DIVISON_26_-_ELECTRICAL.pdf

City of Ft. Myers - Parks & Records Departments.

Warehouse Conversion.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

000110 - 1

ELECTRICAL TABLE OF CONTENTS

DIVISIONS 26

DIVISION 26 ELECTRICAL

260100 Operation and Maintenance Manuals 260500 Common Work Results for Electrical Systems 260507 Submittals 260508 Substitutions 260510 Electrical Symbols and Abbreviations 260519 Building Wire and Cable 260526 Grounding and Bonding 260529 Hangers and Supports for Electrical Systems 260533 Conduit for Electrical Systems 260534 Outlet Boxes for Electrical Systems 260538 Floor Boxes for Electrical Systems 260553 Identification for Electrical Systems 260800 Demonstration of Completed Electrical Systems 260813 Tests and Performance Verification of Electrical System 260923 Occupancy Sensor 262416 Panelboards 262713 Utility Service Entrance 262716 Cabinets and Enclosures for Electrical Systems 262726 Wiring Devices 262819 Enclosed Disconnect Switches 264300 Surge Protective devices 265113 Interior Lighting Fixtures, Lamps and Ballasts 265213 Emergency Lighting Equipment 265600 Exterior Luminaires

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

000110 - 2

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 1

SECTION 260100 - OPERATION AND MAINTENANCE MANUALS

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions, Divisions 01, 26, 27 and 28 Specification Sections apply to this Section.

1.2 SUMMARY

A. O & M Manuals contain copies of all warranties, operation and maintenance instructions, and other pertinent information relative to the project that is used throughout the life of the facility. This section contains additional requirements for the preparation of Electrical (Power and Lighting) and Systems Operation and Maintenance Manuals.

1.3 OPERATION AND MAINTENANCE MANUALS

A. General: Refer to Section 017700 Closeout Procedures.

B. O & M Data:

1. Manufacturers’ operation and maintenance data is required for all items as called for in the specifications. O & M Manuals shall include manufacturer's name, model number(s), characteristics, manufacturer's agent, service agent, supplier, where and/or what item(s) are used for and description (i.e. surge suppression - switchboard MDPA).

2. Include troubleshooting instructions, list of special tools required, theory of operation, manufacturer's care and cleaning, preventative maintenance instructions, wiring diagrams, and point-to-point schematics.

C. O & M Manuals to include, but are not limited to:

1. Completed forms and information contained in Division 01 General Requirements, Section 017700 and this section of the specifications. Reinforced separation sheets tabbed with the appropriate specification reference number and typed index for each section in the Systems Schedule

a) Project Information Sheet (Exhibit A)

b) O & M Cover Examples (Exhibits B/C)

c) Spare Parts/Maintenance Stock Certification (Exhibit D)

d) Check Out Memo

e) Conductor Insulation Resistance Test Memo

f) Ground Test Information

g) Voltage and Amperage Readings (Tabulated Data)

h) Progress and Record Drawing Certification

2. Shop Drawings: Shop drawings shall be a copy of the final and accepted shop drawing submitted in accordance with Division 01 requirements. These shall be inserted in binder in proper order.

3. Product Data: Product data and/or catalog sheets shall be a copy of the final and accepted submittal submitted in accordance with Division 01 requirements. These shall be inserted in binder in proper order.

4. Warranties/Guarantees: Provide copies of warranties/guarantees in respective location in

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 2

O & M binder, (Power and Lighting) (Systems). Original warranties/guarantees are to be incorporated as noted in Division 01 General Requirements.

5. Copies of electrical panel schedules and electrical panel directories included with the corresponding specification section.

6. Wiring diagrams, schematic, etc. inserted in proper order, for:

a) Time clocks.

b) Photocells.

c) Control devices, motor controls.

d) UPS systems.

e) Emergency Generator systems.

f) Automatic transfer switches.

g) Transformers.

h) Panelboards.

i) Distribution panelboards.

j) Switchboards.

k) Each and every part of Divisions 27 and 28 sections of these Specifications

7. Division 26

a) Section 260519 – Building Wire and Cable

1. Product data and/or catalog sheets on all products applicable to this project.

b) Section 260526 – Grounding and Bonding

1. Product data and/or catalog sheets on all products applicable to this project.

2. Test results on each ground rod.

3. Ground Test Information Form

c) Section 260529 – Hangers and Supports

1. Product data and/or catalog sheets on all products applicable to this project.

d) Section 260533 - Conduit

1. Product data and/or catalog sheets on all products applicable to this project.

e) Section 260534 – Outlet Boxes

1. Product data and/or catalog sheets on all products applicable to this project.

f) Section 260537 – Surface Raceways

1. Product data and/or catalog sheets on all products applicable to this project.

g) Section 260538 – Floor Boxes

1. Product data and/or catalog sheets on all products applicable to this project.

2. Equipment supplier list for section's equipment.

3. Installation/removal instructions.

4. Parts list.

h) Section 260553 – Identification for Electrical Systems

1. Product data and/or catalog sheets on all products applicable to this project.

2. Equipment supplier list for each section's equipment.

i) Section 260573 – Power System Study

1. Copy of complete Study

j) Section 2609 0 – Lighting Control System

1. Product data and/or catalog sheets on all equipment applicable to this project.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 3

