FA2816-16-R-0008_Solicitation_RELEASED.pdf

Project Title: Simplif ied Acquisition of Base Engineer Requirements (SABER)

This solicitation is for a one year base contract plus four option years (w ith an optional six month extension).

This solicitation is a SBA Certif ied 8(a) set-aside. It has been determined that competition w ill be limited to eligible 8(a) f irms located w ithin the geographical area serviced by the SBA Los Angeles District Office, and other 8(a) construction f irms w ith a bona fide place of business w ithin the geographical competitive area, and the assigned NAICS code. All other 8(a) BD Participants are deemed ineligible to submit offers.

The contract w ill be a single aw ard Firm-Fixed Price (FFP) Indefinite Delivery/Indefinite Quantity (IDIQ) type contract and w ill include a w ide variety of individual construction type Delivery Orders (DOs). The disclosure of magnitude w ill be specif ied per individual Delivery Order.

Contracts Manager: Ryan P. Kittle, 2d Lt, USAF

Phone: 310-653-5614; Email: ryan.kittle@us.af.mil

Contracting Officer: Mr. Alan R. Mak

Phone: 310-653-1812; Email: alan.mak@us.af.mil

RYAN KITTLE 310-653-5614

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

08-Nov-2016

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10 Alt1

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________2 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________09 Dec 2016 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______180 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

SMC/PKO - FA2816

OPERATIONAL CONTRACTING

483 N. AVIATION BLVD.

EL SEGUNDO CA 90245-2808

FA2816

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

(310) 653-6117FAX:TEL: (310) 653-6118 TEL: FAX:

FA2816-16-R-0008 92

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA2816-16-R-0008

Section A - Solicitation/Contract Form

NOTES

Section A Notes

The Standard Form 1442 – Solicitation, Offer, and Award, (pages 1-2 of the solicitation) constitutes Section A of this solicitation.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

SABER Base Year

FFP

DO NOT PRICE THIS CLIN. THIS CLIN IS INFORMATION ONLY. In accordance with Statement of Work, paragraphs 1.3-1.4, each individual construction project will be awarded by issuing individual Delivery Orders against the basic contract. Projects will be in support of real property maintenance, repair, alteration, and new construction. The contractor shall be required to furnish all materials, equipment, and personnel necessary to design, construct, manage, and accomplish the requirement in accordance with the Statement of Work.

FOB: Destination

SIGNAL CODE: A

NET AMT

0001AA 1 Job Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during standard work hours, as defined in paragraph 44.1 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

0001AB 1 Job Non-Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during non-standard work hours, as defined in paragraph 44.2 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

OPTION SABER Option Year 1

FFP

DO NOT PRICE THIS CLIN. THIS CLIN IS INFORMATION ONLY. In accordance with Statement of Work, paragraphs 1.3-1.4, each individual construction project will be awarded by issuing individual Delivery Orders against the basic contract. Projects will be in support of real property maintenance, repair, alteration, and new construction. The contractor shall be required to furnish all materials, equipment, and personnel necessary to design, construct, manage, and accomplish the requirement in accordance with the Statement of Work.

0101AA 1 Job OPTION Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during standard work hours, as defined in paragraph 44.1 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

0101AB 1 Job OPTION Non-Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during non-standard work hours, as defined in paragraph 44.2 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

OPTION SABER Option Year 2

FFP

DO NOT PRICE THIS CLIN. THIS CLIN IS INFORMATION ONLY. In accordance with Statement of Work, paragraphs 1.3-1.4, each individual construction project will be awarded by issuing individual Delivery Orders against the basic contract. Projects will be in support of real property maintenance, repair, alteration, and new construction. The contractor shall be required to furnish all materials, equipment, and personnel necessary to design, construct, manage, and accomplish the requirement in accordance with the Statement of Work.

0201AA 1 Job OPTION Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during standard work hours, as defined in paragraph 44.1 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

0201AB 1 Job OPTION Non-Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during non-standard work hours, as defined in paragraph 44.2 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

OPTION SABER Option Year 3

FFP

DO NOT PRICE THIS CLIN. THIS CLIN IS INFORMATION ONLY. In accordance with Statement of Work, paragraphs 1.3-1.4, each individual construction project will be awarded by issuing individual Delivery Orders against the basic contract. Projects will be in support of real property maintenance, repair, alteration, and new construction. The contractor shall be required to furnish all materials, equipment, and personnel necessary to design, construct, manage, and accomplish the requirement in accordance with the Statement of Work.

0301AA 1 Job OPTION Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during standard work hours, as defined in paragraph 44.1 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

0301AB 1 Job OPTION Non-Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during non-standard work hours, as defined in paragraph 44.2 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

OPTION SABER Option Year 4

FFP

DO NOT PRICE THIS CLIN. THIS CLIN IS INFORMATION ONLY. In accordance with Statement of Work, paragraphs 1.3-1.4, each individual construction project will be awarded by issuing individual Delivery Orders against the basic contract. Projects will be in support of real property maintenance, repair, alteration, and new construction. The contractor shall be required to furnish all materials, equipment, and personnel necessary to design, construct, manage, and accomplish the requirement in accordance with the Statement of Work.

