4. English Specifications - AMD 1.pdf

PREPARED FOR

DEPARTMENT OF THE AIR FORCE

BY

GISA, S.L.

SPECIFICATIONS (ENGLISH) FOR:

PROJECT QUUG 10-1049

CNS ALT SUBSTATION

AMMENDMENT #1

Prepared by: _________________________________________________________________

Reviewed by: _________________________________________________________________

Approved by: _________________________________________________________________

100%DS, Am#1. June 10th, 2025

THIS PAGE HAS BEEN INTENTIONALLY LEFT BLANK

CNS ALT SUBSTATION

MORÓN AIR BASE, SPAIN

QUUG 10-1049

Specifications (English)

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SCOPE OF WORK AND DRAWINGS

01 11 01 GENERAL CONDITIONS

01 11 02 SPECIAL CONDITIONS

DIVISION 02 - DEMOLITION

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

DIVISION 04 - MANSORY

04 20 00 UNIT MANSORY

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

05 50 15 CIVIL WORKS FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 55 00 LOW SLOPED ROOF FINISHED WITH ROOF FILTERING TILE

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

DIVISION 09 - FINISHES

09 90 00 PAINTS AND COATINGS

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

Page 1100%DS, Am#1. June 10th, 2025

CNS ALT SUBSTATION

MORÓN AIR BASE, SPAIN

QUUG 10-1049

Specifications (English)

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 10 00 INTEGRATED CONTROL AND PROTECTION SYSTEM (ICPS)

DIVISION 26 - ELECTRICAL

26 12 19 PAD-MOUNTED, LIQUID-FILLED, MEDIUM VOLTAGE TRANSFORMERS

26 13 13 METAL-CLAD SWITCHGEAR (MEDIUM VOLTAGE CABINETS) AND

PROTECTION RELAYS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR AND EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 11 00 CLEARING AND GRUBBING

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 04 22 GEOTEXTILES AS SEPARATION AND FILTER ELEMENTS

32 31 13 CHAIN LINK FENCES AND GATES

32 96 00 TRASPLANTING EXTERIOR PLANTS

DIVISION 33 – UTILITIES

33 40 00 STORMWATER UTILITIES

33 46 16 SUBDRAINAGE PIPING

33 71 01 OVERHEAD TRANSMISSION AND DISTRIBUTION

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

Page 2100%DS, Am#1. June 10th, 2025

QUUG 10-1049. CNS ALT SUBSTATION

SECTION 01 11 00

SCOPE OF WORK AND DRAWINGS

1 GENERAL

The work covered by this Statement of Work (SOW) consists in the construction of the project, performing all necessary travels and furnishing all professional services, facilities, labor, equipment, materials, transportation, detailed drawings to construct a complete and usable facility under a firm fixed price contract. Any design change suggested by the Contractor to the SOW requires the approval of the Contracting Officer before its acceptance is given. The Contractor shall be responsible for the temporary markings, signs, markers and lights at the area affected by the construction and, if required, shall provide the flagmen, escorts and foreign object debris controllers during the work hours.

2 WORK DESCRIPTION

The construction works included in this specification set corresponds to the work required to expand the existing and provide a new alternate main electrical substation at Morón Air Base (Spain).

The expansion will consist of a new steel H-frame and the expansion of the substation by installing a new Air Insulated Substation (AIS) equipped with a new 5 MVA transformer, that will be connected in parallel with the existing US Air Force transformer, which will remain as a back-up.

The two transformers (new and existing) will not operate simultaneously, so the project will include the necessary electrical interlocking switchgear so that only one of the transformers is connected to the output high voltage power feeder to the US Air Force facility.

Electrical distribution system coming to Morón Air Base is a 66 kV High-voltage line, owned by Endesa Distribución Eléctrica S.L.U. with a pole installed inside the base perimeter fence that is connected to the H-frame busbar of the sub-station yard.

Additionally, the project will install associated control building and high voltage infrastructure.

Also, design includes some additives:

Additive #1: Redundant batteries rectifier system.

Additive #2: Existing HV yard security fence.

Works include but are not limited to electrical, civil, structural, architectural, HVAC, sewer, telecom, control and cybersecurity.

The work under this project includes furnishing all labor, equipment, and material and performing all operations required to design (when apply), manufacture, assemble, factory test, prepare for shipment and storage, deliver, site installation and assembly of all new required equipment, including all required auxiliary services, materials, machinery and logistic. Provide equipment complete with all accessories, spare parts and tools. Provide equipment complete and totally functional.

The construction works consist of, but are not limited to, the items indicated below, including the testing to be performed by independent laboratories for quality control. All items do not limit or reduce the Contractor’s responsibility to perform all works as required by the project in order to provide a complete, operational and low-maintenance facility.

2.1 Civil Works

Perform demolition works as required for civil works.

Perform the earthwork of the site, including clearing, grading and finishing.

SECTION 01 11 00 - 1100%DS, Am#1. June 10th, 2025

Perform the site improvements.

Construct new access to new control building and expanded high voltage yard.

◦ Construct new concrete pad for new transformer.

Construct new concrete pads and service corridors.

Construct new foundations for new structures.

Construct new perimeter fence for the expanded area of the high voltage yard.

Modify existing perimeter around existing control building #1280 to also enclose new control building #1282.

Construct a new steel H-frame and steel supports ans structures.

Construct a new storm water drainage system.

Additive #2

Remove the existing perimeter fence of the area of the high voltage yard.

Construct new perimeter fence for the existing area of the high voltage yard.

2.2 Architectural, Structural and Interiors Works

Construction of the new control building: Foundation, structure, roofing, and enclosures.

2.3 Mechanical Works

Install new HVAC system for equipment in new control building 1282.

2.4 Electrical Works and Telecommunications:

Provide and install a new 5 MVA substation transformer.

Provide and install new high voltage (HV) equipment and materials.

Provide and install new medium voltage (MV) equipment and materials.

Provide and install grounding and bonding system/s for the installation, including the perimeter fence grounding.

Provide and install marketer’s metering equipment pre-installation/connection to existing metering equipment for invoicing.

Provide a new complete substation control system, that shall also incorporate the existing transformer substation protections at Bldg #1280.

Construct necessary ductbanks and accessible cable trenches.

Provide and install new lightning protection system.

New interior distribution system for new control building 1282.

New interior and exterior lighting system.

New interior and exterior telecommunications distribution system.

Provide a protective devices coordination study to define protective devices settings. The coordination study and the corresponding adjustment of the protections devices must be coordinated with Endesa Distribución Eléctrica S.L.U. System coordination, recommended ratings and settings

SECTION 01 11 00 - 2100%DS, Am#1. June 10th, 2025 of protective devices, and analysis must be accomplished by a registered professional electrical power engineer with a minimum of 3 years of experience.

Additive #1

Install a redundant batteries rectifier system and associated facilities.

