Attachment 24 - UFGS 01 57 19 Temporary Environmental Controls.pdf

SECTION 01 57 19 Page 1

USACE / NAVFAC / AFCEC / NASA UFGS-01 57 19 (August 2022)

Preparing Activity: NAVFAC Superseding

UFGS-01 57 19 (November 2015)

UFGS-01 57 19.01 20 (November 2015)

UNIFIED FACILITIES GUIDE SPECIFICATIONS

References are in agreement with UMRL dated July 2022

SECTION 01 57 19

TEMPORARY ENVIRONMENTAL CONTROLS

JB Charleston (May 2023)

NOTE: This guide specification covers the requirements for environmental protection and other environmental temporary controls.

Use this specification for design and construction projects located CONUS and OCONUS. Edit this specification to the extent that is allowed and does not conflict with the applicable Status of Forces

Agreements (SOFA), Host Nation-Funded Construction

Agreements (HNFA), and in some instances, Bilateral

Infrastructure Agreements (BIA), and country-specific Final Governing Standards (FGS) or the DoD Overseas Environmental Baseline Guidance

Document (OEBGD), DoD 4715.05. The OEBGD applies when there are no FGS in place.

Only edit the parts of this specification section that have bracketed choices.

Many States and Municipalities have more stringent or additional requirements:

For Navy projects, use this section and those portions of this section which contain State and

Local requirements. Add any further local requirements into this section. Use these sections for both Design-Bid-Build and Design-Build projects.

For Army projects. Edit this section to include weblinks to the State or Local requirement. Add the

State and Local source to the Reference list and cite within the body of this section. Clearly state in this section deviations from the State and Local requirements.

Adhere to UFC 1-300-02 Unified Facilities Guide

Specifications (UFGS) Format Standard when editing this guide specification or preparing new project specification sections. Edit this guide

SECTION 01 57 19 Page 2 specification for project specific requirements by adding, deleting, or revising text. For bracketed items, choose applicable item(s) or insert appropriate information.

Remove information and requirements not required in respective project, whether or not brackets are present.

NOTE: To download UFGS Forms, Graphics, and Tables, go to: https://www.wbdg.org/ffc/dod/unified-facilities-guide-specifications-ufgs/forms-graphics-tables

Comments, suggestions and recommended changes for this guide specification are welcome and should be submitted as a Criteria Change Request (CCR).

PART 1 GENERAL

1.1 REFERENCES

NOTE: This paragraph is used to list the publications cited in the text of the guide specification. The publications are referred to in the text by basic designation only and listed in this paragraph by organization, designation, date, and title.

Use the Reference Wizard's Check Reference feature when you add a Reference Identifier (RID) outside of the Section's Reference Article to automatically place the reference in the Reference Article. Also use the Reference Wizard's Check Reference feature to update the issue dates.

References not used in the text will automatically be deleted from this section of the project specification when you choose to reconcile references in the publish print process.

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

ASSOCIATION OF ILLINOIS SOIL AND WATER CONSERVATION DISTRICTS

(AISWCD)

IUM (2020) Illinois Urban Manual

ASTM INTERNATIONAL (ASTM)

ASTM E2356 (2018) Standard Practice for Comprehensive

Building Asbestos Surveys http://www.wbdg.org/ffc/dod/unified-

SECTION 01 57 19 Page 3

ILLINOIS ENVIRONMENTAL PROTECTION AGENCY (IEPA)

35 IAC 900-901 Title 35 of Illinois Administrative Code, Subtitle H: Noise, Chapter I: Pollution

Control Board

INDIANA DEPARTMENT OF ENVIRONMENTAL MANAGEMENT (IDEM)

327 IAC 2-6.1

Indiana Administrative Code, Volume 6, Title 327, Article 2, Rule 6.1. Spills;

Reporting, Containment, and Response

327 IAC 15-5

Title 327, Article 15, Section 5. Storm

Water Run-off Associated with Construction

Activity

327 IAC 15-5-6

Title 327, Article 15, Section 5-6.

Submittal of an NOI Letter and

Construction Plans

327 IAC 15-5-6.5

Title 327, Article 15, Section 5-6.5.

Requirements for Construction Plans

327 IAC 15-5-7

Title 327, Article 15, Section 5-7.

General Requirements for Storm Water

Quality Control

INSTRUCTIONS AND STANDARDS FOR NAVBASE GUANTANAMO BAY CUBA

(COMNAVBASEGTMOINST)

1710.10 Outdoor Recreational and Wildlife

Instruction

4400.2A Consolidated Hazardous Material

Reutilization and Inventory Management

Program

5090.1 Hazardous Waste Management Plan

5090.4 Standard Operating Procedures for Landfill

5090.7 Pollution Control Procedures for Oil and

Hazardous Substances

5090.8 Asbestos Program Management

5100.13 Hazardous Material/Excess Hazardous

Material Control and Safety Program

FGS (1994) Final Governing Standards for

Environmental Protection by U.S. Forces in

Cuba

SECTION 01 57 19 Page 4

PUGET SOUND CLEAN AIR AGENCY (PSCAA)

PSCAA Regulation Regulation I, II, and III

STATE OF VIRGINIA ADMINISTRATIVE CODE (VAC)

9 VAC 25-840 Title 9, Agency 25, Chapter 840: Erosion

And Sediment Control Regulations

9 VAC 25-850 Title 9, Agency 25, Chapter 850: Erosion

And Sediment Control And Stormwater

Management Certification Regulations

9 VAC 25-870 Title 9, Agency 25, Chapter 870: Virginia

Stormwater Management Program (VSMP)

