SIR 6973GH-18-R-00009.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

AC-18-00015

AAQ-811 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

MPB ROOM 380

AAQ0811-AFN

OKLAHOMA CITY OK 73125

FAA Customer Service Desk (AAQ-700)

Room 313, Multi-Purpose Building 6500 S. MacArthur Blvd Oklahoma City, OK 73169

Connie Houpt 405-954-7820

13-007860 x 01/09/2018 75

PURCHASE REQUEST NO.

6973GH-18-R-00009

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

(a) Specifications titled, "Renovation of MPB-24 (Multi-Purpose Building)," dated

December 20, 2017, 1483 pages

(b) Drawings titled, "MMAC MPB-24 (Multi-Purpose Building) Renovation," dated

December 20, 2017, 583 pages

ESTIMATED PRICE RANGE: $45,000,000 to $50,000,000

FULL-AND-OPEN COMPETITION

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

30 1390 calendar days and complete it within ________________ ________________ calendar days after receiving

CLAUSE 3.2.2.3-7 ALT 1

02/09/2018 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

AAQ-811 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

MPB ROOM 380

AAQ811-AFN

OKLAHOMA CITY OK 73125

Connie M. Houpt

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 75

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-18-R-00009

(A) (B) (C) (D) (E) (F)

Delivery Location Code: A6973M4F

A6973M4F

6973M4 FAA AERO CENTER AMP 1

OFC OF FACILITY MGMT HDQS RM 316

6500 S MACARTHUR BLVD

OKLAHOMA CITY OK 731696901 US

0001 MPB Phase 1: Basement Renovation

ISO9000: N Electronic & IT: 03

Delivery: 300 Days After Notice to Proceed

0002 OPTIONAL LINE ITEM

MPB Phase 2: 1st, 2nd and 3rd Floor Renovation

ISO9000: N Electronic & IT: 03

(Option Line Item)

(Expected Exercise Date/Days After Award: ) 300

Days After Award

Delivery: 10/18/2021

0003 OPTIONAL LINE ITEM

Electroglazing at Stair Curtain Wall

ISO9000: N Electronic & IT: 03

(Option Line Item)

(Expected Exercise Date/Days After Award: ) 300

Days After Award

Delivery: 10/18/2021

0004 OPTIONAL LINE ITEM

Install New Pavers over Waterproofing Membrane at the Exterior

ISO9000: N Electronic & IT: 03

(Option Line Item)

(Expected Exercise Date/Days After Award: ) 300

Days After Award

Delivery: 10/18/2021

0005 OPTIONAL LINE ITEM

Loading Dock Area Vertical Wall Acrylic Coating

System

ISO9000: N Electronic & IT: 03

(Option Line Item)

(Expected Exercise Date/Days After Award: ) 300

Continued ...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

4 75

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-18-R-00009

(A) (B) (C) (D) (E) (F)

Days After Award

Delivery: 10/18/2021

Section A - Solicitation/Contract Form

Clauses

Section B - Supplies or Services/Prices

Section B - Schedule

PART I - SECTION B

SUPPLIES/SERVICES & PRICE/COST

The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project; Renovation of MPB-24 (Multi-Purpose Building) at the Mike Monroney Aeronautical Center, Oklahoma City, OK, set forth below in accordance with (IAW) the attached project manual, drawings, and the other terms, conditions, and provisions as set forth herein.

The contractor shall complete the entire Work ready for occupancy and use not later than 300 calendar days after receiving notice to proceed.

ITEM NO. DESCRIPTION Unit TOTAL AMOUNT

0001 FIRM FIXED PRICE LS $

Phase 1, Basement Renovation Contractor shall provide all labor, materials, and equipment necessary to renovate the basement of MPB IAW the Technical Specification, Renovation of MPB-24 (Multi-Purpose Building) (Section J, Attachment 1) and Technical Drawings & Configuration, MPB-24 (Multi-Purpose Building) Renovation (Section J, Attachment 2)

OPTIONAL LINE ITEMS (Per Specifications Section 010300)