2. Equipment supplier list for section's equipment

3. Wiring diagrams.

4. Parts list.

5. Installation/removal instructions.

6. Operation and maintenance requirements

7. Preventative maintenance instructions

8. Check-Out Memo Form.

k) Section 260923 – Occupancy Sensors

1. Product data and/or catalog sheets on all products applicable to this project.

2. Equipment supplier list for section's equipment.

3. Wiring diagrams.

4. Parts list.

5. Operation and maintenance requirements

l) Section 262213 - Dry Type Transformers

1. Product data and/or catalog sheets on equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Recommended periodic testing procedures.

4. Parts list.

5. Any special manufacturer suggested O & M information.

6. Installation/removal instructions.

7. Check-Out Memo Form

m) Section 262416 - Panelboards

1. Product data and/or catalog sheets on equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Internal wiring diagrams.

4. Bus diagrams.

5. Operation and maintenance requirements, instructions, and recommended testing.

6. Parts list.

7. Copy of directory.

8. Voltage and Amperage Readings Tabulated Data Form

9. Check-Out Memo Form

n) Section 262417 – Distribution Panelboards

1. Product data and/or catalog sheets on equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Internal wiring diagrams.

4. Bus diagrams.

5. Operation and maintenance requirements, instructions, and recommended testing.

6. Parts list.

7. Copy of directory.

8. Voltage and Amperage Readings Tabulated Data Form

9. Check-Out Memo Form

10. Overcurrent protective devices; in addition to above provide the following for large circuit breakers:

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 4

(a) Parts list.

(b) Operation and maintenance requirements.

(c) Wiring diagrams.

(d) Testing data.

(e) Installation/removal instructions.

(f) Check-Out Memo Form

o) Section 262716 – Cabinets and Enclosures

1. Product data and/or catalog sheets on products applicable to this project.

2. Equipment supplier list for section’s equipment.

p) Section 262726 – Wiring Devices

1. Product data and/or catalog sheets on all products applicable to this project.

2. Equipment supplier list for section's equipment.

3. Ground fault wiring devices; in addition to above provide:

(a) Wiring diagram.

q) Section 262819 – Enclosed Disconnect Switches

1. Product data and/or catalog sheets on equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

r) Section 264113 – Lightning Protection System

1. Product data and/or catalog sheets on all products applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Shop drawing.

4. Product data on all components.

5. Parts list.

6. Operation and maintenance procedures.

7. Copy of lightning protection system master label.

8. Installer's name, address, etc.

s) Section 264300 – Surge Protection Devices

1. Product data and/or catalog sheets on all equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Parts list.

4. Recommended testing and replacement procedures.

t) Section 265113 – Interior Lighting Fixtures, Lamps and Ballasts

1. Product data and/or catalog sheets on all equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Operation and maintenance requirements/instructions for special light fixtures (these fixtures to be determined by A/E) including:

(a) installation/removal instructions.

(b) special re-lamping instructions.

4. Parts list.

u) Section 265213 – Emergency Lighting Equipment

1. Product data and/or catalog sheets on all equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 5

3. Operation and maintenance requirements/instructions for special light fixtures (these fixtures to be determined by A/E) including:

(a) installation/removal instructions.

(b) special re-lamping instructions.

4. Parts list.

v) Section 265600 – Exterior Lighting

1. Product data and/or catalog sheets on all equipment applicable to this project.

2. Equipment supplier list for section’s equipment.

3. Operation and maintenance requirements/instructions for special light fixtures (these fixtures to be determined by A/E) including:

(a) installation/removal instructions.

(b) special re-lamping instructions.

4. Parts list.

8. Division 28

a) Section 281600 – Intrusion Detection (Pre-Wire)

1. Installer’s name, address, phone, etc. for each system.

2. Authorized representative’s name, address, phone, etc. for system.

3. Product data and/or catalog sheets on equipment applicable to this project.

4. Parts list.

5. Wiring diagrams of panels.

6. Shop drawings as submitted and accepted in submittal process.

b) Section 283100 – Addressable Fire Alarm-Detection System

1. Installer’s name, address, phone, etc. for system.

2. Authorized representative’s name, address, phone, etc. for each system.

3. Product data and/or catalog sheets on equipment applicable to this project.

4. Parts list.

5. Wiring diagrams of panels.

6. Shop drawings as submitted and accepted in submittal process.

1.4 PROCESSING SUBMITTALS

A. Refer to Division 01 General Requirements.

1.5 DELAYS

A. Contractor is responsible for delays in job project accruing directly or indirectly from late submissions or resubmissions of shop drawings, or product data.