0401AA 1 Job OPTION Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during standard work hours, as defined in paragraph 44.1 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

0401AB 1 Job OPTION Non-Standard Hours

FFP

TO BE FILLED IN BY OFFEROR. All work performed during non-standard work hours, as defined in paragraph 44.2 of the Statement of Work, shall be multiplied by the coefficient of _____________%.

CONTRACT MINIMUM/MAXIMUM QUANTITY AND CONTRACT VALUE

The minimum quantity and contract value for all orders issued against this contract shall not be less than the minimum quantity and contract value stated in the following table. The maximum quantity and contract value for all orders issued against this contract shall not exceed the maximum quantity and contract value stated in the following table.

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

1.00 $2,000.00 999.00 $33,000,000.00

DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND ORDER VALUE

The minimum quantity and order value for each Delivery/Task Order issued shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for each

Delivery/Task Order issued shall not exceed the maximum quantity and order value stated in the following table.

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

1.00 $2,000.00 999.00 $1,000,000.00

CLIN MINIMUM/MAXIMUM QUANTITY AND CLIN VALUE

The minimum quantity(s) and CLIN value(s) for all orders issued against the CLIN(s) on this contract shall not be less than the minimum quantity(s) and CLIN value(s) stated in the following table. The maximum quantity(s) and

CLIN value(s) for all orders issued against the CLIN(s) on this contract shall not exceed the maximum quantity(s) and CLIN value(s) stated in the following table.

CLIN

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

0001AA 1.00 $2,000.00 999.00 $6,000,000.00

0001AB 1.00 $2,000.00 999.00 $6,000,000.00

0101AA 1.00 $2,000.00 999.00 $6,000,000.00

0101AB 1.00 $2,000.00 999.00 $6,000,000.00

0201AA 1.00 $2,000.00 999.00 $6,000,000.00

0201AB 1.00 $2,000.00 999.00 $6,000,000.00

0301AA 1.00 $2,000.00 999.00 $6,000,000.00

0301AB 1.00 $2,000.00 999.00 $6,000,000.00

0401AA 1.00 $2,000.00 999.00 $6,000,000.00

0401AB 1.00 $2,000.00 999.00 $6,000,000.00

CLIN DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND CLIN ORDER VALUE

The minimum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not exceed the maximum quantity and order value stated in the following table.

CLIN

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

0001AA 1.00

$2,000.00

999.00

$1,000,000.00

0001AB 1.00

0101AA 1.00

0101AB 1.00

0201AA 1.00

0201AB 1.00

0301AA 1.00

0301AB 1.00

0401AA 1.00

0401AB 1.00

Section C - Descriptions and Specifications

Section C Notes

Section C is blank in this solicitation.

Section D - Packaging and Marking

Section D Notes

Section D is blank in this solicitation.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0001AA Destination Government Destination Government

0001AB Destination Government Destination Government

0101 Destination Government Destination Government

0101AA Destination Government Destination Government

0101AB Destination Government Destination Government

0201 Destination Government Destination Government

0201AA Destination Government Destination Government

0201AB Destination Government Destination Government

0301 Destination Government Destination Government

0301AA Destination Government Destination Government

0301AB Destination Government Destination Government

0401 Destination Government Destination Government

0401AA Destination Government Destination Government

0401AB Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 POP 21-FEB-2017 TO

20-FEB-2018

N/A 61 CELS - F2T0BA

483 N. AVIATION BLVD., BLDG 272

EL SEGUNDO CA 90245-2808

F2T0BA

0001AA POP 21-FEB-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0001AB POP 21-FEB-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0101 POP 21-FEB-2018 TO

20-FEB-2019

N/A (SAME AS PREVIOUS LOCATION)

0101AA POP 21-FEB-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

0101AB POP 21-FEB-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

0201 POP 21-FEB-2019 TO

20-FEB-2020

N/A (SAME AS PREVIOUS LOCATION)

0201AA POP 21-FEB-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

0201AB POP 21-FEB-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

0301 POP 21-FEB-2020 TO

20-FEB-2021

N/A (SAME AS PREVIOUS LOCATION)

0301AA POP 21-FEB-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

0301AB POP 21-FEB-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

0401 POP 21-FEB-2021 TO

20-FEB-2022

N/A (SAME AS PREVIOUS LOCATION)

0401AA POP 21-FEB-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

0401AB POP 21-FEB-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

Section G - Contract Administration Data

Section G Notes

Section G is blank in this solicitation.

