DMAC LIQUIDAM Template PWS appendix B.xlsx
XLSX spreadsheet 13 KB Posted
- Attached to
- Demolition Multiple Award Contract (DMAC)
- Solicitation number
- FA4620-11-Q-B002
About this file
Appendix B.
View the file
Other files
Show all 14
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Physical Work Phase
| LIQUIDATED DAMAGES BREAKDOWN-APPENDIX B |
| Demolition Multiple Award Contract (DMAC) |
| PAY | HOURS | HOURLY | TOTAL |
| GRADE | PER DAY | RATE (1) | PER DAY |
| CIVIL ENGINEERING (CES) | |||||
| COR MANAGEMENT | GS-12 | 0.25 | HR | $ 63.28 | $ 15.82 |
TECHNICAL REPRESENTATIVE GS-11 0.50 HR $ 52.71 $ 26.36
CONTRACTING OFFICER REPRESENTATIVE GS-9 1.00 HR $ 43.69 $ 43.69
TOTAL CIVIL ENGINEERING: $ 85.87
CONTRACTING (CONS)
CONTRACTING MANAGEMENT GS-12 0.25 HR $ 63.28 $ 15.82
CONTRACTING OFFICER GS-11 0.50 HR $ 52.71 $ 26.36
CONTRACT ADMINISTRATOR GS-9 1.00 HR $ 43.69 $ 43.69
TOTAL CONTRACTING: $ 85.87
TOTAL LIQUIDATED DAMAGES: (CES + CONS) $ 171.73
| DAILY RATE: | $ 126 |
| Total Liquidated Damages multiplied by 22 (average # of work days per month) | |
| divided by 30 (average # of days per month) rounded to the nearest dollar. |
| If the contractor fails to complete the work within the time specified in the contract, the contractor shall pay to |
| the Government as liquidated damages the sum of $126 for the first day of delay and $126 for each day thereafter. |
| CONTRACTING OFFICER SIGNATURE & DATE | |
| (1) AFI 65-503, Table A31-1 | |
| Application of Civilian Pay Acceleration Factors |
File details come from the government source that posted it. Updated .