1.6 RESUBMITTALS

A. The A/E shall be reimbursed cost to review re-submittals subsequent to the second submittal.

PART 2 - PRODUCTS (Not Applicable)

PART 3 - EXECUTION (Not Applicable)

END OF SECTION

City of Ft. Myers - Warehouse Conversion

260100 - 6

PROJECT INFORMATION SHEET

School: ______________________________________________________________________________

Project Name: ________________________________________________________________________

Project Number: _________________________________

Substantial Completion Date: _______________________

Certificate of final Completion Date: __________________

Name & Address Phone/Fax Contact Authorized Construction Representative Architect Mechanical Engineer

Electrical Engineer

Matern Professional Engineering, Inc.

7680 Cambridge Manor Place Suite 101 Ft. Myers, FL 33907

P: 239.332.1187 F: 239/332.5195

Civil Engineer Structural Engineer Food Service Consultant Other Consultant(s)

Brief Description of Project Scope:

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 7

MANUAL COVER (face)

Project Name

ELECTRICAL

OPERATION AND MAINTENANCE

MANUAL

DATE

(substantial completion date)

Project Name

SYSTEMS

OPERATION AND MAINTENANCE

MANUAL

DATE

(substantial completion date)

MANUAL COVER (spine)

Project Name

E L E C T R I C A L

OPERATION &

MAINTENANCE

MANUAL

Project Name

S Y S T E M S

OPERATION &

MAINTENANCE

MANUAL

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 8

SPARE PARTS / MAINTENANCE STOCK CERTIFICATION

This form verifies that the parts/stock listed below has been delivered to and received by Maintenance.

Original shall be included in the Closeout Documentation Manual. Copies shall also be included in the O & M Manual.

Project Name: ________________________________________________________________

Type/Name of Spare Parts/Attic Stock: _____________________________________________

Specification Reference: _____________________________________________________

Quantity of Spare Parts/Attic Stock: _______________________________________________

Signature below by the Contractor and Subcontractor signifies that the spare parts/maintenance stock, required by the Contract Documents, have been delivered to the Owner.

Contractor/CM

__________________________________________________ Date: ___________________ Authorized Signature, Title

Subcontractor

__________________________________________________ Date: ___________________ Authorized Signature, Title

Signature by the Owner acknowledges receipt of the same spare parts/maintenance stock.

Owner - Department

__________________________________________________ Date: ___________________ Authorized Signature, Title

City of Ft. Myers - Warehouse Conversion

260100 - 9

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 10

CHECK OUT MEMO

Check Out Memo shall be completed and a copy provided to the Owner at the Owner's Performance Verification and Demonstration meeting. A copy shall also be included in the specification section of each O & M Manual for the equipment checked.

Project Name_________________________________________________________________________

Type of Equipment Checked_____________________________________________________________

Equipment Number ____________________________________________________________________

Name of Manufacturer of Equipment_______________________________________________________

Signature below by the manufacturer's authorized representative signifies that the equipment has been satisfactorily tested and checked out on the job by the manufacturer.

1. The attached Test and Data and Performance Verification information was used to evaluate the equipment installation and operation.

2. The equipment is properly installed, has been tested by the manufacturer's authorized representative, and is operating satisfactorily in accordance with all requirements, except for items noted below.*

3. Written operating and maintenance information has been presented and reviewed in detail with the Contractor.

4. Sufficient copies of all applicable operating and maintenance information, parts lists, lubrication checklists, and warranties have been furnished to the Contractor for insertion in the Operation and Maintenance Manuals.

Checked By ______________________________________________________________________ (print name of manufacturer’s representative)

(address manufacturer’s representative)

(telephone, fax, e-mail address)

Signature and Title of Manufacturer’s Representative Date Checked Witnessed By: Signature and Title of Contractor’s Representative)

*EXCEPTIONS NOTED AT TIME OF CHECK-OUT (USE ADDITIONAL PAGE IF NECESSARY)

CONDUCTOR INSULATION RESISTANCE TEST MEMO

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 11

PROJECT NAME______________________________________________________________________

CONDUCTOR FROM TO

SIZE ________________________________________________________________________________

INSULATION TYPE ____________________________________________________________________

INSULATION VOLTAGE RATING_________________________________________________________

DATE____________ TIME____________

WEATHER CONDITIONS_______________________________________________________________

TEST VOLTAGE (DC)__________________________________________________________________

RANGE _____________________________________________________________________________

MEGGER INSTRUMENT/SERIAL NUMBER________________________________________________

TESTING METHODOLOGY _____________________________________________________________

INSULATION RESISTANCE MEASUREMENT (ACCEPTABLE MEASUREMENT NOT TO BE LESS THAN

(1) MEGOHM):

PHASE A TO GROUND _____________

PHASE B TO GROUND _____________

PHASE C TO GROUND _____________

NEUTRAL TO GROUND _____________

ISOLATED GROUND TO GROUND _____________

CONTRACTOR'S REPRESENTATIVE ____________________________________________________

DATE____________

OWNER'S REPRESENTATIVE __________________________________________________________

DATE:____________

ENGINEER'S REPRESENTATIVE:________________________________________________________

DATE:_____________

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 12

GROUND TEST INFORMATION

PROJECT NAME:

GROUND TYPE:

TEST BY:

DATE OF TEST:

GROUND LOCATION:

GROUND TYPE (Rod, Water pipe, etc.):

PRIOR TO CONNECTION TO SYSTEM

GROUND (OHMS)

AFTER CONNECTION TO SYSTEM

GROUND (OHMS)

WEATHER CONDITIONS (Wet/Dry) ____________

SOIL CONDITIONS (Wet/Dry) ____________

CONTRACTOR’S REPRESENTATIVE__________________________________________________

DATE ________________________

ENGINEER'S REPRESENTATIVE_______________________________________________________

DATE:_________________________

OWNER'S REPRESENTATIVE _________________________________________________________

DATE__________________________

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 13

VOLTAGE AND AMPERAGE READINGS (TABULATED DATA)

PROJECT NAME _____________________________________________________________________

SWITCHGEAR/PANELBOARD __________________________________________________________

FULL LOAD AMPERAGE READINGS:

DATE

TIME

PHASE A ______________________

B ______________________ C ______________________ N ______________________

GROUND _______________

FULL LOAD VOLTAGE READINGS:

DATE _______________

TIME _______________

PHASE A TO N A TO B

B TO N A TO C

C TO N B TO C

VOLTAGE AT THE END OF THE LONGEST BRANCH _______________________________________

TYPE OF LOAD ______________________________________________________________________

NO LOAD VOLTAGE READINGS:

DATE_________________

TIME _________________

PHASE A TO N A TO B

B TO N A TO C

C TO N B TO C

ENGINEER’S REPRESENTATIVE ________________________________________________________

DATE _______________

OWNER’S AUTHORIZED REPRESENTATIVE ______________________________________________

DATE _______________

CONTRACTOR’S REPRESENTATIVE _____________________________________________________

DATE _______________

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 14

PROGRESS AND RECORD DRAWING CERTIFICATION

NAME OF PROJECT: _________________________________________________________________

DIVISION NUMBER AND NAME: ________________________________________________________

This is to certify that the attached marked-up design prints were marked as the items were installed at the site during construction, and that these prints represent as accurate "As-Builts" record of the work as actually installed. One copy will be turned over to the Owner at the instruction in Operation Conference. The duplicate copy is for the Engineer's file.

General Contractor

By: Authorized Signature And Title

Date

Subcontractor

By: Authorized Signature And Title

Date

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260100 - 15

This Page Intentionally Left Blank

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 1

SECTION 260500 - COMMON WORK RESULTS FOR ELECTRICAL

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions, Division 01, Division 26, Division 27 and Division 28 Specification Sections, apply to this Section.

1.2 SUMMARY

A. The work required under this Section shall include all materials, labor and auxiliaries required to install a complete and properly operating electrical system.

B. The Contractor shall furnish, perform, or provide all labor including planning, purchasing, transporting, storing, installing, testing, cutting and patching, trenching, excavating, backfilling, coordination, field verification, equipment (installation and safety), supplies, and materials necessary for the correct installation of complete electrical systems (as described or implied by these specifications and the applicable drawings) in strict accordance with applicable codes, which may not be repeated in these specifications, but are expected to be common knowledge of qualified Bidders.

C. The Division 26 Contract Documents refer to work required in addition to (or above) the minimum requirements of the NEC 2008 Edition and applicable local codes. All work shall comply with all applicable codes as a minimum and with the additional requirements called for in these Contract Documents.

D. Only trained and licensed personnel shall be used by the Contractor to perform work. The Contractor shall not perform work, which violates applicable codes, even if called for in the Contract Documents. The Contractor's Bid shall include work necessary to completely install the electrical systems indicated by the Contract Documents in accordance with applicable codes.

E. Refer to other division sections for additional work requirements.

F. Coordinate and verify power and telephone company service requirements prior to bid. Bid to include all work required for complete and properly operating systems.

G. Connections of all items using electric power shall be included under this division of the specifications, including necessary wire, conduit, circuit protection, disconnects and accessories.

Securing of roughing-in drawings and connection information for equipment involved shall also be included under this division. See other divisions for specifications for electrically operated equipment.

H. The Contractor shall provide and install panic hardware on all electrical room doors where the electrical room houses equipment rated 1200 amps or more per NEC 110.26. All electrical room doors shall open in the direction of egress.

1.3 WORK SEQUENCE

A. Install work in stages and/or phases to accommodate Owner's occupancy requirements.

Coordinate electrical schedule and operations with Owner and Architect/Engineer.

1.4 CODES, FEES, AND STANDARDS

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 2

A. Obtain permits and request inspections from Authority Having Jurisdiction and applicable utility companies.

B. Pay for all required licenses, fees, and inspections.

C. Contact the utility companies to determine if fees, charges or costs are required by the utility company for permanent power and for temporary power, installations and hook-ups. These fees, charges or costs shall be included in Contractor's bid.

D. Material shall be new and free of defects with UL listing or be listed with an approved, nationally recognized Electrical Testing Agency if and only if UL Listing is not available for material.

