Amendment A006.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A006 1/20/2022 N/A See Box 14

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

69056721B000017

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers (__ ) is extended, ( x ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

N/A

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

N/A

D OTHER (Specify type of modification and authority) N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

MT PRA GLAC 10(45), Rehabilitate Final 9.3 miles of the Going-to-the-Sun Road & Replace Bridge Over McDonald Creek Amendment A003 is issued to revise the following:

Continued on page 2

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A006, dated 1/20/2022 Project No MT PRA GLAC 10(45) Project Name Rehabilitate Final 9.3 miles of the Going-to-the-Sun Road & Replace Bridge Over McDonald Creek Solicitation No. 69056721B000017 Page 2 of 2

REVISIONS ARE AS FOLLOWS:

CONTRACT CLAUSES

Page C-23. Revises, FAR Clauses 52.211-10, Commencement, Prosecution, and Completion of Work (Apr 1984) Alternate I (Apr 1984) Revises Fixed completion date.

SPECIAL CONTRACT REQUIREMENTS

Page E-24 - Subsection 108.01 Commencement, Prosecution and Completion of work, deletes 108.01(a)(11)

ENCLOSURES

Pages:

C-23 E-24

C-23

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than September 30November 17, 2023 subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by March 4May 02, 2022. The completion date will be extended by the number of calendar days after the above date that the contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.211-12 Liquidated Damages—Construction (Sep 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the

Contractor shall pay liquidated damages to the Government in the amount of: See Special Contract Requirements, Subsection 108.04.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-13 Time Extension (Sep 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.211-18 Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

52.214-26 Audit and Records – Sealed Bidding (Jun 2020)

(a)As used in this clause, “records” includes books, documents, accounting procedures and practices, and other data, regardless of type and regardless of whether such items are in written form, in the form of computer data, or in any other form.

Revised by Amendment A006

Revised by Amendment A005

Contract Clauses Project: MT PRA GLAC 10(45) Rehabilitate Final 9.3 miles of the Going-to-the-Sun Road & Replace Bridge Over McDonald Creek

E-24 DIVISION 100

Special Contract Requirements Project: MT PRA GLAC 10(45), Rehabilitate Final 9.3 Miles of Going-to-the-Sun Road & Replace Bridge Over McDonald Creek

McDonald Creek Bridge sites, unless otherwise coordinated with the Utility Relocation contractor per review and approval of the CO.

(9) From May 1 to May 31, 2023 work is only allowed from 8:15 a.m. to 6:45 p.m. daily.

(10) From June 1 to June 30, 2023 work is only allowed from 7:45 a.m. to 7:30 p.m. daily.

(11) Complete all phase 2 bridge work, bridge approach construction, and parking area construction up to top of recycled aggregate base by June 30, 2023

(11)(12) From July 1 to September 30, 2023 no night work is allowed.

(b) Going-to-the-Sun Road:

(1) From April 1, 2022 to May 31, 2023 no work is allowed.

(2) From June 1 to September 30, 2023 no night work is allowed from 1000 feet west of Sprague Creek Campground to North McDonald Creek Road.

(3) No night work is allowed on June 4, July 3, August 1, August 31, or September 29, 2023.

(4) Perform all curve enhancement construction up to top of recycled aggregate base prior to performing full depth reclamation work.

(c) Camas Road Fiber Optic Extension:

(1) Complete all work by September 30, 2022.

(2) No night work is allowed from 44+40 to 97+00.

(d) Public Fiber Optic Installation:

(1) Complete all work by September 30, 2022.

(2) No night work is allowed from 150+00 to 195+00.

108.01A Labor. (Added Subsection).

Follow the requirements of FAR Clause 52.222-6 Construction Wage Rate Requirements.

Adjacent or virtually adjacent work sites, as used in FAR Clause 52.222-6, are defined to be work sites within ½ mile of the project. Application of Construction Wage Rate Requirements (Davis- Bacon Act) for work sites beyond ½ mile of the project will be determined by the CO.

Revised by Amendment A006