Regulation

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety -- Safety and Health

Requirements Manual

U.S. DEPARTMENT OF DEFENSE (DOD)

DOD 4715.05 (2020) Overseas Environmental Baseline

Guidance Document: Conservation

U.S. ENVIRONMENTAL PROTECTION AGENCY (EPA)

EPA SW-846 (Third Edition; Update IV) Test Methods for Evaluating Solid Waste:

Physical/Chemical Methods

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910.1053

Respirable Crystalline Silica

29 CFR 1910.1200

Hazard Communication

29 CFR 1926.1153

Respirable Crystalline Silica

40 CFR 50

National Primary and Secondary Ambient Air

Quality Standards

40 CFR 60

Standards of Performance for New

Stationary Sources

40 CFR 61.145

Standard for Demolition and Renovation

40 CFR 63

National Emission Standards for Hazardous

Air Pollutants for Source Categories

40 CFR 64

Compliance Assurance Monitoring

40 CFR 68

Chemical Accident Prevention Provisions

40 CFR 82

Protection of Stratospheric Ozone

40 CFR 112

Oil Pollution Prevention

SECTION 01 57 19 Page 5

40 CFR 122.26 Storm Water Discharges (Applicable to

State NPDES Programs, see section 123.25)

40 CFR 152 Pesticide Registration and Classification

Procedures

40 CFR 152 - 186 Pesticide Programs

40 CFR 241 Guidelines for Disposal of Solid Waste

40 CFR 243 Guidelines for the Storage and Collection of Residential, Commercial, and

Institutional Solid Waste

40 CFR 258 Subtitle D Landfill Requirements

40 CFR 260 Hazardous Waste Management System: General

40 CFR 261 Identification and Listing of Hazardous

Waste

40 CFR 261.7 Residues of Hazardous Waste in Empty

Containers

40 CFR 262 Standards Applicable to Generators of

Hazardous Waste

40 CFR 262.11 Hazardous Waste Determination and

Recordkeeping

40 CFR 262.34 Standards Applicable to Generators of

Hazardous Waste-Accumulation Time

40 CFR 263 Standards Applicable to Transporters of

Hazardous Waste

40 CFR 264 Standards for Owners and Operators of

Hazardous Waste Treatment, Storage, and

Disposal Facilities

40 CFR 265 Interim Status Standards for Owners and

Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 266 Standards for the Management of Specific

Hazardous Wastes and Specific Types of

Hazardous Waste Management Facilities

40 CFR 268 Land Disposal Restrictions

40 CFR 273 Standards for Universal Waste Management

40 CFR 273.2 Standards for Universal Waste Management -

Batteries

40 CFR 273.3 Standards for Universal Waste Management -

Pesticides

SECTION 01 57 19 Page 6

40 CFR 273.4 Standards for Universal Waste Management -

Mercury Containing Equipment

40 CFR 273.5 Standards for Universal Waste Management -

Lamps

40 CFR 273.6 Applicability - Aerosol Cans

40 CFR 279 Standards for the Management of Used Oil

40 CFR 300 National Oil and Hazardous Substances

Pollution Contingency Plan

40 CFR 300.125 National Oil and Hazardous Substances

Pollution Contingency Plan - Notification and Communications

40 CFR 302 Designation, Reportable Quantities, and

Notification

40 CFR 355 Emergency Planning and Notification

40 CFR 403 General Pretreatment Regulations for

Existing and New Sources of Pollution

40 CFR 745 Lead-Based Paint Poisoning Prevention in

Certain Residential Structures

40 CFR 761 Polychlorinated Biphenyls (PCBs)

Manufacturing, Processing, Distribution in

Commerce, and Use Prohibitions

49 CFR 171 General Information, Regulations, and

Definitions

49 CFR 172 Hazardous Materials Table, Special

Provisions, Hazardous Materials

Communications, Emergency Response

Information, and Training Requirements

49 CFR 172.101 Hazardous Material Regulation-Purpose and

Use of Hazardous Material Table

49 CFR 173 Shippers - General Requirements for

Shipments and Packagings

49 CFR 178 Specifications for Packagings

77 FR 12286 Final National Pollutant Discharge

Elimination System (NPDES) General Permit for Stormwater Discharges from

Construction Activities

WASHINGTON STATE ADMINISTRATIVE CODE (WAC)

WAC-173-60 Maximum Environmental Noise Levels

WAC-173-160 Minimum Standards for Construction and

Maintenance of Wells

SECTION 01 57 19 Page 7

WAC-173-303 Washington Dangerous Waste Regulations

WAC-173-303-330 Personnel Training

WAC-173-303-573 Standards for Universal Waste Management

WAC-173-303-573(2) Standards for Universal Waste Management -

Batteries

WAC-173-303-573(3) Standards for Universal Waste Management -

Mercury-containing Equipment

WAC-173-303-573(5) Standards for Universal Waste Management -

Lamps

WAC-173-350 Solid Waste Handling Standards

WAC-222-30 Timber Harvesting

WAC-246-290 Department of Health Drinking Water

Regulation

WASHINGTON STATE DEPARTMENT OF ECOLOGY (WSDE)

WSDE SMM (2014) Washington State Stormwater

Management Manual for Western Washington

WISCONSIN DEPARTMENT OF NATURAL RESOURCES (WDNR)

s. NR 415, Wis. Adm. Code Control of Particulate Emissions

1.2 DEFINITIONS

1.2.1 Class I and II Ozone Depleting Substance (ODS)

Class I ODS is defined in Section 602(a) of The Clean Air Act. A list of

Class I ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances.