1.5 PROJECT/SITE CONDITIONS

A. Install Work in locations shown or described in the Contract Documents, unless prevented by project conditions.

B. The Contractor shall install all equipment so that all code required and manufacturer recommended servicing clearances are maintained. Contractor shall be responsible for the proper arrangement and installation of all equipment within any designated space. Should the Contractor determine that a departure from the Contract Documents is necessary, he shall submit to the A/E, for approval, detailed drawings of his proposed changes with his written reasons for the changes.

No changes shall be implemented by the Contractor without the issuance of the required drawings, clarifications, and/or change orders.

C. The Contractor shall verify finish dimensions at the project site in preference to using dimensions noted on Contract Documents.

1.6 CONTRACT DOCUMENTS

A. These specifications and applicable drawings shall be considered supplementary, one to the other and are considered Contract Documents. All workmanship, methods, and/or material described or implied by one and not described or implied by the other shall be furnished, performed, or otherwise provided just as if it had appeared in both sets of documents.

B. Where a discrepancy or conflict is found between these specifications and any applicable drawing, the Contractor shall notify the A/E in written form. In the event that a discrepancy exists between specifications and any applicable drawing, the most stringent requirement shall govern unless the discrepancy conflicts with applicable codes wherein the code shall govern. The most stringent requirement shall be that work, product, etc which is the most expensive and costly to implement.

C. The drawings are diagrammatic and are not intended to include every detail of construction, materials, methods, and equipment. They indicate the result to be achieved by an assemblage of various systems. Coordinate equipment locations with Architectural and Structural drawings.

Layout equipment before installation so that all trades may install equipment in spaces available.

Coordinate installation in a neat and workmanlike manner.

D. Wiring arrangements for equipment shown on the drawings are intended to be diagrammatic and do not show all required conductors and functional connections. All wiring and appurtenances required for the proper operation of all equipment to be connected shall be provided.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 3

E. Specifications require the Contractor to provide shop drawings which shall indicate the fabrication, assembly, installation, and erection of a particular system's components. Drawings that are part of the Contract Documents shall not be considered a substitute for required shop drawings, field installation drawings, code requirements, or applicable standards.

F. Locations indicated for outlets, switches, and equipment are approximate and shall be verified by instructions in specifications and notes on the drawings. Where instructions or notes are insufficient to locate the item, notify the A/E.

G. The Contractor shall take finish dimensions at the project site in preference to scaling dimensions on the drawings.

H. Where the requirements of another Division, section, or part of these specifications exceed the requirements of this Division those requirements shall govern.

1.7 MATERIALS AND EQUIPMENT

A. Material shall be new (except where specifically noted, shown or specified as "Reused") and/or denoted as existing) and shall be UL listed and bear UL label. Where no UL label listing is available for a particular product, material shall be listed with an approved, nationally recognized Electrical Testing Agency. Where no labeling or listing service is available for certain types of equipment, test data shall be submitted to prove to the Engineer that equipment meets or exceeds available standards.

B. Where Contract Documents list design selection or manufacturer, type, this model shall set the standard of quality and performance required. Where no brand name is specified, the source and quality shall be subject to A/E's review and acceptance. Where Contract Documents list accepted substitutions, these items shall comply with requirements in Division 01.

C. When a product is specified to be in accordance with a trade association or government standard and at the request of A/E the Contractor shall furnish a certificate that the product complies with the referenced standard and supporting test data to substantiate compliance.

D. Where multiple items of the same equipment or materials are required, they shall be the product of a single Manufacturer.

E. Where the Contract Documents require materials and/or equipment installed, pulled, or otherwise worked on, the materials and/or equipment shall be furnished and installed by the Contractor responsible for Division 26 methods and materials unless specifically noted otherwise.

F. Where the contract documents refer to the terms "furnish," "install," or "provide," or any combination of these terms the materials and/or equipment shall be supplied and delivered to the project including all labor, unloading, unpacking, assembly, erection, anchoring, protecting supplies and materials necessary for the correct installation of complete system unless specifically noted otherwise.

G. Before the Contractor orders equipment, the physical size of specified equipment shall be checked to fit spaces allotted on the drawings, with NEC working clearances provided. Internal access for proposed equipment substitutions shall be provided.

H. Electrical equipment shall be protected from the weather during shipment, storage, and construction per manufacturer's recommendations for storage and protection. Should any apparatus be subjected to possible damage by water, it shall be thoroughly dried and put through a dielectric test, at the expense of the Contractor, to ascertain the suitability of the apparatus, or it

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 4 shall be replaced without additional cost to the Owner. No additional time will be allowed and the project completion date shall be maintained.

I. Inspect all electrical equipment and materials prior to installation. Damaged equipment and materials shall not be installed or placed in service. Replace or repair and test damaged equipment in compliance with industry standards at no additional cost to the Owner. Equipment required for the test shall be provided by the Contractor.

