pages

18. ESTIMATED

TOTAL PRICE

17. PRICE

GROUP

IV (NSP)

N00173-14-R-VH01

Exhibit A