0002 FIRM FIXED PRICE LS $

Phase 2, 1st, 2nd & 3rd Floor Renovation Contractor shall provide all labor, materials, and equipment necessary to renovate the 1st, 2nd & 3rd floors of MPB IAW the Technical Specification, Renovation of MPB-24 (Multi-Purpose Building) (Section J, Attachment 1) and Technical Drawings & Configuration, MPB-24 (Multi-Purpose Building) Renovation (Section J, Attachment 2) *This is an optional line item to be exercised at the discretion of the Government

0003 *OPTION ITEM – FIRM FIXED PRICE LS $

Loading Dock Area Vertical Wall Acrylic Coating System Contractor shall provide all labor, materials, and equipment necessary to construct Loading Dock Area Vertical Wall Acrylic Coating System IAW the Technical Specification, Renovation of MPB-24 (Multi-Purpose Building) (Section J, Attachment 1) and Technical Drawings & Configuration, MPB-24 (Multi-Purpose Building) Renovation (Section J, Attachment 2) *This is an optional line item to be exercised at the discretion of the Government

0004 *OPTION ITEM – FIRM FIXED PRICE LS $

Electroglazing at Stair Curtain Wall Contractor shall provide all labor, materials, and equipment necessary to construct Electroglazing at Stair Curtain Wall IAW the Technical Specification, Renovation of MPB-24 (Multi-Purpose Building) (Section J, Attachment 1) and Technical Drawings & Configuration, MPB-24 (Multi-Purpose Building) Renovation (Section J, Attachment 2) *This is an optional line item to be exercised at the discretion of the Government

0005 *OPTION ITEM – FIRM FIXED PRICE LS $

Install New Pavers over W.P. Membrane at the Exterior Perimeter Contractor shall provide all labor, materials, and equipment necessary to construct Install New Pavers over W.P. Membrane at Exterior Perimeter IAW the Technical Specification, Renovation of MPB-24 (Multi-Purpose Building) (Section J, Attachment 1) and Technical Drawings & Configuration, MPB-24 (Multi-Purpose Building) Renovation (Section J, Attachment 2) *This is an optional line item to be exercised at the discretion of the Government

UNIT PRICES (Per Specifications Section 012700)

0006 INSTALL FLOOR LEVELING MATERIAL OVER $__________ / SQ FT

EXISTING STRUCTURAL SLAB TO RECEIVE

NEW WATERPROOFING MEMBRANE

FOLLOWING TOPPING SLAB REMOVAL AT

THE FIRST FLOOR PERIMETER.

0007 AFTER HOURS AND WEEKEND PROJECT $__________ / HR

CONSTRUCTION ACTIVITIES

CLIN Worksheet The contractor shall furnish a price for all labor, tools, materials, equipment, and supplies, necessary to accomplish the following breakout items. The pricing of these items will not affect the project award. These prices should be included in prices above and are only for FAA internal use.

0001 Basement Renovation, Phase 1

Basement Mechanical Replacement (including LS $ installation of mechanical shaft walls from basement to 1st floor, AHU-B-1 replacement, AHU-B2 replacement, associated housekeeping pads and duct modifications in basement):

Basement Grinder Pump and Sewerage Ejector: LS $

Switchgear Retrofill, Phase 1 portion: LS $

Transformer Relocation (including moving LS $ transformers from basement to exterior and demolition of interior equipment vault):

Mechanical Replacement, Phase 1 portion: LS $

Plumbing System Replacement, Phase 1 portion: LS $

0002 1st, 2nd & 3rd Floor Renovation, Phase 2

Roof Top AHU Support Steel (including support steel LS $ frame, walk grating, perimeter safety rail and screen wall support steel):

Building Structural Deficiencies Correction LS $ (Including slab demolition, installation of new shear walls, expansion joint, drilled piers, seismic bracing – portal framing, increased steel at courtyard and window openings ):

Site Utility Lines: LS $

Exterior Wall Panels and Glazing (including LS $ demolition of existing windows and storefront, demolition of precast wall panels, installation of wall panels, column covers and glazing):

Roof Repairs: LS $

Exterior Concrete Paving and Walks: LS $

Switchgear Retrofill, Phase 2 portion: LS $

Courtyard Leak Repair (including demolition of brick LS $ veneer, demolition of concrete topping slab, replacement of concrete topping slab, repair of waterproofing and replacement of veneer):

Mechanical Replacement, Phase 2 portion (including LS $ shaft walls from floors 1 to roof and roof hood):

Plumbing System Replacement, Phase 2 portion: LS $

Elevators: LS $

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications

Scope of Work

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE AT

THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

C.1 SCOPE OF WORK

The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project set forth below, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein.