Class II ODS is defined in Section 602(s) of The Clean Air Act. A list of

Class II ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances.

1.2.2 Contractor Generated Hazardous Waste

Contractor generated hazardous waste is materials that, if abandoned or disposed of, may meet the definition of a hazardous waste. These waste streams would typically consist of material brought on site by the

Contractor to execute work, but are not fully consumed during the course of construction. Examples include, but are not limited to, excess paint thinners (i.e., methyl ethyl ketone, toluene), waste thinners, excess paints, excess solvents, waste solvents, excess pesticides, and contaminated pesticide equipment rinse water.

http://www.epa.gov/ozone-layer-protection/ozone-depleting-substances http://www.epa.gov/ozone-layer-protection/ozone-depleting-substances

SECTION 01 57 19 Page 8

1.2.3 Electronics Waste

Electronics waste is discarded electronic devices intended for salvage, recycling, or disposal.

1.2.4 Environmental Pollution and Damage

Environmental pollution and damage is the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances of importance to human life; affect other species of importance to humankind; or degrade the environment aesthetically, culturally or historically.

1.2.5 Environmental Protection

Environmental protection is the prevention/control of pollution and habitat disruption that may occur to the environment during construction.

The control of environmental pollution and damage requires consideration of land, water, and air; biological and cultural resources; and includes management of visual aesthetics; noise; solid, chemical, gaseous, and liquid waste; radiant energy and radioactive material as well as other pollutants.

1.2.6 Hazardous Debris

As defined in paragraph SOLID WASTE, debris that contains listed hazardous waste (either on the debris surface, or in its interstices, such as pore structure) in accordance with 40 CFR 261. Hazardous debris also includes debris that exhibits a characteristic of hazardous waste in accordance with 40 CFR 261.

1.2.7 Hazardous Materials

Hazardous material is any material that: Is defined in 49 CFR 171, listed in 49 CFR 172, regulated as a hazardous material in accordance with

49 CFR 173; or requires a Safety Data Sheet (SDS) in accordance with

29 CFR 1910.1200; or during end use, treatment, handling, packaging, storage, transportation, or disposal meets or has components that meet or have potential to meet the definition of a hazardous waste as defined by

40 CFR 261 Subparts A, B, C, or D. Designation of a material by this definition, when separately regulated or controlled by other sections or directives, does not eliminate the need for adherence to that hazard-specific guidance which takes precedence over this section for

"control" purposes. Such material includes ammunition, weapons, explosive actuated devices, propellants, pyrotechnics, chemical and biological warfare materials, medical and pharmaceutical supplies, medical waste and infectious materials, bulk fuels, radioactive materials, and other materials such as asbestos, mercury, and polychlorinated biphenyls (PCBs).

1.2.8 Hazardous Waste

Hazardous Waste is any material that meets the definition of a solid waste and exhibits a hazardous characteristic (ignitability, corrosivity, reactivity, or toxicity) as specified in 40 CFR 261, Subpart C, or contains a listed hazardous waste as identified in 40 CFR 261, Subpart D, or meets a state, local, or host nation definition of a hazardous waste.

SECTION 01 57 19 Page 9

1.2.9 Land Application

Land Application means spreading or spraying discharge water at a rate that allows the water to percolate into the soil. No sheeting action, soil erosion, discharge into storm sewers, discharge into defined drainage areas, or discharge into the "waters of the United States" must occur.

Comply with federal, state, and local laws and regulations.

1.2.10 Municipal Separate Storm Sewer System (MS4) Permit

MS4 permits are those held by municipalities or installations to obtain

NPDES permit coverage for their stormwater discharges.

1.2.11 National Pollutant Discharge Elimination System (NPDES)

The NPDES permit program controls water pollution by regulating point sources that discharge pollutants into waters of the United States.

1.2.12 Oily Waste

Oily waste are those materials that are, or were, mixed with Petroleum, Oils, and Lubricants (POLs) and have become separated from that POLs.

Oily wastes also means materials, including wastewaters, centrifuge solids, filter residues or sludges, bottom sediments, tank bottoms, and sorbents which have come into contact with and have been contaminated by, POLs and may be appropriately tested and discarded in a manner which is in compliance with other state and local requirements.

This definition includes materials such as oily rags, "kitty litter" sorbent clay and organic sorbent material. These materials may be land filled provided that: It is not prohibited in other state regulations or local ordinances; the amount generated is "de minimus" (a small amount);

it is the result of minor leaks or spills resulting from normal process operations; and free-flowing oil has been removed to the practicable extent possible. Large quantities of this material, generated as a result of a major spill or in lieu of proper maintenance of the processing equipment, are a solid waste. As a solid waste, perform a hazardous waste determination prior to disposal. As this can be an expensive process, it is recommended that this type of waste be minimized through good housekeeping practices and employee education.

1.2.13 Regulated Waste

Regulated waste are solid wastes that have specific additional federal, state, or local controls for handling, storage, or disposal.

1.2.14 Sediment

Sediment is soil and other debris that have eroded and have been transported by runoff water or wind.