2.5 Miscellaneous

Testing and Commissioning in accordance with the requirements of RD 334/2014 “Reglamento sobre Condiciones Técnicas y Garantías de Seguridad en Instalaciones Eléctricas de Alta Tensión y sus Instrucciones Técnicas Complementarias ITC RAT 01 a 23”, RD 223/2008 “Reglamento sobre condiciones técnicas y garantías de seguridad en líneas eléctricas de alta tensión y sus instrucciones técnicas complementarias ITC-LAT 01 a 09”. and RD 842/2002 “Reglamento Electrotécnico para Baja Tensión” (as applicable).

Necessary arrangements with the Endesa Distribución Eléctrica SLU company for the coordination, execution of work, and commissioning of the utilities. Including the payment of any necessary fees, taxes and supervision cost.

Necessary arrangements with the Consejería de Industria, energía y Minas de la Junta de Andalucía for the execution of work, and commissioning of the utilities. Including legalization projects and the payment of any necessary fees.

Technical services for Construction Director (Dirección de Obra) as required by RD 334/2014 “Reglamento sobre Condiciones Técnicas y Garantías de Seguridad en Instalaciones Eléctricas de Alta Tensión y sus Instrucciones Técnicas Complementarias ITC RAT 01 a 23”, RD 223/2008 “Reglamento sobre condiciones técnicas y garantías de seguridad en líneas eléctricas de alta tensión y sus instrucciones técnicas complementarias ITC-LAT 01 a 09”. and RD 842/2002 “Reglamento Electrotécnico para Baja Tensión” (as applicable).

Final cleaning.

Delivery of As-built drawings.

Delivery of Spatial Data.

3 DRAWINGS

The list of drawings is included below:

No. of Drawing Sheet Title

R-786-1 GI001 1 OF 117 PORTADA

COVER SHEET

R-786-2 GI002 2 OF 117 RELACIÓN DE PLANOS

DRAWING SCHEDULE

R-786-3 GI003 3 OF 117 PLANO DE SITUACIÓN

LOCATION PLAN

R-786-4 GI004 4 OF 117 NOTAS GENERALES I

GENERAL NOTES I

R-786-5 GI005 5 OF 117 NOTAS GENERALES II

GENERAL NOTES II

R-786-6 GI006 6 OF 117 LEYENDA Y ABREVIATURAS

LEGEND AND ABBREVIATIONS

R-786-7 GI007 7 OF 117 COORDINACIÓN DE EJECUCIÓN DE INSTALACIONES

COORDINATION OF THE EXECUTION OF INSTALLATIONS

SECTION 01 11 00 - 3100%DS, Am#1. June 10th, 2025

No. of Drawing Sheet Title

R-786-8 V-001 8 OF 117 LEVANTAMIENTO TOPOGRÁFICO. PUNTOS DE REFERENCIA

TOPOGRAPHIC SURVEY. BENCH MARKS

R-786-9 V-101 9 OF 117 LEVANTAMIENTO TOPOGRÁFICO. PLANO GENERAL

TOPOGRAPHIC SURVEY. GENERAL PLAN

R-786-10 B-101 10 OF 117 GEOTÉCNICO. PLANO DE SONDEOS

GEOTECHNICAL. BORING SITE PLAN

R-786-11 CD101 11 OF 117 CIVIL. ESTADO EXISTENTE Y DEMOLICIÓN

CIVIL. EXISTING CONDITION AND DEMOLITION

R-786-12 CD102 12 OF 117 CIVIL. SERVICIOS PÚBLICOS. ESTADO EXISTENTE Y DEMOLICIÓN

CIVIL. UTILITIES PLAN. EXISTING CONDITION AND DEMOLITION

R-786-13 CP101 13 OF 117 CIVIL. ESTADO PROYECTADO Y REPLANTEO

CIVIL. PROJECTED CONDITION AND STAKING PLAN

R-786-14 CP102 14 OF 117 CIVIL. DISTRIBUCIÓN DE PERFILES. ESTADO PROYECTADO

CIVIL. PROFILES LAYOUT. PROJECTED CONDITION

R-786-15 CP201 15 OF 117 CIVIL. PERFILES DE ZONA DE TRABAJO

CIVIL. WORK AREA PROFILES

R-786-16 CP301 16 OF 117 CIVIL. DETALLES DE PAVIMENTOS Y MEJORAS DE TERRENO. SECCIONES TIPO

CIVIL. PAVEMENT AND SITE IMPROVEMENTS DETAILS. TYPE SECTIONS

R-786-17 CP401 17 OF 117 CIVIL. DISTRIBUCIÓN DE JUNTAS. ESTADO PROYECTADO

CIVIL. JOINTS LAYOUT. PROJECTED CONDITION

R-786-18 CP501 18 OF 117 CIVIL. DETALLES DE JUNTAS

CIVIL. JOINTS DETAILS

R-786-19 CP502 19 OF 117 CIVIL. DETALLES DE VALLA I

CIVIL. FENCE DETAILS I

R-786-20 CP503 20 OF 117 CIVIL. DETALLES DE VALLA II

CIVIL. FENCE DETAILS II

R-786-21 CP504 21 OF 117 CIVIL. DETALLES DE VALLA III

CIVIL. FENCE DETAILS III

R-786-22 CP505 22 OF 117 CIVIL. CAMINOS DE CIRCULACIÓN DE VEHICULOS. RUTAS

CIVIL. VEHICLE TRAFFIC PATHS. ROUTES

R-786-23 CS101 23 OF 117 CIVIL. DISTRIBUCIÓN DE DRENAJES. ESTADO PROYECTADO

CIVIL. DRAINAGE LAYOUT. PROJECTED CONDITION

R-786-24 CS501 24 OF 117 CIVIL. DETALLES DE DRENAJE

CIVIL. DRAINAGE DETAILS

R-786-25 CU101 25 OF 117 CIVIL. SERVICIOS PÚBLICOS. ESTADO PROYECTADO

CIVIL. UTILITIES PLAN. PROJECTED CONDITION

R-786-26 CU102 26 OF 117 CIVIL. EDIFICIO #202

CIVIL. BUILDING #202

R-786-27 CU501 27 OF 117 CIVIL. DETALLES DE ZANJAS Y CANALIZACIONES SUBTERRANEAS

CIVIL. DETAILS OF TRENCHES AND UNDERGROUND CONDUITS

R-786-28 CU502 28 OF 117 CIVIL. DETALLES DE ARQUETAS I

CIVIL. MANHOLE DETAILS I

R-786-29 CU503 29 OF 117 CIVIL. DETALLES DE ARQUETAS II

CIVIL. MANHOLE DETAILS II

R-786-30 SD101 30 OF 117

ESTRUCTURA. PLANTA DE SUBESTACIÓN ELÉCTRICA. ESTADO EXISTENTE Y

DEMOLICIÓN

STRUCTURAL. ELECTRICAL SUBSTATION LAYOUT. EXISTING CONDITION AND

DEMOLITION

R-786-31 S-101 31 OF 117 ESTRUCTURA. PLANTA DE SUBESTACIÓN ELÉCTRICA. ESTADO PROYECTADO

STRUCTURAL. ELECTRICAL SUBSTATION LAYOUT. PROJECTED CONDITION

R-786-32 SB401 32 OF 117 ESTRUCTURA. EDIFICIO #1282. ESTADO PROYECTADO

STRUCTURAL. BLDG #1282. PROJECTED CONDITION

SECTION 01 11 00 - 4100%DS, Am#1. June 10th, 2025

R-786-33 SB501 33 OF 117 ESTRUCTURA. EDIFICIO #1282. DETALLES DE LOSA DE CIMENTACIÓN

STRUCTURAL. BLDG #1282. FOUNDATION SLAB DETAILS

R-786-34 SB502 34 OF 117 ESTRUCTURA. EDIFICIO #1282. DETALLES DE PORTICOS DE CIMENTACIÓN

STRUCTURAL. BLDG #1282. FOUNDATION FRAMES DETAILS

R-786-35 SB503 35 OF 117 ESTRUCTURA. EDIFICIO #1282. DETALLES DE FORJADO

STRUCTURAL. BLDG #1282. ROOF SLAB DETAILS

R-786-36 SB504 36 OF 117

ESTRUCTURA. EDIFICIO #1282. DETALLES DE UNIDAD DE MAMPOSTERÍA DE

HORMIGÓN I

STRUCTURAL. BLDG #1282. CONCRETE MASONRY UNIT DETAILS I

R-786-37 SB505 37 OF 117

ESTRUCTURA. EDIFICIO #1282. DETALLES DE UNIDAD DE MAMPOSTERÍA DE

HORMIGÓN II

STRUCTURAL. BLDG #1282. CONCRETE MASONRY UNIT DETAILS II

R-786-38 SB506 38 OF 117 ESTRUCTURA. DETALLES TIPOS

STRUCTURAL. TYPE DETAILS

R-786-39 SB507 39 OF 117 ESTRUCTURA. DETALLE DE CIMENTACIÓN DEL TRANSFORMADOR I

STRUCTURAL. TRANSFORMER FOUNDATION DETAIL I

R-786-40 SB508 40 OF 117 ESTRUCTURA. DETALLE DE CIMENTACIÓN DEL TRANSFORMADOR II

STRUCTURAL. TRANSFORMER FOUNDATION DETAIL II

R-786-41 SB509 41 OF 117 ESTRUCTURA. DETALLE DE CIMENTACIÓN DEL TRANSFORMADOR III

STRUCTURAL. TRANSFORMER FOUNDATION DETAIL III

R-786-42 SC501 42 OF 117

ESTRUCTURA. DETALLE DE ESTRUCTURA AMPLIACIÓN DE PÓRTICO

PRINCIPAL DE ACERO DE LA SUBESTACIÓN I

STRUCTURAL. SUBSTATION MAIN STEEL H-FRAME EXPANSION STRUCTURE

DETAIL I

R-786-43 SC502 43 OF 117

ESTRUCTURA. DETALLE DE ESTRUCTURA AMPLIACIÓN DE PÓRTICO

PRINCIPAL DE ACERO DE LA SUBESTACIÓN II

STRUCTURAL. SUBSTATION MAIN STEEL H-FRAME EXPANSION STRUCTURE

DETAIL II

R-786-44 SC503 44 OF 117

ESTRUCTURA. DETALLE DE ESTRUCTURA AMPLIACIÓN DE PÓRTICO

PRINCIPAL DE ACERO DE LA SUBESTACIÓN III

STRUCTURAL. SUBSTATION MAIN STEEL H-FRAME EXPANSION STRUCTURE

DETAIL III

R-786-45 SC504 45 OF 117

ESTRUCTURA. DETALLE DE SOPORTE DE ACERO DE TRANSFORMADORES DE

CORRIENTE

STRUCTURAL. CURRENT TRANSFORMERS STEEL SUPPORT DETAIL

R-786-46 SC505 46 OF 117

ESTRUCTURA. DETALLE DE SOPORTE DE ACERO DE TRANSFORMADORES DE

TENSIÓN INDUCTIVOS

STRUCTURAL. INDUCTIVE VOLTAGE TRANSFORMERS STEEL SUPPORT DETAIL

R-786-47 SC506 47 OF 117

ESTRUCTURA. DETALLE DE SOPORTE DE ACERO DE INTERRUPTOR

AUTOMÁTICO TRIFÁSICO.

STRUCTURAL. THREE-POLE CIRCUIT BREAKER STEEL SUPPORT DETAIL

R-786-48 SC507 48 OF 117

ESTRUCTURA. DETALLE DE SOPORTE DE ACERO DE PARARRAYOS DE ÓXIDO

DE ZINC

STRUCTURAL. ZINC OXIDE ARRESTER STEEL SUPPORT DETAIL

R-786-49 SC508 49 OF 117

ESTRUCTURA. DETALLE DE SOPORTE DE ACERO DE RESISTENCIA DE PUESTA

A TIERRA DEL NEUTRO

STRUCTURAL. NEUTRAL GROUNDING RESISTOR STEEL SUPPORT DETAIL

R-786-50 SC509 50 OF 117 ESTRUCTURA. DETALLE DE ESTRUCTURAS AUXILIARES

STRUCTURAL. AUXILIARY STRUCTURES DETAIL

R-786-51 SC601 51 OF 117 ESTRUCTURA. TABLA DE UNIONES SOLDADAS

STRUCTURAL. WELDED UNION SCHEDULE

R-786-52 A-101 52 OF 117 ARQUITECTURA. NUEVO EDIFICIO #1282 DE CONTROL DE SUBESTACIÓN

ARCHITECTURAL. NEW SUBSTATION CONTROL BUILDING #1282

R-786-53 A-102 53 OF 117

ARQUITECTURA. ACABADOS DE NUEVO EDIFICIO #1282 DE CONTROL DE

SUBESTACIÓN

ARCHITECTURAL. NEW SUBSTATION CONTROL BUILDING #1282 FINISHES

R-786-54 A-103 54 OF 117

ARQUITECTURA. TAPAS DE CANAL REVISABLE DE NUEVO EDIFICIO #1282 DE

CONTROL DE SUBESTACIÓN

SECTION 01 11 00 - 5100%DS, Am#1. June 10th, 2025

ARCHITECTURAL. NEW SUBSTATION CONTROL BUILDING #1282 IN FLOOR

CABLE TRENCH COVERS

R-786-55 A-301 55 OF 117

ARQUITECTURA. NUEVO EDIFICIO #1282 DE CONTROL DE SUBESTACIÓN.

SECCIONES

ARCHITECTURAL. NEW SUBSTATION CONTROL BUILDING #1282. SECTIONS

R-786-56 A-501 56 OF 117 ARQUITECTURA. DETALLES DE SUELO

ARCHITECTURAL. FLOOR DETAILS

R-786-57 A-502 57 OF 117 ARQUITECTURA. DETALLES DE FORJADO

ARCHITECTURAL. ROOF DETAILS

R-786-58 A-503 58 OF 117 ARQUITECTURA. DETALLES DE PUERTAS

ARCHITECTURAL. DOORS DETAILS

R-786-59 A-504 59 OF 117

ARQUITECTURA. DETALLE PANTALLA DE PROTECCIÓN DEL

TRANSFORMADOR

ARCHITECTURAL. DETAIL OF TRANSFORMER PROTECTION SCREEN

R-786-60 F-101 60 OF 117 PROTECCIÓN CONTRA INCENDIOS. EDIFICIO #1282. ESTADO PROYECTADO

FIRE PROTECTION. BLDG #1282. PROJECTED CONDITION

R-786-61 MH101 61 OF 117 MECÁNICA. EDIFICIO #1282. ESTADO PROYECTADO

MECHANICAL. BLDG #1282. PROJECTED CONDITION

R-786-62 MH601 62 OF 117 MECÁNICA. TABLAS DE CLIMATIZACIÓN

MECHANICAL. HVAC SCHEDULES

R-786-63 ED101 63 OF 117 ELECTRICIDAD. EDIFICIO #1280. ESTADO EXISTENTE

ELECTRICAL. BUILDING #1280. EXISTING CONDITION

R-786-64 ED601 64 OF 117

ELECTRICIDAD. ESQUEMA UNIFILAR DE SUBESTACIÓN ELÉCTRICA. ESTADO

EXISTENTE Y DEMOLICIÓN

ELECTRICAL. ELECTRICAL SUBSTATION SINGLE-LINE DIAGRAM. EXISTING

CONDITION AND DEMOLITION

R-786-65 ES101 65 OF 117

ELECTRICIDAD. PLANTA DE SUBESTACIÓN ELÉCTRICA. DISTRIBUCIÓN DE

CABLES DE MT. ESTADO PROYECTADO

ELECTRICAL. ELECTRICAL SUBSTATION LAYOUT. MV CABLES DISTRIBUTION.

PROJECTED CONDITION

R-786-66 ES102 66 OF 117

ELECTRICIDAD. PLANTA DE SUBESTACIÓN ELÉCTRICA. DISTRIBUCIÓN DE

CABLES DE BT. ESTADO PROYECTADO

ELECTRICAL. ELECTRICAL SUBSTATION LAYOUT. LV CABLES DISTRIBUTION.

PROJECTED CONDITION

R-786-67 ES103 67 OF 117

ELECTRICIDAD. DISTANCIAS DE AISLAMIENTO Y SEGURIDAD. ESTADO

PROYECTADO

ELECTRICAL. INSULATION AND SAFETY DISTANCES. PROJECTED CONDITION

R-786-68 ES301 68 OF 117

ELECTRICIDAD. SECCIÓN DE SUBESTACIÓN ELÉCTRICA. DISTANCIAS DE

AISLAMIENTO Y SEGURIDAD. ESTADO PROYECTADO

ELECTRICAL. ELECTRICAL SUBSTATION SECTION. INSULATION AND SAFETY

DISTANCES. PROJECTED CONDITION

R-786-69 ES501 69 OF 117 ELECTRICIDAD. DETALLES DE INSTALACIÓN DE SECCIONADOR DE AT

ELECTRICAL. HV DISCONNECTING SWITCH INSTALLATION DETAILS

R-786-70 ES502 70 OF 117

ELECTRICIDAD. DETALLES DE INSTALACIÓN DE TRANSFORMADORES DE

CORRIENTE Y DE TENSIÓN AT

ELECTRICAL. HV CURRENT AND VOLTAGE TRANSFORMERS INSTALLATION

DETAILS

R-786-71 ES503 71 OF 117

ELECTRICIDAD. DETALLES DE INSTALACIÓN DE INTERRUPTOR AUTOMÁTICO

TRIFÁSICO

ELECTRICAL. THREE POLE CIRCUIT BREAKER INSTALLATION DETAIL

R-786-72 ES504 72 OF 117

ELECTRICIDAD. DETALLES DE INSTALACIÓN DE PARARRAYOS Y DE

RESISTENCIA DE PUESTA A TIERRA DEL NEUTRO

ELECTRICAL. SURGE ARRESTER AND NEUTRAL GROUNDING RESISTOR

INSTALLATION DETAIL

R-786-73 ES505 73 OF 117

ELECTRICIDAD. DETALLES DE CONECTORES DE CONDUCTORES DESNUDOS Y

TUBOS

ELECTRICAL. CONNECTOR FOR OVERHEAD CONDUCTOR AND TUBES

DETAILS

SECTION 01 11 00 - 6100%DS, Am#1. June 10th, 2025

R-786-74 ES506 74 OF 117 ELECTRICIDAD. DETALLES DE TRANSFORMADOR

ELECTRICAL. TRANSFORMER DETAILS

R-786-75 ES507 75 OF 117 ELECTRICIDAD. DETALLE DE CAJA DE BORNES DEL TRANSFORMADOR

ELECTRICAL. TRANSFORMER TERMINAL BOX DETAIL

R-786-76 ES601 76 OF 117 ELECTRICIDAD. DIAGRAMA AVR

ELECTRICAL. AVR DIAGRAM

R-786-77 ES602 77 OF 117 ELECTRICIDAD. TABLA DE TENDIDO

ELECTRICAL. SAG AND TENSION SCHEDULE

R-786-78 ES901 78 OF 117 ELECTRICIDAD. VISTAS 3D. ESTADO PROYECTADO

ELECTRICAL. 3D VIEWS. PROJECTED CONDITION

R-786-79 EL101 79 OF 117

ELECTRICIDAD. ILUMINACIÓN. PLANTA DE SUBESTACIÓN ELÉCTRICA.