C.2 BID VS. OFFER

References to the terms “bid”, “bidder”, etc. throughout the specification are intended to mean “offer”, “offeror”, etc.

C.3 SPECIFICATIONS AND/OR DRAWINGS

The following specifications and/or drawings are applicable to this acquisition.

(a) Specifications titled, "Renovation of MPB-24 (Multi-Purpose Building)," dated December 20, 2017, 1495 pages

(b) Drawings titled, "MMAC MPB-24 (Multi-Purpose Building) Renovation," dated December 20, 2017, 583 pages.

Section D - Packaging and Marking

Clause List

D - SECTION D - N/A

There are no applicable Section D clauses.

Section E - Inspection and Acceptance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.4-1 CONTRACTOR INSPECTION REQUIREMENTS (APR 1996)

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

F.1 WORKING HOURS

(a) Work at the site shall be accomplished between the hours of 6:00 a.m. and 6:00 p.m., Monday through Friday, excluding federally established holidays, except when prior approval has been obtained from the Contracting Officer. Approval for overtime work shall not be construed as an agreement for payment of overtime work. No Work, with the exception of the demolition work as described below, shall occur at night, or on Saturday’s, Sunday’s or designated government holidays unless approved by the Contracting Officer seven (7) days in advance.

(b) All demolition including the removal of the existing concrete slab, sub-soil removal below existing concrete slab, demolition and removal of interior GWB and CMU partitions, windows, floor, wall and ceiling finishes, HVAC equipment and ductwork, plumbing and waste lines and vents, electrical demolition and removal, and any or all other items related to demolition, shall be between the hours of 6:00 P.M and 6:00 A.M Monday thru Friday.

Work on the demolition may also be accomplished on weekends and approved government holidays. Work during these times (weekend and government holidays), must be pre-approved and scheduled in advance. Provide a minimum of seven (7) days prior notice to AMP-400, Project Manager, Mike Monroney Aeronautical Center, 405- 954-4574 to coordinate scheduling of any work to be done outside of the occupants normal working hours.

F.2 UTILITY OUTAGES AND SHUTDOWN

Coordinate with the Project Manager at 405-954-4574. Outages affecting FAA Operations are required to be accomplished at night, or on Saturday’s, Sunday’s or designated government holidays. Prior to any outage or shutdown, seven (7) working days notification must be made to coordinate scheduling of any Work to be performed during any hours.

F.3 CONTRACTOR USE OF PREMISES

(a) General: Limit use of site and premises to allow:

(1) Owner occupancy: The Print Room, Studio Graphics in the Basement and Data Center on the First Floor of the building will be occupied throughout the duration of this project. The Contractor shall make every effort to not disrupt the day to day operations of this facility. The Contractor will be responsible for providing safety barriers, warnings, temporary lighting, heating and other appurtenances necessary to keep the occupants safe.

Contractor shall provide temporary dust-proof partitions to demark exit travel and maintain safe egress from the building for the second floor occupants of the building at all times. At least three means of egress from each floor are required to be accessible at all times.

(2) Work by others:

(A) FAA IT personnel will be installing telecommunications and security equipment.

(B) Abatement of asbestos containing material (ACM); however, ACM removal must be accommodated by the contractor in the overall construction schedule.

(b) Access to Site: Coordinate site access and staging areas with FAA project manager prior to commencement of work.

F.4 CONTRACTOR’S CONSTRUCTION SCHEDULE

The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for “Commencement of Work” in accordance with Clause 3.2.2.3-56, which is incorporated by reference.

Section G - Contract Administration Data

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.1-22 CONTRACTING OFFICER'S REPRESENTATIVE (APR 2012)

(a) The Contracting Officer may designate other Government personnel (known as the Contracting Officer's Representative) to act as his or her authorized representative for contract administration functions which do not involve changes to the scope, price, schedule, or terms and conditions of the contract. The designation will be in writing, signed by the Contracting Officer, and will set forth the authorities and limitations of the representative(s) under the contract. Such designation will not contain authority to sign contractual documents, order contract changes, modify contract terms, or create any commitment or liability on the part of the Government different from that set forth in the contract.

(b) The Contractor shall immediately contact the Contracting Officer if there is any question regarding the authority of an individual to act on behalf of the Contracting Officer under this contract.

(End of Clause)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL 2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

G.1 PAYMENT PROCEDURES

(a) Payment for work performed or items furnished under this contract is subject to approval by the Contracting Officer. The contractor shall submit electronic invoices, including applications for finance payments, to FAA, Facilities & Aviation Safety Contracting Section (AAQ-811).

(b) The contractor shall submit electronic invoices, including applications for finance payments, directly to Financial Operations Division (AMK-311), 9-AMZ-FAA-APInvoices@FAA.GOV.

(c) Each invoice, including applications for finance payments, must reflect the contract number, delivery order number, and a description of the work, services, or items being invoiced.

(d) Contract Modifications (Change Orders) that include more than one proposed change, shall itemize each change, to facilitate assessment of work progress.

(e) Points of contact for invoice submission will be provided at the Post Award Conference.

mailto:9-AMZ-FAA-APInvoices@faa.gov

Section H - Special Contract Requirements

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2013)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

Contractors may use the following means of electronic signature technology : digital signatures.

(End of Clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer’s Representative (COR).

FAA ORDERS/DIRECTIVES

Contractor & Industrial Security Program FAA Order 1600.72A http://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Accountability Board FAA Order 1110.125A http://www.faa.gov/documentLibrary/media/Order/1110.125A.pdf

Smoking Restrictions in FAA Controlled or Occupied Space FAA Order 3900.47 http://www.faa.gov/documentLibrary/media/Order/3900.47.pdf

FAA Occupational Safety & Health Program FAA Order 3900.19B http://www.faa.gov/documentLibrary/media/Order/3900.19B.pdf

Airfield Driver Training for FAA Employees FAA Order 5200.7A http://www.faa.gov/documentLibrary/media/Order/5200.7A.pdf

Internet Use Policy FAA Order 1370.79A http://www.faa.gov/documentLibrary/media/Order/FAA_Order_1370.79A.pdf

Electronic Mail FAA Order 1370.81A https://employees.faa.gov/documentLibrary/media/Order/1370.81A.pdf

Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

H.1 PERMITS AND RESPONSIBILITIES

The Contractor shall secure and pay for all permits, licenses, special inspections, etc., required in the execution of the work, whether of a permanent or temporary nature.

H.2 TIME EXTENSION

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

H.3 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.4 CONSTRUCTION SAFETY PROGRAM

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities. Chapter 33 Construction Safety (Section J, Attachment 3) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.5 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS DISTURBED

If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

H.6 EXERCISE OF OPTIONAL CONTRACT LINE ITEM (CLINS)

The Government may exercise none, some or all Option items at the prices established in Section B, CLINs 0002- 0005. Exercise of the option CLINs must be made in writing by the Contracting Officer within 30 days of completion of Phase 1.

Section I - Contract Clauses

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (AUG 1997)

3.1.7-5 DISCLOSURE OF CONFLICTS OF INTEREST (MAR 2009)

3.1.8-1 CANCELLATION, RESCISSION AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER

ACTIVITY (OCT 2014)

3.1.8-2 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (OCT 2014)

3.2.2.3-8 AUDIT AND RECORDS (JUL 2010)

3.2.2.3-25 REDUCING THE PRICE OF A CONTRACT OR MODIFICATION FOR DEFECTIVE COST

OR PRICING DATA (OCT 2011)

3.2.2.3-27 SUBCONTRACTOR COST OR PRICING DATA (JUL 2004)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-61 RESPONSIBILITY OF THE ARCHITECT-ENGINEER CONTRACTOR (JUL 2004)

3.2.2.3-64 DISMANTLING AND DEMOLISHING OF PROPERTY (JUL 2004)

3.2.2.3-65 USE OF EXPLOSIVES (JUL 2004)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-69 SUBCONTRACTS - CONSTRUCTION (JUL 2004)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.4-4 FIXED-PRICE CONTRACTS WITH ECONOMIC PRICE ADJUSTMENT-LABOR AND

MATERIAL (APR 1996)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 1996)

3.2.5-3 GRATUITIES OR GIFTS (JAN 1999)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2010)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.2.5-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APR 2010)

3.2.5-14 DISPLAY OF HOTLINE POSTER(S) (APR 2008)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (APR 1996)

3.3.1-9 INTEREST (SEP 2009)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-15 ASSIGNMENT OF CLAIMS (APR 1996)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(AUG 2012)

3.3.2-1 FAA COST PRINCIPLES (JAN 2016)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (APR 1996)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JUL 1996)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2013)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED, AND

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS CONCERNS (MAR 2009)

3.6.1-4 SMALL, SMALL DISADVANTAGED, WOMEN-OWNED AND SERVICE-DISABLED VETERAN

OWNED SMALL BUSINESS SUBCONTRACTING PLAN (JUL 2017)

3.6.1-6 LIQUIDATED DAMAGES - SUBCONTRACTING PLAN (JAN 2010)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (APR 2016)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2016)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME COMPENSATION

(JAN 2012)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (AUG 1998)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (JAN 2011)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 1996)

3.6.2-18 DAVIS BACON ACT (APR 2017)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (APR 2017)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (APR 2017)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (APR 2017)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (AUG 1998)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2015)

3.6.2-43 PROJECT LABOR AGREEMENT (AUG 2010)

3.6.2-43 PROJECT LABOR AGREEMENT (AUG 2010) - ALTERNATE I (AUG 2010)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2012)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (OCT 2016)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-17 EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (OCT 2016)

3.6.3-19 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-21 EFFICIENCY IN WATER CONSUMING PRODUCTS AND SERVICES (OCT 2016)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (OCT 2016)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.3-25 AEROSOLS (OCT 2016)

3.6.3-26 FOAMS (OCT 2016)

3.6.4-4 BUY AMERICAN ACT - CONSTRUCTION MATERIALS UNDER NORTH AMERICAN FREE

TRADE AGREEMENT (OCT 2015)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.5-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN OWNED ECONOMIC

ENTERPRISES (MAR 2009)

3.9.1-1 CONTRACT DISPUTES (OCT 2011)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-26 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (APR 2013)

3.10.2-6 SUBCONTRACTS FOR COMMERCIAL ITEMS AND COMMERCIAL COMPONENTS (APR

1996)

3.10.4-19 GOVERNMENT INDUSTRY DATA EXCHANGE PROGRAM (GIDEP) (JAN 2002)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-11 PLAIN LANGUAGE (JUL 2006)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(OCT 2012)

3.14-3 FOREIGN NATIONALS AS CONTRACTOR EMPLOYEES (OCT 2017)

3.2.2.3-37 NOTIFICATION OF OWNERSHIP CHANGES (JUL 2004)

(a) The Contractor (you) must notify FAA in writing within 30 days when you become aware that a change in ownership has occurred or will occur and that the change could affect the value of your capitalized assets in the accounting records, asset valuations, or cause any other cost changes.

(b) You must:

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the Contracting Officer (CO) access to the records on request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of your ownership changes; and

(4) Retain and maintain depreciation and amortization schedules based on the asset records maintained before each ownership change.

(c) You must include the substance of this clause in all subcontracts under this contract with a value exceeding $1,000,000 and that require cost and price data.

(End of clause)

3.2.2.3-39 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA OR OTHER INFORMATION

-MODIFICATIONS (JUL 2010)

(a) When there are price adjustments in the contract, the Contractor (you, your) must submit the following:

(1) A certificate of current cost or pricing data…