1.2.15 Solid Waste

Solid waste is a solid, liquid, semi-solid or contained gaseous waste. A solid waste can be a hazardous waste, non-hazardous waste, or non-Resource

Conservation and Recovery Act (RCRA) regulated waste. Types of solid waste typically generated at construction sites may include:

SECTION 01 57 19 Page 10

1.2.15.1 Debris

Debris is non-hazardous solid material generated during the construction, demolition, or renovation of a structure that exceeds 60 mm 2.5-inch particle size that is: a manufactured object; plant or animal matter; or natural geologic material (for example, cobbles and boulders), broken or removed concrete, masonry, and rock asphalt paving; ceramics; roofing paper and shingles. Inert materials may not be reinforced with or contain ferrous wire, rods, accessories and weldments. A mixture of debris and other material such as soil or sludge is also subject to regulation as debris if the mixture is comprised primarily of debris by volume, based on visual inspection.

1.2.15.2 Green Waste

Green waste is the vegetative matter from landscaping, land clearing and grubbing, including, but not limited to, grass, bushes, scrubs, small trees and saplings, tree stumps and plant roots. Marketable trees, grasses and plants that are indicated to remain, be re-located, or be re-used are not included.

1.2.15.3 Material Not Regulated As Solid Waste

Material not regulated as solid waste is nuclear source or byproduct materials regulated under the Federal Atomic Energy Act of 1954 as amended; suspended or dissolved materials in domestic sewage effluent or irrigation return flows, or other regulated point source discharges;

regulated air emissions; and fluids or wastes associated with natural gas or crude oil exploration or production.

1.2.15.4 Non-Hazardous Waste

Non-hazardous waste is waste that is excluded from, or does not meet, hazardous waste criteria in accordance with 40 CFR 261.

1.2.15.5 Recyclables

Recyclables are materials, equipment and assemblies such as doors, windows, door and window frames, plumbing fixtures, glazing and mirrors that are recovered and sold as recyclable materials. It also includes commercial-grade refrigeration equipment with Freon removed, household appliances where the basic material content is metal, clean polyethylene terephthalate bottles, cooking oil, used fuel oil, textiles, high-grade paper products and corrugated cardboard, stackable pallets in good condition, clean crating material, and clean rubber/vehicle tires. Metal meeting the definition of lead contaminated or lead based paint contaminated may be included as recyclable if sold to a scrap metal company. Paint cans that meet the definition of empty containers in accordance with 40 CFR 261.7 may be included as recyclable if sold to a scrap metal company.

1.2.15.6 Surplus Soil

Surplus soil is existing soil that is in excess of what is required for this work, including aggregates intended, but not used, for on-site mixing of concrete, mortars, and paving. Contaminated soil meeting the definition of hazardous material or hazardous waste is not included and must be managed in accordance with paragraph HAZARDOUS MATERIAL MANAGEMENT.

SECTION 01 57 19 Page 11

1.2.15.7 Scrap Metal

This includes scrap and excess ferrous and non-ferrous metals such as reinforcing steel, structural shapes, pipe, and wire that are recovered or collected and disposed of as scrap. Scrap metal meeting the definition of hazardous material or hazardous waste is not included.

1.2.15.8 Wood

Wood is dimension and non-dimension lumber, plywood, chipboard, hardboard. Treated or painted wood that meets the definition of lead contaminated or lead based contaminated paint is not included. Treated wood includes, but is not limited to, lumber, utility poles, crossties, and other wood products with chemical treatment.

1.2.21 Surface Discharge

Surface discharge means discharge of water into drainage ditches, storm sewers, or creeks meeting the definition of "waters of the United

States". Surface discharges from construction sites are discrete, identifiable sources and require a permit from the governing agency.

Comply with federal, state, and local laws and regulations.

1.2.22 Wastewater

Wastewater is the used water and solids that flow through a sanitary sewer to a treatment plant.

1.2.22.1 Stormwater

Stormwater is any precipitation in an urban or suburban area that does not evaporate or soak into the ground, but instead collects and flows into storm drains, rivers, and streams.

1.2.23 Waters of the United States

Waters of the United States means Federally jurisdictional waters, including wetlands, that are subject to regulation under Section 404 of the Clean Water Act or navigable waters, as defined under the Rivers and

Harbors Act.

1.2.24 Wetlands

Wetlands are those areas that are inundated or saturated by surface or groundwater at a frequency and duration sufficient to support, and that under normal circumstances do support, a prevalence of vegetation typically adapted for life in saturated soil conditions.

1.2.25 Universal Waste

Note: States' universal waste regulations may differ from the federal requirements below. Verify all constituents listed below are categorized as universal waste by the State where the project is located and edit accordingly. Some states may include additional materials. Include those here.

The universal waste regulations streamline collection requirements for

SECTION 01 57 19 Page 12 certain hazardous wastes in the following categories: batteries, pesticides, mercury-containing equipment (for example, thermostats), and lamps (for example, fluorescent bulbs). The rule is designed to reduce hazardous waste in the municipal solid waste (MSW) stream by making it easier for universal waste handlers to collect these items and send them for recycling or proper disposal. These regulations can be found at

40 CFR 273.

1.2.26 Location Specific Universal Waste

Any of the following dangerous waste that are subject to the universal waste requirements of WAC-173-303-573: Batteries as described in

WAC-173-303-573(2)); Lamps as described in WAC-173-303-573(5);

Mercury-containing equipment as described in WAC-173-303-573(3).

1.2.26.1 Reportable Release

A reportable release means any spilling, leaking, pumping, pouring, emitting, emptying, discharging, injecting, escaping, leaching, dumping, or disposing into the environment of a known or unknown material or hazardous substance that poses an immediate threat to human health or the environment to the air, soil, or water. Reportable releases are: a sheen of oil on the water; a violation of the Installation's or project's water permit (NPDES permit); a sewage spill that threatens human health or the environment; a Comprehensive Environmental Response, Compensation, and

Liability Act reportable quantity for hazardous/toxic substances (

40 CFR 302); an air or hazardous substance release that is a threat to human health or the environment, or released outside the facility boundaries; any discharge from an underground storage tank regulated under

WAC 173-360; or oil spilled to the ground or to permeable secondary containment of 160 liters 42 gallons and greater.