Section H - Special Contract Requirements

Section H Notes

Section H is blank in this solicitation.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015

52.203-14 Display of Hotline Poster(s) OCT 2015

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management JUL 2013

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2015

52.204-13 System for Award Management Maintenance JUL 2013

52.204-16 Commercial and Government Entity Code Reporting JUL 2015

52.204-18 Commercial and Government Entity Code Maintenance JUL 2015

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-10 Commencement, Prosecution, and Completion of Work APR 1984

52.211-10 Alt I Commencement, Prosecution, and Completion of Work (Apr

1984) - Alternate I

APR 1984

52.211-13 Time Extensions SEP 2000

52.211-18 Variation in Estimated Quantity APR 1984

52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2004

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.215-20 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data

OCT 2010

52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.217-5 Evaluation Of Options JUL 1990

52.219-8 Utilization of Small Business Concerns OCT 2014

52.219-14 Limitations On Subcontracting NOV 2011

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records MAY 2014

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014

52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity APR 2015

52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-30 Construction Wage Rate Requirements--Price Adjustment

(None or Separately Specified Method)

MAY 2014

52.222-37 Employment Reports on Veterans FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015

52.222-54 Employment Eligibility Verification OCT 2015

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.226-4 Notice of Disaster or Emergency Area Set-Aside NOV 2007

52.226-5 Restrictions on Subcontracting Outisde Disaster or

Emergency Area

NOV 2007

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014

52.228-14 Irrevocable Letter of Credit NOV 2014

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-17 Interest MAY 2014

52.232-18 Availability Of Funds APR 1984

52.232-23 Assignment Of Claims MAY 2014

52.232-25 Prompt Payment JUL 2013

52.232-27 Prompt Payment for Construction Contracts MAY 2014

52.232-28 Invitation to Propose Performance-Based Payments MAR 2000

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-16 Quantity Surveys APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.236-26 Preconstruction Conference FEB 1995

52.236-28 Preparation of Proposals--Construction OCT 1997

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.242-17 Government Delay Of Work APR 1984

52.243-4 Changes JUN 2007

52.244-5 Competition In Subcontracting DEC 1996

52.244-6 Subcontracts for Commercial Items FEB 2016

52.245-1 Government Property APR 2012

52.245-9 Use And Charges APR 2012

52.246-12 Inspection of Construction AUG 1996

52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.247-34 F.O.B. Destination NOV 1991

52.248-3 Value Engineering-Construction OCT 2015

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-3 Termination for Convenience of the Government

(Dismantling, Demolition, or Removal of Improvements)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting.

DEC 2015

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.211-7007 Reporting of Government-Furnished Property AUG 2012

252.215-7000 Pricing Adjustments DEC 2012

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012

252.245-7004 Reporting, Reutilization, and Disposal MAR 2015

252.246-7000 Material Inspection And Receiving Report MAR 2008

252.247-7007 Liability and Insurance DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)

(a) The offeror certifies that --

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to –

(i) Those prices,

(ii) The intention to submit an offer, or

(iii) The methods of factors used to calculate the prices offered:

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --

(1) Is the person in the offeror's organization responsible for determining the prices offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; or

(2) (i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provison ______________________________________________________ (insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization);

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) above have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs

(a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) of this provision, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

(End of Provision)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2016)

*To be filled in by Offeror.*

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vi) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(viii) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(ix) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(x) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xi) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xvi) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xvii) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xviii) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xix) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-

5.

(xx) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxi) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to

Iran—Representation and Certification. This provision applies to all solicitations.

(xxii) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS--

REPRESENTATION (NOV 2015)

(a) Definitions. Inverted domestic corporation and subsidiary have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10).

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(c) Representation. The Offeror represents that--

(1) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and

(2) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation.

https://www.acquisition.gov/

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or

State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have ( ), have not ( ), within a three-year period preceding this offer, been notified of any delinquent

Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of To Be Determined By The Contracting Officer

For Each Delivery Order As Applicable, for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

https://www.acquisition.gov/

The Government contemplates award of a Firm-Fixed Price, Indefinite Delivery / Indefinite

Quantity (IDIQ) contract resulting from this solicitation.

52.216-7 ALLOWABLE COST AND PAYMENT (JUN 2013) -- ALTERNATE I (FEB 1997)

(a) Invoicing.

(1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the

Contracting Officer in accordance with Federal Acquisition Regulation (FAR) Subpart 31.2 in effect on the date of this contract and the terms of this contract. The Contractor may submit to an authorized representative of the

Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract.

(2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act.

Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232-25. (3) The designated payment office will make interim payments for contract financing on the 30th day after the designated billing office receives a proper payment request. In the event that the Government requires an audit or other review of a specific payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date.

(b) Reimbursing costs.

(1) For the purpose of reimbursing allowable costs (except as provided in paragraph (b)(2) of this clause, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term "costs" includes only-

(i) Those recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract;

(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for-

(A) Supplies and services purchased directly for the contract and associated financing payments to subcontractors, provided payments determined due will be made-

(1) In accordance with the terms and conditions of a subcontract or invoice; and

(2) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government;

(B) Materials issued from the Contractor's inventory and placed in the production process for use on the contract;

(C) Direct labor;

(D) Direct travel;

(E) Other direct in-house costs; and

(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and

(iii) The amount of progress and other payments to the Contractor's subcontractors that either have been paid, or that the Contractor is required to pay pursuant to the clause of this contract entitled "Prompt Payment for Construction

Contracts." Payments shall be made by cash, check, or other form of payment to the Contractor's subcontractors under similar cost standards.

(2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid…