S06 - Att 1 Updates to Pages 3 and 11 of SOL 36C25226B0014.pdf
PDF 449 KB Posted
- Solicitation number
- 36C25226B0014-1
About this file
This is a Bid Schedule and Statement of Work for a federal construction contract to upgrade the fire alarm system at the VA Medical Center in Tomah, Wisconsin (Project #676-22-110).
The contractor must provide all labor, materials, equipment, qualified supervision, and related items necessary to complete the fire alarm system upgrade in accordance with federal, state, and local requirements, project specifications, and drawings. The contract is structured as an all-inclusive base bid (CLIN 0001) with no alternate bid items. The total project magnitude is estimated between $5,000,000 and $10,000,000. All work must be completed within 460 calendar days after receipt of the notice to proceed, broken down into three phases: pre-construction (20 calendar days for contractor work plus 60 days for VA review, totaling 80 days), campus work (350 calendar days for contractor work plus 10 days for VA review, totaling 440 days), and closeout (10 calendar days for contractor work plus 10 days for VA review, totaling 460 days). Award will be made to the responsible bidder submitting the lowest responsive bid; only one award will be made. If submitting as a joint venture, bidders must include a copy of the joint-venture agreement and printed proof of SBA small business status with their offer, or the bid will be rendered non-responsive. Prior to commencing construction, the contractor must submit an approved cost-loaded Critical Path Method construction schedule for approval by the Contracting Officer or Contracting Officer's Representative.
View the file
Other files
Show all 24
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
36C25226B0014
BID SCHEDULE
VA Construction Project Number: 676‐22‐110 Upgrade Fire Alarm System
While inclusion of the project magnitude $5,000,000 to $10,000,000 is no longer a mandatory element, the Government believes inclusion of this information assists prospective bidders in understanding the overall scale
0001 – All-Inclusive Base Bid: Contractor shall provide for and furnish all labor, materials, equipment, qualified supervision, and other items designated in this contract in accordance with the specifications and drawings to complete Project # 676‐22‐110: Upgrade Fire Alarm System at Tomah VA Medical Center, Tomah, WI.
All work, starting with preconstruction phase through construction, ending in post-substantial completion is to be accomplished within four hundred and sixty days (460) calendar days after receipt of the notice to proceed.
CLIN 0001 All-Inclusive Base Bid: _______________________________
Alternate Bid Items noted in the design and specifications will not be used.
NOTICE TO BIDDERS: Award will be made to the responsible bidder, who submitted the lowest responsive bid.
A single award will be made on the Base Bid. Only one award will be made as a result of this solicitation.
NOTICE TO BIDDERS: Additional information regarding the general and specific scope of work is defined in the specifications and drawings.
NOTICE TO BIDDERS: If submitting a joint-venture (JV), bidders must include a copy of the joint-venture agreement within the bid package. All potential bidders are responsible for monitoring and downloading all amendments from Contract Opportunities at:
https://sam.gov/contracting
Joint Ventures (JVs) submitting a bid shall also submit printed proof of their SBA SBS and / or with their offer. JV offerors failing to submit this proof shall be rendered non-responsive outright and shall not be eligible for award.
NOTICE TO BIDDERS: An approved cost-loaded, Critical Path Method (CPM) construction schedule is required prior to commencement of construction. See specifications for details. CPM schedule shall be approved by the Contracting Officer or the Contracting Officer’s Representative. See specifications for details.
End of Section
36C25226B0014
Statement of Work
CONSTRUCTION STATEMENT OF WORK
Project Data:
a. Title: Upgrade Fire Alarm System
b. Location: VA Medical Center, Tomah, Wisconsin
c. Project #: 676‐22‐110
I. General Description:
Provide Construction Services for Project 676‐22‐110 Upgrade Fire Alarm System
II. Project Scope:
1. The contractor shall provide for and furnish all labor, materials, equipment, qualified supervision, and other items designated in this contract in accordance with federal, state, and local authorities, project specifications, and drawings necessary to complete the construction of this project at the VA Medical Center, Tomah, Wisconsin.
2. All work shall be completed within 460 calendar days after receiving the notice to
Proceed (NTP).
3. See plans and specifications for further information.
III. Period of Performance:
1. The Pre-construction (kick-off) meeting will be held on a future, agreed-to-date (post award) and will coincide with the NTP.
CONSTRUCTION PERIOD OF PERFORMANCE CHART
(IN CALENDAR DAYS AFTER NTP)
Calendar
Days for the Work
VA Review Total days after
NTP
Level Complete
Pre-Construction 20 60 20 40 80
Campus work 350 10 400 440
Closeout 10 10 420 460
File details come from the government source that posted it. Updated .