1.2.26.2 Non-emergency Spill Event

A non-emergency spill event is a discharge of a known material or any hazardous substance that does not pose an immediate threat to human health or the environment, can be cleaned up as part of normal housekeeping by the personnel who discovered the spill, and is not released on the soil or into any waterway inlet (for example, storm drain) or outside Navy property boundaries.

1.3 SUBMITTALS

NOTE: Review Submittal Description (SD) definitions in Section 01 33 00 SUBMITTAL PROCEDURES and edit the following list, and corresponding submittal items in the text, to reflect only the submittals required for the project. The Guide Specification technical editors have classified those items that require Government approval, due to their complexity or criticality, with a "G." Generally, other submittal items can be reviewed by the Contractor's

Quality Control System. Only add a "G" to an item if the submittal is sufficiently important or complex in context of the project.

For Army projects, fill in the empty brackets following the "G" classification, with a code of up to three characters to indicate the approving authority. Codes for Army projects using the

SECTION 01 57 19 Page 13

Resident Management System (RMS) are: "AE" for

Architect-Engineer; "DO" for District Office

(Engineering Division or other organization in the

District Office); "AO" for Area Office; "RO" for

Resident Office; and "PO" for Project Office. Codes following the "G" typically are not used for Navy, Air Force, and NASA projects.

The "S" classification indicates submittals required as proof of compliance for sustainability Guiding

Principles Validation or Third Party Certification and as described in Section 01 33 00 SUBMITTAL

PROCEDURES.

Choose the first bracketed item for Navy, Air Force, and NASA projects, or choose the second bracketed item for Army projects.

NOTE: For Navy Design-Build projects, delete

01 33 00 SUBMITTAL PROCEDURES, and replace with UFGS

01 33 00.05 20 CONSTRUCTION SUBMITTAL PROCEDURES and

UFGS 01 33 10.05 20 DESIGN SUBMITTAL PROCEDURES.

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are

[for Contractor Quality Control approval.][for information only. When used, a code following the "G" classification identifies the office that will review the submittal for the Government.] Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

NOTE: For projects in the NAVFAC PAC Area of

Operation, and for the submittals identified as

SD-01 Preconstruction Submittals, select the "G" designation requiring Government approval for

Environmental Protection Plan, and Stormwater

Pollution Protection Plan. Remove the "G" designation for Stormwater Notice of Intent, Solid

Waste Management Permit, Regulatory Notifications, Dirt and Dust Control Plan, Employee Training

Records, and Environmental Manager Qualifications.

Preconstruction Survey; FIO

Regulatory Notifications; G

Environmental Protection Plan; G

Dirt and Dust Control Plan; G

Solid Waste Management Permit; G

Stormwater Pollution Prevention Plan (SWPPP); G[IF APPLICABLE]

Stormwater Notice of Intent (for NPDES coverage under the general permit for construction activities); G[IF APPLICABLE]

SECTION 01 57 19 Page 14

Spill Prevention Control And Countermeasure (SPCC) Plan; G

SD-06 Test Reports

Monthly Solid Waste Disposal Report; FIO

Inspection Reports; FIO

][ Laboratory Analysis; FIO

SD-11 Closeout Submittals

Regulatory Notifications; G

[ Stormwater Pollution Prevention Plan Compliance Notebook; FIO

][ Stormwater Notice of Termination (for NPDES coverage under the general permit for construction activities); G[IF APPLICABLE]

][ As-Built Topographic Survey; G [IF APPLICABLE]

] Waste Determination Documentation; G[IF APPLICABLE]

Project Solid Waste Disposal Documentation Report; FIO[IF

APPLICABLE]

Contractor Hazardous Material Inventory Log; G[, [ ]]

1.4 ENVIRONMENTAL PROTECTION REQUIREMENTS

Provide and maintain, during the life of the contract, environmental protection as defined. Plan for and provide environmental protective measures to control pollution that develops during construction practice.

Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work during the entire duration of this

Contract. Comply with federal, state, and local regulations pertaining to the environment, including water, air, solid waste, hazardous waste and substances, oily substances, and noise pollution.

Tests and procedures assessing whether construction operations comply with

Applicable Environmental Laws may be required. Analytical work must be performed by qualified laboratories; and where required by law, the laboratories must be certified.

1.4.1 Conformance with the Environmental Management System

Perform work under this contract consistent with the policy and objectives identified in the installation's Environmental Management System (EMS).

Perform work in a manner that conforms to objectives and targets of the environmental programs and operational controls identified by the EMS.

Support Government personnel when environmental compliance and EMS audits are conducted by escorting auditors at the Project site, answering

SECTION 01 57 19 Page 15 questions, and providing proof of records being maintained. Provide monitoring and measurement information as necessary to address environmental performance relative to environmental, energy, and transportation management goals. In the event an EMS nonconformance or environmental noncompliance associated with the contracted services, tasks, or actions occurs, take corrective and preventative actions. In addition, employees must be aware of their roles and responsibilities under the installation EMS and of how these EMS roles and responsibilities affect work performed under the contract.

