Amendment0003(11RP45002).pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

0003 27 SEP 11 21-11-851P45002

6. ISSUED BY CODE HSCG85 7. ADMINISTERED BY (If other than Item 6) CODE

COMMANDER

SURFACE FORCES LOGISTICS CENTER C&P2

1301 CLAY ST. STE 807N

OAKLAND, CA 94612-5217

8. NAME AND ADRESS OF CONTRACTOR (no., street, county, State and ZIP Code) √ 9.A AMENDMENT OF SOLICITATION NO.

HSCG85-11-R-P45002

9B. DATE (SEE ITEM 11)

12 SEP 11

10A. MODIFICATION OF CONTRACT/ORDER

NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing Items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the Offer submitted: or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

√ A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT/.ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc)

SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority).

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

CGC SPAR (WLB 206) FY12 DRYDOCK & REPAIRS

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remain unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)

)PREVIOUS EDITION UNUSABLE Prescribed by GSA, FAR (48 CFR) 53.2

HSCG85-11-R-P45002 Amendment 0003

1. Response(s) to Request(s) for Clarification 0005-007 & 0010 is/are provided as Attachment A.

2. Offerors are reminded of the early submission requirements of the drydock information detailed in solicitation section L.9.2

3. There is no change to the proposal closing date, which remains as follows:

10/18/11 11 a.m. Pacific Time Price Proposal & Attachment J.2.

ATTACHMENT A

Date: 09/22/11

Question No. 0003

REQUEST FOR CLARIFICATION

SHIP & HULL No.: CGC SPAR (WLB 206) FY12 DRYDOCK REPAIRS

RFP No.: HSCG85-11-R-P45002

SOLICITATION SECTION: SLFC 8635 PARA NO. 3.3.5

WORK ITEM NO. 57 PARA NO. 3.5

TITLE: Period of Performance

QUESTION:

Does the CGC SPAR have an onboard shore power isolation transformer? If not, can the government provide the shore side isolation transformer to provide ungrounded shore power?

RESPONSE:

Contractor shall provide shore power isolation transformer.

Date: 09/23/11

Question No. 0006

RFP No.: HSCG85-11-R-P45002

SOLICITATION SECTION: Section F PARA NO. F-4

WORK ITEM NO. PARA NO.

TITLE: Period Of Performance

Technical wrong date on ( Completion Date ) I believe this should read 03/21/12 instead of 03/21/11.

Error noted.

Offerors shall revise Section F.4 to read:

“Completion Date: 03/21/11”

Date: 9/23/11

Question No. 0007

RFP No.: HSCG85-11-R-P45002

SOLICITATION SECTION: PARA NO.

WORK ITEM NO. 70 PARA NO. 3.2.1

TITLE: Boat Boom, Inspect & Repair

Item 70, Par. 3.2.1, Line # 3: Requires contractor to renew with apparent CFM hydraulic counterbalance valves (Qty = 2 ea). Couterbalance valves are not found in item referenced TP 3762 by the contractor. OEM Welin- Lambie representative requests clarification regarding valve type and quantity – and notes there are overcenter valves (Qty = 4).

Request confirmation if the counterbalance valves specified are the overcenter valves indicated in TP 3762 and confirmation regarding on quantity required.

The Contractor shall provide four (4) each P/N: 891-00698; Overcenter valve with seal kit, This P/N is for both the seal kit and center valve

Date: 9/26/11

Question No. 0010

RFP No.: HSCG85-11-R-P45002

SOLICITATION SECTION: PARA NO.

WORK ITEM NO. All PARA NO. All

TITLE: All Hull Related

Is Hull Thermal & Acoustic Insulation Schedule 225(B?)-WLB-635-001 available for estimating purposes?

The requested document (225-WLB_635_1_1_-_J) is supplied as an attachment to this amendment.