J. Material and equipment shall be provided complete and shall function up to the specified capacity/function. Should any material and/or equipment as a part or as a whole fail to meet performance requirements, replacements shall be made to bring performance up to specified requirements. Damages to finish by such replacements, alterations, or repairs shall be restored to prior conditions, at no additional cost to the Owner.

K. Where tamperproof screws are specified or required, Phillips head or Allen head devices shall not be accepted. For each type used, provide Owner with three tools. Owner will designate the specific hardware design to correspond with existing devices elsewhere in the building, to limit special tool requirements.

L. Where the Contract Documents denote equipment and/or material to be 'new' and/or 'existing' and also provide no denotation for other equipment as to it being 'new' and/or 'existing,' this is not to infer that the non-denoted equipment is either new or existing, or opposite of the equipment that is denoted. The use of the terms 'new' or 'existing' is meant to clarify denoted equipment/materials for that item only, and the lack of the terms 'new' or 'existing' in relation to identifiers/notes/denotations on the drawings is not to infer that this non-denoted equipment or materials is new or existing.

1.8 MISCELLANEOUS CIRCUITS REQUIRED

A. Provide 120 volt, 20 amp circuit to post indicator valves (whether shown on drawings or not).

Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with civil engineer (and drawings/specifications) or fire protection engineer (and drawings/specifications) prior to bid and provide all electrical. Coordinate final location and electrical requirements with valve installer after bid and provide all electrical. Nearest panel to be nearest emergency panel, when building has emergency generator system.

B. Provide 120 volt, 20 amp circuit to fire protection system panel and bell (whether shown on drawings or not). Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with civil engineer (and drawings/specifications) or fire protection engineer (and drawings/specifications) prior to bid and provide all electrical. Coordinate final location and electrical requirements with panel installer after bid and provide all electrical. Nearest panel to be nearest emergency panel, when building has emergency generator system.

C. Provide 120 volt, 20 amp circuit to intercom system panel (whether shown on drawings or not).

Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with intercom system engineer (and drawings/specifications) prior to bid and provide all electrical. Coordinate final location and electrical requirements with panel installer after bid and provide all electrical.

Nearest panel to be nearest emergency panel, when building has emergency generator system.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 5

D. Provide 120 volt, 20 amp circuit to all fire alarm panels, remote panels, etc. (whether shown on drawings or not). Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with fire alarm system engineer (and drawings/specifications) prior to bid and provide all electrical.

Coordinate final location and electrical requirements with panel installer after bid and provide all electrical. Nearest panel to be nearest emergency panel, when building has emergency generator system.

E. Provide 120 volt, 20 amp circuit to fire and smoke dampers (whether shown on drawings or not).

Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with fire protection engineer (and drawings/specifications) prior to bid and provide all electrical. Coordinate final location and electrical requirements with damper installer after bid and provide all electrical. Nearest panel to be nearest emergency panel, when building ahs emergency generator system.

F. Provide 120 volt, 20 amp circuit to building control panels for HVAC system (whether shown on drawings or not). Connect to spare 20 amp, 1 pole circuit breaker in nearest 120 volt panel. Re-label circuit breaker accordingly. Provide locking device on breaker. Coordinate location with fire protection engineer (and drawings/specifications) prior to bid and provide all electrical.

Coordinate final location and electrical requirements with damper installer after bid and provide all electrical.

1.9 SUPERVISION OF THE WORK

A. Reference the General Conditions for additional requirements.

B. The Contractor shall provide experienced, qualified, and responsible supervision for work. A competent foreman shall be in charge of the work in progress at all times. If, in the judgment of the A/E, the foreman is not performing his duties satisfactorily, the Contractor shall immediately replace him upon receipt of a letter of request from the A/E. Once a satisfactory foreman has been assigned to the work, he shall not be withdrawn by the Contractor without the written consent of the A/E.

C. Provide field superintendent who has had a minimum of four years previous successful experience on projects of comparable size and complexity. Superintendent shall be on the site at all times during construction and must have an active Journeyman's Electrical License.

D. Superintendent shall be employed by a Florida Registered Electrical Contractor (ER) or Florida Certified Electrical Contractor (EC).

1.10 COORDINATION

A. Provide all required coordination and supervision where work connects to or is affected by work of others, and comply with all requirements affecting this Division. Work required under other divisions, specifications or drawings to be performed by this Division shall be coordinated with the Contractor and such work performed at no additional cost to Owner including but not limited to electrical work required for:

1. Door Hardware.

2. Roll-up Doors.

3. Fire Shutters.

4. Roll-up Grilles.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 6

5. Elevators.

6. Mechanical Division of the Specifications.

7. Landscape Architect Drawings.

8. Kitchen Equipment.

9. Millwork Design Drawings and Shop Drawings.

B. Contractor shall obtain set of Contract Documents from Owner for all areas of work noted above and include all electrical work in bid whether included in Division 26 Contract Documents or not.

C. Installation studies shall be made to coordinate the electrical work with other trades. Work shall be preplanned. Unresolved conflicts shall be referred to the A/E prior to installation of the equipment.

D. For locations where several elements of electrical or combined mechanical and electrical work must be sequenced and positioned with precision in order to fit into the available space, prepare coordination drawings at 1/4 inch scale showing the actual physical dimension required for the installation to assure proper integration of equipment with building systems and NEC required clearances. Coordination drawings shall be provided for all areas determined by the A/E.

E. Secure accepted shop drawings from all required disciplines and verify final electrical characteristics before roughing power feeds to any equipment. When electrical data on accepted shop drawings differs from that shown or called for in Construction Documents, make adjustments to the wiring, disconnects, and branch circuit protection to match that required for the equipment installed.

F. Damage from interference caused by inadequate coordination shall be corrected at no additional cost to the Owner and the contract time for completion will not be extended.

G. The Contractor shall maintain an up-to-date set of Contract Documents and Specifications of all trades on the project site, including Architectural, Structural, Mechanical, Electrical and, where provided Interior Design Drawings.

H. It is the responsibility of this Contractor to coordinate the exact required location of floor outlets, floor ducts, floor stub-ups, etc. with Owner and Architect (and receive their written approval) prior to rough-in. Locations indicated in Contract Documents are approximate.

I. The Contract Documents describe specific sizes of switches, breakers, fuses, conduits, conductors, motor starters and other items of wiring equipment. These sizes are based on specific items of power consuming equipment (heaters, lights, motors for fans, compressors, pumps, etc.).

The Contractor shall coordinate the requirements of each load with each load's respective circuitry shown and with each load's requirements as noted on its nameplate data and manufacturer's published electrical criteria. The Contractor shall adjust circuit breaker, fuse, conduit, and conductor sizes to meet the actual requirements of the equipment being provided and installed and change from single point to multiple points of connection (or vice versa) to meet equipment requirements. Changes due to these coordination efforts shall be made at no additional cost to the Owner.

1.11 PROVISION FOR OPENINGS

A. Locate openings required for work. Provide sleeves, guards or other accepted methods to allow passage of items installed.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 7

B. Coordinate with roofing Contractor on installation of electrical items which pierce roof. Roof penetrations shall not void warranty. The use of pitch pockets is not acceptable.

C. Where work pierces waterproofing, it shall maintain the integrity of the waterproofing.

Coordinate roofing materials which pierce roof for compatibility with membrane or other roof types with Contractor prior to installation.

1.12 CONCRETE PADS

A. Furnish and install reinforced concrete housekeeping pads for transformers, switchgear, and other free-standing equipment. Unless otherwise noted, pads shall be four inches high and shall exceed dimensions of equipment being set on them, including future sections, by six inches each side, except when equipment is flush against a wall where the side against the wall shall be flush with the equipment. Pads shall be reinforced with W1.4 x 1.4 6 x 6 welded wire mesh. Chamfer top edges 1/2 inch. Trowel all surfaces smooth. Provide 3000 psi concrete.

B. Contractor to provide/install concrete pad for exterior pad mount transformers as required by power company.

C. Contractor to provide/install concrete pad for generators as recommended by generator manufacturer and structural engineer (8 inch minimum).

1.13 SURFACE MOUNTED EQUIPMENT

A. Surface mounted fixtures, outlets, cabinets, conduit, panels, etc. shall have finish as directed by Engineer.

1.14 CUTTING AND PATCHING

A. New Construction:

1. Reference Division 01 - General Requirements.

2. Cutting of work in place shall be cut, drilled, patched and refinished by trade responsible for initial installation.

3. The Contractor shall be responsible for backfilling and matching new grades with adjacent undisturbed surface.

1.15 TRENCHING

A. Trench excavation in excess of 5 feet deep shall comply with OSHA Standard 29 C.F.R.s. 1926.

650 Subpart P.

1.16 INSTALLATION

A. Erect equipment to minimize interferences and delays in execution of the work.

B. Take care in erection and installation of equipment and materials to avoid marring finishes or surfaces. Any damage shall be repaired or replaced as determined by the A/E at no additional cost to the Owner.

C. Equipment requiring electrical service shall not be energized or placed in service until A/E is notified and is present or have waived their right to be present in writing. Where equipment to be placed in service involves service or connection from another Contractor or the Owner, the Contractor shall notify the Owner in writing when the equipment will be ready. The Owner shall be notified as far in advance as possible of the date the various items of equipment will be

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 8 complete.

D. Equipment supports shall be secured and supported from structural members except as field accepted by the A/E in writing.

E. Plywood material shall not be used as a backboard for mounting panel boards, disconnects, motor starters, and dry type transformers. Provide "cast in place" type inserts or install expansion type anchor bolts. Electrical equipment shall not be mounted directly to drywall for support without additional channels as anchors. Channels shall be anchored to the floor and structure above.

Panelboards and terminal cabinets shall be provided with structural framing located within drywall partitions.

F. The Contractor shall keep the construction site clean of waste materials and rubbish. Upon completion of the work, the Contractor shall remove from the site all debris, waste, unused materials, equipment, etc.

G. Inserts, pipe sleeves, supports, and anchorage of electrical equipment shall be provided. Where items are to be set or embedded in concrete or masonry, the items shall be furnished and a layout made prior to the setting or embedment thereof, so as to cause no delay.

1.17 PROGRESS AND RECORD DRAWINGS

A. Keep two sets of prints on the job, and neatly mark up design drawings each day as components are installed. Different colored pencils shall be used to differentiate each system of electrical work. Cost of prints and this labor task shall be included under this Division. All items on Progress Drawings shall be shown in actual location installed. Change the equipment schedules to agree with items actually furnished.

B. Prior to request for substantial completion observation, furnish a set of neatly marked prints showing "as-installed" (as-built) condition of all electrical installed under this Division of the specifications. Marked up prints are to reflect all changes in work including change orders, field directives, addenda from bid set of Contract Documents, request for information responses, etc.

Marked up set of prints are to show:

1. All raceways 1-1/2 inch and above, exactly as installed.

2. All site raceways exactly as installed.

3. Any combining of circuits (which is only allowed by specific permission) or change in homerun outlet box shall be made on as-builts.

4. Any circuit number changes on plan shall be indicated on as-builts.

5. Any panelboard schedule changes shall be indicated on as-builts.

C. Marked up prints as noted above are to be submitted to A/E for acceptance. Contractor shall review submitted as-builts with Engineer in the field. Contractor shall verify every aspect for accuracy.

D. After acceptance of marked up prints by A/E with all changes, additions, etc. included on accepted marked up prints, submit prior to request for final payment and/or request for final observation.

E. Where the Contractor has failed to produce representative "as-built" drawings in accordance with requirements specified herein, the Contractor shall reimburse Engineer all costs to produce a set

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 9 of "as-built" drawings to the Architect/Owner satisfaction.

1.18 "OBSERVATION OF WORK" REPORT

A. Reference the General Conditions.

B. Items noted by A/E or his representative during construction and before final acceptance which do not comply with the Contract Documents will be listed in an Observation of Work report which will be sent to the Contractor for immediate action. The Contractor shall correct all deficiencies in a prompt concise manner. After completion of the outstanding items, provide a written confirmation report for each item. The report shall indicate each item noted, and method of correction. Enter the date on which the item was corrected, and return the signed reports so items can be rechecked. Failure to correct the deficiencies in a prompt concise manner or failure to return the signed reports shall be cause for disallowing request for payments.

C. Items noted after acceptance during one-year guarantee period shall be checked by the Contractor in the same manner as above. The signed reports are to be returned by him when the items have been corrected.

1.19 SYSTEMS WARRANTY

A. Reference the General Conditions.

B. The work shall include a one-year warranty. This warranty shall be by the Contractor to the Owner for any defective workmanship or material which has been furnished at no cost to the Owner for a period of one year from the date of substantial completion of System. Warranty shall not include light bulbs in service after one month from date of substantial completion of the System. Explain the provisions of warranty to the Owner at the "Demonstration of Completed System" meeting to be scheduled with the Owner upon project completion.

C. Where items of equipment or materials carry a manufacturer's warranty for any period in excess of twelve months, then the manufacturer's warranty shall apply for that particular piece of equipment or material.

D. Where extended warranties or guaranties are called for, furnish three copies to be inserted in Operation and Maintenance Manuals.

E. All preventative maintenance and normal service will be performed by the Owner's maintenance personnel after final acceptance of the work which shall not alter the Contractor's warranty.

1.20 WASTE MATERIALS DISPOSAL

A. Contractor shall include in his bid the transport and disposal or recycling of all waste materials generated by this project in accordance with all rules, regulations and guidelines applicable.

Contractor shall comply fully with Florida statute 403.7186 regarding mercury containing devices and lamps. Lamps, ballasts and other materials shall be transported and disposed of in accordance with all DEP and EPA guidelines applicable at time of disposal. Contractor shall provide owner with written certification of accepted disposal.

1.21 SUBSTANTIAL COMPLETION

A. The Contractor shall be fully responsible for contacting all applicable parties to schedule required observations of the work by Engineer.

City of Ft. Myers - Warehouse Conversion Bid / Permit - Construction Documents

260500 - 10

B. Work shall be complete as required by authorities having jurisdiction and the general conditions of the contract prior to request for substantial completion observation. Work must be deemed substantially complete by A/E to fulfill requirements.

1.22 PROHIBITION OF ASBESTOS AND PCB

A. The use of any process involving asbestos or PCB, and the installation of any product, insulation, compound of material containing or incorporating asbestos or PCB, is prohibited. The requirements of this specification for complete and operating electrical systems shall be met without the use of asbestos or PCB.

B. Prior to the Final Review field visit, the Contractor shall certify in writing that the equipment and materials installed in this Project contain no asbestos or PCB’s. Additionally, all manufacturers shall provide a statement with their submittal that indicates that their product contains no asbestos or PCB’s. This statement shall be signed and dated by a duly authorized agent of the manufacturer.

PART 2 - PRODUCTS (Not Applicable)

PART 3- EXECUTION (Not Applicable)

City of Ft. Myers -…