ESTADO PROYECTADO

ELECTRICAL. LIGHTING. ELECTRICAL SUBSTATION LAYOUT. PROJECTED

CONDITION

R-786-80 EL401 80 OF 117 ELECTRICIDAD. ILUMINACIÓN. EDIFICIO #1282. ESTADO PROYECTADO

ELECTRICAL. LIGHTING. BLDG #1282. PROJECTED CONDITION

R-786-81 EP401 81 OF 117 ELECTRICIDAD. EDIFICIO #1282. SISTEMA MT. ESTADO PROYECTADO

ELECTRICAL. BUILDING #1282. MV SYSTEM. PROJECTED CONDITION

R-786-82 EP402 82 OF 117 ELECTRICIDAD. DISTRIBUCIÓN DE CABLEADO DE BT. ESTADO PROYECTADO

ELECTRICAL. LV CABLE DISTRIBUTION. PROJECTED CONDITION

R-786-83 EP501 83 OF 117 ELECTRICIDAD. DETALLES DE CELDAS DE MT

ELECTRICAL. MV CABINETS DETAILS

R-786-84 EP502 84 OF 117 ELECTRICIDAD. DETALLE DE ARMARIO DE BCU-A3

ELECTRICAL. BCU-A3 PANELBOARD DETAILS

R-786-85 EP503 85 OF 117 ELECTRICIDAD. DETALLE DE CUADRO SCU

ELECTRICAL. SCU PANELBOARD DETAIL

R-786-86 EP504 86 OF 117 ELECTRICIDAD. DETALLES DE CUADROS ELÉCTRICOS

ELECTRICAL. ELECTRICAL PANELBOARDS DETAILS

R-786-87 EP505 87 OF 117 ELECTRICIDAD. DETALLES DE CANALIZACIONES

ELECTRICAL. RACEWAYS DETAILS

R-786-88 EP506 88 OF 117

ELECTRICIDAD. DETALLE DE CONJUNTO DE ELEMENTOS DE SEGURIDAD

ELÉCTRICA

ELECTRICAL. SET OF ELECTRICAL SAFETY EQUIPMENT DETAIL

R-786-89 EP601 89 OF 117

ELECTRICIDAD. CONFIGURACIÓN DE CELDAS DE MT PARA PROTECCIÓN Y

CONTROL

ELECTRICAL. CONTROL & PROTECTION MV CABINETS

R-786-90 EP602 90 OF 117 ELECTRICIDAD. ESQUEMA UNIFILAR FUNCIONAL DE MT. EDIFICIO #1280

ELECTRICAL. FUNCTIONAL MV SINGLE LINE DIAGRAM. BLDG #1280

R-786-91 EP603 91 OF 117 ELECTRICIDAD. ESQUEMA UNIFILAR FUNCIONAL DE MT. EDIFICIO #1282

ELECTRICAL. FUNCTIONAL MV SINGLE LINE DIAGRAM. BLDG #1282

R-786-92 EP604 92 OF 117

ELECTRICIDAD. ESQUEMA UNIFILAR DE SUBESTACIÓN ELÉCTRICA. ESTADO

PROYECTADO

ELECTRICAL. ELECTRICAL SUBSTATION SINGLE-LINE DIAGRAM. PROJECTED

CONDITION

R-786-93 EP605 93 OF 117 ELECTRICIDAD. ESQUEMA UNIFILAR FUNCIONAL DE AT DE LA SUBESTACIÓN

ELECTRICAL. SUBSTATION FUNCTIONAL HV SINGLE LINE DIAGRAM

R-786-94 EP606 94 OF 117 ELECTRICIDAD. DIAGRAMA DE SSAA

ELECTRICAL. AASS DIAGRAM

R-786-95 EP607 95 OF 117 ELECTRICIDAD. DIAGRAMA DE CUADROS 125VDC Y 24VDC

ELECTRICAL. 125VDC & 24VDC PANELBOARD DIAGRAM

R-786-96 EP608 96 OF 117 ELECTRICIDAD. CUADROS ELÉCTRICOS

ELECTRICAL. PANEL SCHEDULES

R-786-97 EP609 97 OF 117 ELECTRICIDAD. TABLAS DE EQUIPOS DE MT

ELECTRICAL. MV EQUIPMENT SCHEDULE

SECTION 01 11 00 - 7100%DS, Am#1. June 10th, 2025

R-786-98 EP610 98 OF 117 ELECTRICIDAD. TABLAS DE EQUIPOS DE AT

ELECTRICAL. HV EQUIPMENT SCHEDULE

R-786-99 EP611 99 OF 117 ELECTRICIDAD. TABLAS DE CABLEADO I

ELECTRICAL. CABLE SCHEDULE I

R-786-100 EP612 100 OF 117 ELECTRICIDAD. TABLAS DE CABLEADO II

ELECTRICAL. CABLE SCHEDULE II

R-786-101 EP613 101 OF 117 ELECTRICIDAD. TABLAS DE FUNCIONES DE PROTECCIÓN

ELECTRICAL. PROTECTION FUNCTIONS SCHEDULE

R-786-102 EG101 102 OF 117

ELECTRICIDAD. PUESTA A TIERRA. PLANTA DE SUBESTACIÓN ELÉCTRICA.

ESTADO PROYECTADO

ELECTRICAL. GROUNDING. ELECTRICAL SUBSTATION LAYOUT. PROJECTED

CONDITION

R-786-103 EG401 103 OF 117 ELECTRICIDAD. PUESTA A TIERRA. EDIFICIO #1282. ESTADO PROYECTADO

ELECTRICAL. GROUNDING. BLDG #1282. PROJECTED CONDITION

R-786-104 EG501 104 OF 117 ELECTRICIDAD. DETALLES DE PUESTA A TIERRA

ELECTRICAL. GROUNDING DETAILS

R-786-105 EG102 105 OF 117

ELECTRICIDAD. PARARRAYOS. PLANTA DE SUBESTACIÓN ELÉCTRICA.

ESTADO PROYECTADO

ELECTRICAL. LIGHTNING PROTECTION. ELECTRICAL SUBSTATION LAYOUT.

PROJECTED CONDITION

R-786-106 EG301 106 OF 117

ELECTRICIDAD. PARARRAYOS. SECCIÓN DE SUBESTACIÓN ELÉCTRICA.

ESTADO PROYECTADO

ELECTRICAL. LIGHTNING PROTECTION. ELECTRICAL SUBSTATION SECTION.

PROJECTED CONDITION

R-786-107 EG402 107 OF 117 ELECTRICIDAD. PARARRAYOS. EDIFICIO #1282. ESTADO PROYECTADO

ELECTRICAL. LIGHTNING PROTECTION. BLDG #1282. PROJECTED CONDITION

R-786-108 EG502 108 OF 117 ELECTRICIDAD. DETALLES DE PARARRAYOS

ELECTRICAL. LIGHTNING PROTECTION DETAILS

R-786-109 T-101 109 OF 117

TELECOMUNICACIONES. DISTRIBUCIÓN DE CABLEADO DE CONTROL.

ESTADO PROYECTADO

TELECOMMUNICATIONS. CONTROL CABLE DISTRIBUTION. PROJECTED

CONDITION

R-786-110 T-601 110 OF 117 ICPS. ARQUITECTURA Y CIBERSEGURIDAD

ICPS. ARCHITECTURE AND CYBERSECURITY

R-786-111 T-602 111 OF 117 ICPS. ALARMAS Y DISPAROS. PANTALLAS SCADA E INFORMES SCADA

ICPS. ALARMS & TRIPS. SCADA SCREENS & SCADA REPORTS

R-786-112 RE001 112 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT I

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT I

R-786-113 RE002 113 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT II

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT II

R-786-114 RE003 114 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT III

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT III

R-786-115 RE004 115 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT IV

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT IV

R-786-116 RE005 116 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT V

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT V

R-786-117 RE006 117 OF 117 SUBESTACIÓN ELÉCTRICA. ELECTRICIDAD AS BUILT VI

ELECTRICAL SUBSTATION. ELECTRICAL AS BUILT VI

ADDITIVE #1

R-786-118 GI001 1 OF 7 PORTADA

COVER SHEET

R-786-119 GI002 2 OF 7 RELACIÓN DE PLANOS

DRAWING SCHEDULE

SECTION 01 11 00 - 8100%DS, Am#1. June 10th, 2025

R-786-120 GI003 3 OF 7 PLANO DE SITUACIÓN

LOCATION PLAN

R-786-121 GI004 4 OF 7 NOTAS GENERALES

GENERAL NOTES

R-786-122 GI005 5 OF 7 LEYENDA Y ABREVIATURAS

LEGEND AND ABBREVIATIONS

R-786-123 EP101 6 OF 7

ELECTRICIDAD. SERVICIOS AUXILIARES Y COMUNICACIONES. ESTADO

PROYECTADO

ELECTRICAL. AUXILIARY SERVICES AND COMMUNICATIONS. PROJECTED

CONDITION

R-786-124 EP601 7 OF 7 ELECTRICIDAD. DIAGRAMA DE SSAA

ELECTRICAL. AASS DIAGRAM

ADDITIVE #2

R-786-125 GI001 1 OF 10 PORTADA

COVER SHEET

R-786-126 GI002 2 OF 10 RELACIÓN DE PLANOS

DRAWING SCHEDULE

R-786-127 GI003 3 OF 10 PLANO DE SITUACIÓN

LOCATION PLAN

R-786-128 GI004 4 OF 10 NOTAS GENERALES

GENERAL NOTES

R-786-129 GI005 5 OF 10 LEYENDA Y ABREVIATURAS

LEGEND AND ABBREVIATIONS

R-786-130 CD101 6 OF 10 CIVIL. ESTADO EXISTENTE Y DEMOLICIÓN

CIVIL. EXISTING CONDITION AND DEMOLITION

R-786-131 CI101 7 OF 10 CIVIL. DISTRIBUCIÓN DE VALLADO. ESTADO PROYECTADO

CIVIL. FENCE LAYOUT. PROJECTED CONDITION

R-786-132 CI501 8 OF 10 CIVIL. DETALLES DE VALLA I

CIVIL. FENCE DETAILS I

R-786-133 CI502 9 OF 10 CIVIL. DETALLES DE VALLA II

CIVIL. FENCE DETAILS II

R-786-134 CI503 10 OF 10 CIVIL. DETALLES DE VALLA III

CIVIL. FENCE DETAILS III

*** END OF SECTION ***

SECTION 01 11 00 - 9100%DS, Am#1. June 10th, 2025

THIS PAGE HAS BEEN INTENTIONALLY LEFT BLANK

SECTION 01 11 01

GENERAL CONDITIONS

1. GENERAL: The work consists of furnishing all labor, materials, utilities, transportation, equipment, and services to execute the project. In accordance with the drawings and specifications, complete and ready for use. Measurements shown on the drawings and specifications are given for reference use only. They are not conclusive and may be erroneous. It is the Contractor’s responsibility to verify any and all of measurements. The Government will not be held responsible for measurements shown or measurements and estimations made by the Contractor.

2. GENERAL DESCRIPTION: The work consists in, but is not limited to, executing the line items indicated in the scope of work. All line items indicated in the scope of work do not limit nor reduce the Contractor’s responsibility to perform all work as required by the project in order to provide a complete and usable facility.

3. LOCATION: The work is located in Morón Air Base, Spain, as shown on the contract drawings.

4. DRAWINGS ACCOMPANYING SPECIFICATIONS: Drawings are the property of the Government and shall not be used for any purpose other than that contemplated by the specifications. The drawings indicated in the specifications are in A1 size.

5. WARRANTY: For this contract the Contractor shall provide a two-year standard commercial warranty for with all line items of the scope of work, including materials and workmanship. The warranty shall cover all defects noticed and reported to the Contractor within two years after acceptance of the work. The Contractor shall repair or replace defective materials at their expense within a reasonable time and as approved by the Contracting Officer. The Contractor must comply with any additional warranty periods established by Spanish codes and regulations.

The Contractor shall submit the warranty letter within 15 calendar days after to the acceptance of the work by the Contracting Officer.

6. BASE ACCESS:

6.1. Permits or Authorizations: The Contractor shall obtain all permits or authorizations required to access Morón Air Base. All the communications in relation to the Base Access request must be directed to Construction Management Section for PASS&ID Office processing.

Once the works have finalized, the Contractor will return the permits or authorizations.

Contractor is responsible to provide the required escorts as required to execute the works.

6.2. Delays and Interruptions: The Contractor is advised that delays are liable to occur, due to security reasons, during the access/egress process of personnel and materials from Morón Air

01 11 01 - 1

Base. Additionally, the Contractor shall immediately interrupt the work when it is required if security warning/risk situations occur. The contractor shall submit in writing, excess delays (90 minutes or more) experienced due to base access.

7. WORK CLEARANCE REQUEST:

7.1. 15 calendar days in advance, as minimum, before the commencement of the works, the Contractor shall request AF Form 103 “BCE Work Clearance Request” to Construction Management in order to obtain all the information pertaining to the current status of Base utilities. Additional requests shall be submitted to Construction Management 15 calendar days in advance, at minimum. The Contractor shall not perform any work under any circumstances without having the approved Work Clearance at the construction site (hard copy) and not before having marked at the site with stakes and/or pins the location of the utilities. Work Clearance Request shall only be processed once all materials and documentation necessary to commence work have been submitted and approved. The Contractor shall be responsible for any damage caused to Base utilities shown on the AF Form 103 and project drawings and shall be responsible for the repairs without additional cost to the Government.

7.2. Return entire permit to Geobase Office after completion of digging excavating activities.

If additional utilities are located or encounters (or marked utilities are not found in their expected locations) then the requester shall provide a sketch to Geobase office precisely detailing the location(s) of all utilities that were found to not be in the location expected within the 10 workdays after the discovery of the discrepancy.

8. BASE UTILITIES:

8.1. The Contractor, at its expense and in coordination with the Contracting Officer or CE personnel, shall install and maintain all necessary temporary connections and distribution lines.

Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, and associated accessories.

8.2. Use of Base Utilities: Water, sewage and electrical utilities may be available to the Contractor for supply to the following buildings: Offices, latrines, break rooms and laboratories.

If the contractor wants any of these available utilities, the contractor must provide the material for the temporary utility connection and he must perform the work for the temporary utility installation. If the contractor does not want any of these available utilities, the contractor is responsible for providing their own utilities at no additional cost to the government. Contractor must request officially the connection points needed in the Mobility Plan for CE review/approval.

Other utilities, apart from the listed below, shall be supplied by the Contractor at no cost to the Government.

The following utilities are available from the existing Base utilities:

01 11 01 - 2

1. Electricity: 120/208 volts, 60 Hz.

2. Non-potable water.

8.3. Base utility connection and/or disconnection: 15 calendar days before the connection/disconnection date, the Contractor shall request the connection and/or disconnection and shall indicate:

1. Type of utility required

2. Type of connection and/or disconnection to be performed

3. Utility use

4. Required consumption

5. Maximum duration

All connection and/or disconnection works of Base utilities shall be programmed between 08:30 and 16:00 hours (between 08:30 to 15:00 during the period from 15 June to 15 September) from Monday to Friday, except holidays. The utility connections and/or disconnections can be considered critical by the Government, in which case they shall be performed on the date and time most convenient to the Government, i.e. weekends and/or during nighttime hours, without additional cost to the Government. The Contractor shall be responsible for making connections and/or disconnections, conversion, transportation of Base utility to the work site, including the furnishing and installation of the mechanisms that prevent the backflow of water to the Base service (backflow preventers) and the furnishing and installation of the transformers, if required.

The Contractor shall not activate or alter any control device of the Base utilities including water, sewage and electricity. The Government shall operate said control devices. The Contractor shall submit additional requests to Construction Management with a minimum of 15 calendar days in advance of the estimated date for the required connection, disconnection or control maneuver of the corresponding utility. The temporary overhead connections to utility are prohibited. All utilities shall be restored to their original condition prior to satisfying final contractual payments.

8.4. Base Utility Outages: When a utility outage is necessary, the Contractor shall request the utility outage, at least 15 calendar days in advance of the work, and shall indicate:

1. Type of affected utility

2. Type of cut to be performed

3. Maximum duration

01 11 01 - 3

All utility outages shall be scheduled from 08:30 and 16:00 hours (from 08:30 to 15:00 during the period from 15 June to 15 September) from Monday to Friday, except holidays. The utility outages can be considered critical by the Government, in which case they shall be performed on the date and time most convenient to the Government, i.e. weekends and/or during nighttime hours, without Government cost. The Contractor shall be responsible for making the outage, including the provision and installation of devices and materials. The Contractor shall not activate or alter any control device of the Base utilities, including water, sewage and electricity.

The Government shall operate said control devices. Temporary overhead connections to utility are prohibited. All systems shall be restored to their original condition prior to satisfying final contractual payments.

9. HOT WORK: The Contractor shall submit for approval a written request to Construction Management 15 calendar days prior to any welding, as oxyacetylene or plasma cutting work.

Said request shall indicate welding procedures and fire prevention measures. All welding work performed during the project execution shall be carried out by qualified welders only. The copies of the welder certificates, issued by an approved agency, shall be kept in the construction inspector’s files. Contractor will be responsible to keeping in effect the Hot Work Permit along the project execution period with the frequency established by the Fire Prevention Department.

10. VEHICULAR, MACHINERY AND EQUIPMENT TRAFFIC:

10.1. Transit Control Plan: All works requiring vehicular or pedestrian traffic disruptions on the Base shall require an approved transit control plan. Said plan shall be approved at least 15 calendar days prior to carrying out said disruption. Said plan shall include:

1. Start date of the traffic disruption

2. Duration of the traffic disruption

3. Proposed alternative routes

4. Signs, barriers, cones, flags and/or flagmen to be implemented

The Contractor shall establish alternate procedures if unforeseen circumstances take place. The responsibility of the provision, erecting, keeping and removing all signs, barriers, cones and flags shall be solely the Contractor. Once the work is completed, the Contractor shall remove the signaling elements such as signs, barriers, cones and/or flags.

10.2. Access Route Plan: 10 calendar days after the contract commencement date, the Contractor shall submit an access route plan to Construction Management for its approval by Contracting Officer or authorized representative.

01 11 01 - 4

10.3. Trucks: Trucks loaded with loose material (volatile dust, construction debris or other objects that could fall from them) shall be duly covered. Said covers (tarpaulins, etc.) shall be securely secured and placed on the load before accessing the Base roads.

11. STOCKPILING:

11.1. Stockpiling area of demolished/removed material: The Contractor shall transport the demolished or excavated materials to an authorized dump. Should any of the Morón Air Base shops need all or part of any of the materials from the demolition operations (concrete, aggregate and natural ground), the Contracting Office representative shall coordinate with the base Construction Management office on the exact location to stockpile said material.

11.2. Stockpiling area for Contractor material and Contractor offices: The C.O. representative shall coordinate with the base Construction Management office the exact location for Contractor offices and stockpiling.

12. CONSTRUCTION SCHEDULE:

12.1. It shall be the sole responsibility of the Contractor to ensure all required submittals are submitted for approval in a timely manner, which shall not incur any delay in completion of the project. For materials or equipment requiring a long term of procurement and delivery, said term shall be included in the period of performance. Delay in delivery/procurement will not justify an extension of the period of performance.

12.2. The Contractor shall submit an updated Construction Schedule within 7 calendar days after the Construction Phase starting date and when requested by the Contracting Officer or his authorized representative. In no case is the Contractor required to submit an updated more frequently than 20 working days. For Design-Build contracts, the updated Construction Schedule shall be submitted prior the actual construction starts.

12.3. The Construction Schedule shall include a Gantt chart showing each task, including task description, identification number, duration in calendar days, earliest start and finish dates, predecessor and successor task identification numbers, critical path and float that a task in the project network can be delayed without causing a delay to the subsequent task/s (free float) and to the project completion date (total float). The critical path shall be shown by means of a red color line and the float by means of black line after the predecessor task bar.

12.4. The Construction Schedule shall show the whole week, from Monday through Sunday. The labor days shall be from Monday through Friday. Saturday and Sunday shall be non-labor days. The holidays shall not be considered on the Construction Schedule and, therefore, they shall be considered labor days for Construction Schedule development purpose only.

12.5. The Construction Schedule shall be developed assuming 8-working hours for each labor days.

01 11 01 - 5

12.6. The Construction Schedule must include the following tasks if required:

12.6.1. Preconstruction tasks:

1. Preparation and transmittal of the bond and insurance submittals.

2. Preparation, transmittal, and approval of the submittals shown on document Schedule of Material Submittals (progress schedule, mobility plan, project sign, quality control plan, key staff, health and safety plan, environmental protection plan, AF Form 103 BCE Work Clearance Request, utility connection request, utility outage requests, welding work request, transit control plan, access routes, materials and equipment).

3. Procurement, fabrication and delivery on construction site of long lead time materials, equipment and fabricated assemblies.

4. The installation of the portable/modular buildings (rest room, dressing room, dining room, first aid, office, if required).

5. The installation of temporary connections from the portable/modular buildings to the utilities of the base.

6. The installation of the temporary fence and fabric plastic mesh along the perimeter of the area assigned for the Contractor (equipment and material storage, personnel vehicle parking area, portable/modular buildings, off-construction site disposal and waste area, if required).

7. The installation of the project sign.

8. The installation of the temporary plastic Jersey barriers filled with water, fence, fabric plastic mesh, cones and lights along the perimeter of the construction site.

9. The installation of the temporary signs, barriers, cones and flags along the transit routes.

10. The installation of the temporary occupational safety and health signs (prohibition, mandatory, warning, help, fire prevention, danger, directional board) at the area assigned for the Contractor.

11. The installation of the temporary occupational safety and health signs at the construction site.

01 11 01 - 6

12.6.2. Construction tasks:

1. The construction tasks shown on the AF Form 3052, Construction Cost Estimate Breakdown, including testing, curing time and the submission of the delivery tickets of the waste and construction debris and the approval of the field test result data.

12.6.3. Finish tasks:

1. Required testing.

2. Commissioning.

3. Pre-final inspection, including the request.

4. Correction of deficiencies.

5. Final inspection, including the request.

6. The removal of the temporary occupational safety and health signs at the construction site.

7. The removal of the temporary plastic Jersey barriers filled with water, fence, fabric plastic mesh, cones and lights along the perimeter of the construction site.

8. Final cleaning.

9. The removal of the temporary signs, barriers, cones and flags along the transit routes.

10. The removal of the project sign.

11. The removal of the temporary occupational safety and health signs at the area assigned for the Contractor.

12. The removal of temporary connections to the utilities of the base, including the preparation and transmittal of the utility disconnection request, the utility outage request and the approval of the Government.

13. The removal of the portable/modular buildings.

14. The removal of the temporary fence and fabric plastic mesh along the perimeter of the area assigned for the Contractor.

01 11 01 - 7

15. Restoration of the area assigned for the Contractor. To include restoration of all grass by means of hydro seeding. Final project acceptance and progress report will not be approved until grass is established and accepted by Contracting Officer.

16. Preparation and transmittal of the letter submittal about the inventory of all excess supplies, materials and equipment imported duty free for use under this contract.

17. Preparation and transmittal of the As-Built drawing submittal.

18. Preparation and transmittal of the spatial data submittal.

19. Preparation and transmittal of the warranty letter submittal.

20. Preparation and transmittal of the submittal of a certificate from the authorized dump about the estimated amounts or waste and construction debris managed during the execution of the project.

21. Approval of the submittals.

22. Project closeout.

13. PROGRESS SCHEDULE (AF Form 3064) : Within the 10 calendar days after the contract commencement date or another period determined by the Contracting Officer, the Contractor shall develop and submit a practicable schedule to Construction Management for its approval by Contracting Officer or authorized representative. The plan shall show:

1. Activity sequence that the Contractor proposes to perform the work.

2. Dates proposed by the Contractor for the start and completion of the salient features of the work (including the acquiring of materials, plant and equipment).

The progress schedule of the work shall be delivered in the line graphic format at an adequate scale indicating the percentage of work scheduled every 30 calendar days for its execution during the performance period. The programmed works shall correspond to the line items of the cost estimate of the contract. If the Contractor fails to submit a progress schedule of the works within the established period, the Contracting Officer may withhold the approval of the progress payments until the Contractor submits the required progress schedule.

14. PROGRESS REPORT (AF Form 3065) : Every 30 calendar days progress report to be submitted to Construction Management Office in accordance with previously submitted

01 11 01 - 8

Progress Schedule AF Form 3064. If the Contractor fails to submit a progress report of the works within the established period, the Contracting Officer may withhold the approval of the progress payments until the Contractor submits the required progress schedule. No work items will be considered 100% complete until approval of preconstruction and final submittals required. For each individual project Contracting Officer will determine the maximum percentage of work complete without preconstruction and final submittals required.

15. WORK PLAN

15.1 The Contractor shall submit a Work Plan within 7 calendar days after the Construction Phase starting date. The Work Plan shall present the construction activities planned to take place.

The Work Plan shall be prepared in coordination with the Health and Safety Plan and the Quality Control Plan and shall contain the following:

1. The summary of the proposed methodology for the execution of each task required for the project completion.

2. The resources to be used for the execution of each task required for the project completion describing the equipment and personnel to be used.

3. Daily production for each task required for the project completion.

16. MOBILITY PLAN: The Contractor shall submit a mobility plan to Construction Management for its approval by Contracting Officer or authorized representative. Said plan shall show:

1. Location and area of the work site.

2. Location and area of the offices.

3. Location and area of the parking area.

4. Location and area of the material storage areas.

The Contractor shall include in the mobility plan the proposed system to supply the utilities required at each site.

16.1. Construction Site Fencing: The construction site, offices, parking area, latrines, and material storage areas shall be fenced in by means of a two-meter high fence with gates and locks, unless otherwise approved the Government. The Contracting Officer or authorized representative shall specify the type of fencing, height and color. Fences shall be screened with a green opaque mesh to prevent the view of the inside of the fenced area from the outside. Fencing shall be completely secured at top and bottom to prevent the access to the fenced area. The fence and mesh shall be

01 11 01 - 9 adequately anchored to prevent their failing during high wind gusts. The Contractor shall include in the Mobilization Plan:

1. Photos, catalogs or samples of the fence to be used

2. Photos, catalog or samples of the mesh to be used

The Contractor shall not start the installation of the fencing and mesh until the plan is approved in writing by the Contracting Officer or authorized representative. The responsibility of providing, erecting, keeping and removing all the fences and meshes shall be solely the Contractor. The Contractor shall replace or repair, within the following 24 hours or as determined by the Contracting Officer or authorized representative, all fence or mesh sections that have been damaged or deteriorated. Once the works have been finalized, the Contractor shall remove the fences and meshes.

16.2. Offices: Temporary prefabricated buildings required for administrative reasons (office space, conference room and break room) shall be in good conditions. Temporary prefabricated buildings requiring paint, repairs or are in bad conditions shall not be allowed at the site. Said temporary prefabricated buildings shall show on the outside a plaque of 0.5 x 0.5 meters maximum dimensions, indicating the name of the company and telephone number (s) of the person (s) designated as POC for the Contractor. Once the works are finalized, the Contractor shall remove the temporary prefabricated buildings.

16.3. Latrines: Prefabricated temporary buildings required for personnel latrines shall be in good conditions. The prefabricated temporary buildings requiring paint, repairs or are in bad conditions shall not be allowed on the work site. These buildings shall be kept in perfect use conditions and sanitized, shall be treated for insects and shall be emptied and cleaned with a detergent for sanitary use once a week. The frequency of emptying and cleaning shall be adjusted according to needs. The prefabricated temporary buildings shall be located at no less than 50 meters from the existing buildings of Base if they cannot be located near a sewage manhole. Once the works have been completed, the Contractor shall remove the temporary facilities and shall leave the area clean and sanitized.

16.4. Parking: The Contractor, their employees and subcontractors shall park all vehicles, including heavy machinery, equipment and vehicles, in areas where they do not pose an obstruction in the corresponding work site.

16.5. Material Storage: Material storage containers shall be in good conditions. The storage of materials, in containers or not, at the work site shall be at the Contractor’s risk. The use of private security guards at the work site shall require the previous Spanish Air Force Security Forces approval. The Contractor shall not use the work site to store material. Once the works have finished, the Contractor shall remove the excess stored material.

01 11 01 - 10

17. PROJECT SIGN : Within 15 calendar days after the Construction Phase starting date, the Contractor shall install an identifying work/project sign in accordance with Figure 1 no later than one day after the work site fencing is completed. The sign shall be mounted on two wooden posts of 10 cm x 10 cm, as minimum, fastened to the ground and adequately anchored. The location of said sign shall be determined by the Contracting Officer or his representative. During final cleanup of the work site, the sign, posts, fasteners and anchoring elements shall be removed. Unless otherwise specified, the sign shall have white background and the lettering shall be dark blue.