Coordinate with the installation's EMS coordinator to identify training needs associated with environmental aspects and the EMS, and arrange training or take other action to meet these needs. Provide training documentation to the Contracting Officer. The Installation Environmental

Office will retain associated environmental compliance records. Make EMS

Awareness training completion certificates available to Government auditors during EMS audits and include the certificates in the Employee

Training Records. See paragraph EMPLOYEE TRAINING RECORDS.

1.5 SPECIAL ENVIRONMENTAL REQUIREMENTS

NOTE: The special environmental requirements with which the Contractor must comply must be developed during the design process, included in the bidding documents, and made a part of the contract. The special environmental requirements must be developed by the Designer from such documents as the National

Environmental Policy Act (NEPA) compliance measures specified in the Categorical Exclusion documentation, Environmental Assessment (EA), or the

Environmental Impact Statement (EIS), the

Installation Master Plan, or the Installation Storm

Water Management Plan. For Civil Works projects, the Environmental commitments made during planning are usually tracked by Project Management.

Coordination with the Project Manager is essential in developing the special requirements.

Special Project Environmental Requirements for JB

Charleston may include but not limited to:

- Storm Water Pollution Prevention Plan (SWPPP)

- Permit to Construct an Air Pollution Source

- Construction Permit Application - Drinking

Water and/or Wastewater Facilities

- Water Line Extensions - General Construction

Permit Application for Public Water Supply

Systems

- Bacteriological Analysis Input Form

List attachments referenced below in paragraph

LICENSES AND PERMITS, which require Contractor's actions, in the blank provided and attach to the end of this Section. Remove this paragraph if not required in the project after coordination with paragraph LICENSES AND PERMITS.

https://scdhec.gov/sites/default/files/Library/D-1970.pdf https://scdhec.gov/sites/default/files/Library/D-1970.pdf https://scdhec.gov/sites/default/files/Library/D-2507.pdf https://scdhec.gov/sites/default/files/Library/D-2507.pdf https://scdhec.gov/sites/default/files/Library/D-2507.pdf https://scdhec.gov/sites/default/files/Library/d-1974.pdf

SECTION 01 57 19 Page 16

Comply with the special environmental requirements listed here [ ] and attached at the end of this section.

1.5.1 Mid-Atlantic

NOTE: The following paragraph and subparagraphs are tailored for NAVFAC ML use only.

NOTE: Applicable environmental requirements such as; erosion/sediment control, storm water, hazardous waste, and solid waste may have unique state regulations. Edit this section to include these unique state requirements for each state listed below.

NOTE: For each project, provide the following:

1. Unique local requirements and state regulations.

2. Environmental Point of Contact information for design review and base specific requirements.

3. For every installation in area of responsibility, the FEC must identify the facility Hazardous Waste

Generator status as specified in paragraph FACILITY

HAZARDOUS WASTE GENERATOR STATUS.

4. For each installation listed below, provide specific requirements of the installation's

Environmental Management System (EMS) that relate to construction operations. Identify those site specific EMS actions that the Contractor must perform under this contract.

Comply with the following state, regional, and local requirements.

1.5.1.1 South Carolina - JB Charleston

1.5.1.1.1 Unique Local Requirements [COMPLETE IF APPLICABLE]

1.5.1.1.2 Environmental Point of Contact Information for Design Review and Base

Specific Requirements:

1.5.1.1.2.1 628 CES/CEIE – Contact the Contracting Officer for the most current Point of Contact Information for design review and base specific requirements.

SECTION 01 57 19 Page 17

1.6 QUALITY ASSURANCE

1.6.1 Preconstruction Survey and Protection of Features

NOTE: Use this paragraph as applicable. For example, it may not be necessary for an interior renovation project.

This paragraph supplements the Contract Clause PROTECTION OF EXISTING

VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS. Prior to start of any onsite construction activities, perform a Preconstruction

Survey of the project site with the Contracting Officer, and take photographs showing existing environmental conditions in and adjacent to the site. Submit a report for the record. Include in the report a plan describing the features requiring protection under the provisions of the

Contract Clauses, which are not specifically identified on the drawings as environmental features requiring protection along with the condition of trees, shrubs and grassed areas immediately adjacent to the site of work and adjacent to the Contractor's assigned storage area and access route(s), as applicable. The Contractor and the Contracting Officer will sign this survey report upon mutual agreement regarding its accuracy and completeness. Protect those environmental features included in the survey report and any indicated on the drawings, regardless of interference that their preservation may cause to the work under the Contract.

1.6.2 Regulatory Notifications

NOTE: Coordinate with the Installation

Environmental Office as applicable to fill in the number of days that notification is required prior to work starting.

Provide regulatory notification requirements in accordance with federal, state and local regulations. In cases where the Government will also provide public notification (such as stormwater permitting), coordinate with the Contracting Officer. Submit copies of regulatory notifications to the Contracting Officer prior to commencement of work activities.

Additionally, submit copies of regulatory notifications to the

Installation Environmental Office as directed in the Pre-Construction

Conference.

Typically, regulatory notifications must be provided for the following

(this listing is not all-inclusive): demolition, renovation, NPDES defined site work, construction, removal or use of a permitted air emissions source, and remediation of controlled substances (asbestos, hazardous waste, lead paint).

1.6.3 Environmental Brief

NOTE: Coordinate incorporation of this requirement with the Installation Environmental Office as applicable.

Attend an environmental brief to be included in the preconstruction

SECTION 01 57 19 Page 18 meeting. Provide the following information: types, quantities, and use of hazardous materials that will be brought onto the installation; and types and quantities of wastes/wastewater that may be generated during the

Contract. Discuss the results of the Preconstruction Survey at this time.

Prior to initiating any work on site, meet with the Contracting Officer and Installation Environmental Office to discuss the proposed

Environmental Protection Plan (EPP) or equipment local requirement.

Develop a mutual understanding relative to the details of environmental protection, including measures for protecting natural and cultural resources, required reports, required permits, permit requirements (such as mitigation measures), and other measures to be taken.

[1.6.4 Environmental Manager

NOTE: Coordinate incorporation of this requirement with the Installation Environmental Office as applicable. Consider project environmental risks versus project size or dollar value. A small project, such as demolishing a plating shop could be low cost, but high risk and a large project, such as replacing a roof on a hangar, could be high cost, but low risk.

Appoint in writing an Environmental Manager for the project site. The

Environmental Manager is directly responsible for coordinating contractor compliance with federal, state, local, and installation requirements. The

Environmental Manager must ensure compliance with Hazardous Waste Program requirements (including hazardous waste handling, storage, manifesting, and disposal); implement the EPP; ensure environmental permits are obtained, maintained, and closed out; ensure compliance with Stormwater

Program requirements; ensure compliance with Hazardous Materials (storage, handling, and reporting) requirements; and coordinate any remediation of regulated substances (lead, asbestos, PCB transformers). This can be a collateral position; however, the person in this position must be trained to adequately accomplish the following duties: ensure waste segregation and storage compatibility requirements are met; inspect and manage

Satellite Accumulation areas; ensure only authorized personnel add wastes to containers; ensure Contractor personnel are trained in 40 CFR requirements in accordance with their position requirements; coordinate removal of waste containers; and maintain the Environmental Records binder and required documentation, including environmental permits compliance and close-out. Submit Environmental Manager Qualifications to the Contracting

Officer.

- Training required for this position?

o HAZWOPER?

o Certified Storm water Inspector?

o Etc.

]1.6.5 Employee Training Records

NOTE: Insert the bracketed text for projects on a

Large Quantity Generator Facility. See paragraph

FACILITY HAZARDOUS WASTE GENERATOR STATUS for determination of generator status.

Erosion and Sediment Control Inspector

SECTION 01 57 19 Page 19

Qualifications are determined by the state; not all states require the inspector be certified by the state.

Prepare and maintain Employee Training Records throughout the term of the contract meeting applicable 40 CFR requirements. Provide Employee Training Records in the

Environmental Records Binder.[Ensure every employee completes a program of classroom instruction or on-the-job training that teaches them to perform their duties in a way that ensures compliance with federal, state and local regulatory requirements for RCRA Large Quantity Generator. Provide a Position Description for each employee, by subcontractor, based on the Davis-Bacon Wage Rate designation or other equivalent method, evaluating the employee's association with hazardous and regulated wastes. This Position Description will include training requirements as defined in 40 CFR 265 for a Large Quantity Generator facility.]

Submit these Assembled Employee Training Records to the Contracting Officer at the conclusion of the project, unless otherwise directed.

Train personnel to meet [EPA][state] requirements. Conduct environmental protection/pollution control meetings for personnel prior to commencing construction activities. Conduct additional meetings for new personnel and when site conditions change. Include in the training and meeting agenda: methods of detecting and avoiding pollution; familiarization with statutory and contractual pollution standards; installation and care of devices, vegetative covers, and instruments required for monitoring purposes to ensure adequate and continuous environmental protection/pollution control; anticipated hazardous or toxic chemicals or wastes, and other regulated contaminants; recognition and protection of archaeological sites, artifacts, waters of the United States, and endangered species and their habitat that are known to be in the area.[

Provide copy of the Erosion and Sediment Control Inspector[ Qualifications as defined by EPA][ Certification as required by[ state]].]

1.6.6 Non-Compliance Notifications

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with federal, state or local environmental laws or regulations, permits, and other elements of the Contractor's EPP. After receipt of such notice, inform the Contracting Officer of the proposed corrective action and take such action when approved by the Contracting

Officer. The Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. FAR

52.242-14 Suspension of Work provides that a suspension, delay, or interruption of work due to the fault or negligence of the Contractor allows for no adjustments to the contract for time extensions or equitable adjustments. In addition to a suspension of work, the

Contracting Officer may use additional authorities under the contract or law.

1.7 ENVIRONMENTAL PROTECTION PLAN

NOTE: Edit this paragraph to include any environmental concerns or plans that may be required for the construction Contractor to protect the environment during construction of the project.

Coordinate the requirements with the Installation

Environmental Office as applicable in addition to the Federal, State, Regional, and Local agencies.

SECTION 01 57 19 Page 20

Some permits required under the Environmental

Protection Plan require up to 90 days advance regulator notice before site work may begin.

NOTE: For DBB projects, remove the second bracketed sentence and select the first bracketed sentence. For DB projects remove the first bracketed sentence and select the second bracketed sentence.

The purpose of the EPP is to present an overview of known or potential environmental issues that must be considered and addressed during construction. Incorporate construction related objectives and targets from the installation's EMS into the EPP. Include in the EPP measures for protecting natural and cultural resources, required reports, and other measures to be taken. Meet with the Contracting Officer or Contracting

Officer Representative to discuss the EPP and develop a mutual understanding relative to the details for environmental protection including measures for protecting natural resources, required reports, and other measures to be taken. [Submit the EPP within 30 calendar days after

Notice to Proceed.][Submit the EPP not less than 60 calendar days before scheduled final site or building design approval.] Revise the EPP throughout the project to include any reporting requirements, changes in site conditions, or contract modifications that change the project scope of work in a way that could have an environmental impact. No requirement in this section will relieve the Contractor of any applicable federal, state, and local environmental protection laws and regulations. During

Construction, identify, implement, and submit for approval any additional requirements to be included in the EPP. Maintain the current version onsite.

The EPP includes, but is not limited to, the following elements:

1.7.1 General Overview and Purpose

1.7.1.1 Descriptions

NOTE: Edit paragraph below to include those plans required for the project. The bracketed list of plans is for example only and not meant to be all inclusive.

A brief description of each specific plan required by environmental permit or elsewhere in this Contract such as[ stormwater pollution prevention plan,][ spill control plan,][ solid waste management plan,][ wastewater management plan,][ air pollution control plan,][ contaminant prevention plan,][ a historical, archaeological, cultural resources, biological resources and wetlands plan,][ traffic control plan][ Hazardous, Toxic and

Radioactive Waste (HTRW) Plan][ Non-Hazardous Solid Waste Disposal Plan][ borrowing material plan][ ].

1.7.1.2 Duties

The duties and level of authority assigned to the person(s) on the job site who oversee environmental compliance, such as who is responsible for adherence to the EPP, who is responsible for spill cleanup and training personnel on spill response procedures, who is responsible for manifesting

SECTION 01 57 19 Page 21 hazardous waste to be removed from the site (if applicable), and who is responsible for training the Contractor's environmental protection personnel.

1.7.1.3 Procedures

A copy of any standard or project-specific operating procedures that will be used to effectively manage and protect the environment on the project site.

1.7.1.4 Communications

Communication and training procedures that will be used to convey environmental management requirements to Contractor employees and subcontractors.

1.7.1.5 Contact Information

Emergency contact information contact information (office phone number, cell phone number, and e-mail address).

1.7.2 General Site Information

1.7.2.1 Drawings

Drawings showing locations of proposed temporary excavations or embankments for haul roads, stream crossings, jurisdictional wetlands, material storage areas, structures, sanitary facilities, storm drains and conveyances, and stockpiles of excess soil.

1.7.2.2 Work Area

Work area plan showing the proposed activity in each portion of the area and identify the areas of limited use or nonuse. Include measures for marking the limits of use areas, including methods for protection of features to be preserved within authorized work areas and methods to control runoff and to contain materials on site, and a traffic control plan.

Show where any fuels, hazardous substances, solvents, or lubricants will be stored. Provide a spill plan to address any releases of those materials.

1.7.2.3 Documentation

A letter signed by an officer of the firm appointing the Environmental

Manager and stating that person is responsible for managing and implementing the Environmental Program as described in this contract.

Include in this letter the Environmental Manager's authority to direct the removal and replacement of non-conforming work.

1.7.3 Management of Natural Resources

a. Land resources

b. Tree protection

c. Replacement of damaged landscape features

d. Temporary construction

SECTION 01 57 19 Page 22

e. Stream crossings

f. Fish and wildlife resources

g. Wetland areas

1.7.4 Protection of Historical and Archaeological Resources

a. Objectives

b. Methods

1.7.5 Stormwater Management and Control

a. Ground cover

b. Erodible soils

c. Temporary measures

(1) Structural Practices

(2) Temporary and permanent stabilization

d. Effective selection, implementation and maintenance of Best Management

Practices (BMPs).

e. Stormwater Pollution Prevention Plan (SWPPP).

1.7.6 Protection of the Environment from Waste Derived from Contractor

Operations

Control and disposal of solid and sanitary waste.

Control and disposal of hazardous waste.

This item consists of the management procedures for hazardous waste to be generated. The elements of those procedures will coincide with the

Installation Hazardous Waste Management Plan when within an installation.

The Contracting Officer will provide a copy of the Installation Hazardous

Waste Management Plan as applicable.

As a minimum, include the following:

a. List of the types of hazardous wastes expected to be generated

b. Procedures to ensure a written waste determination is made for appropriate wastes that are to be generated

c. Sampling/analysis plan, including laboratory method(s) that will be used for waste determinations and copies of relevant laboratory certifications

d. Methods and proposed locations for hazardous waste accumulation/storage (that is, in tanks or containers)

e. Management procedures for storage, labeling, transportation, and disposal of waste (treatment of waste is not allowed unless specifically noted)

SECTION 01 57 19 Page 23

f. Management procedures and regulatory documentation ensuring disposal of hazardous waste complies with Land Disposal Restrictions (40 CFR 268

g. Management procedures for recyclable hazardous materials such as lead-acid batteries, used oil, and similar

h. Used oil management procedures in accordance with 40 CFR 279;

Hazardous waste minimization procedures

i. Plans for the disposal of hazardous waste by permitted facilities; and

Procedures to be employed to ensure required employee training records are maintained.

j. Plans for hazardous waste of liquids. Liquids shall not be disposed of in industrial dumpsters. Liquid waste shall be solidified prior to disposal, or managed as sewer when appropriate. Liquid waste other than domestic sanitary sewer will need to be approved by the Installation

Hazardous Waste Manager prior to discharge into the sanitary or storm sewer system(s). Liquids meeting the definition of Hazardous Waste shall not be discharged to the sanitary or storm sewer system(s).

1.7.7 Prevention of Releases to the Environment

Procedures to prevent releases to the environment

Notifications in the event of a release to the environment

1.7.8 Regulatory Notification and Permits

List what notifications and permit applications must be made. Some permits require up to 180 days to obtain.