36C24225B0009.docx

09-01-23

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C24225B0009 X 02-12-2025 632-25-001 36C242 Department of Veterans Affairs Network Contracting Office 2 James J. Peters VA Medical Center 130 West Kingsbridge Road Bronx

NY

10468-3904 Department of Veterans Affairs Network Contracting Office 2 James J. Peters VA Medical Center 130 West Kingsbridge Road Bronx

NY

10468-3904 Torell Camp

(929) 656-2560 This project is to furnish all construction services to Mill and Fill at Northport VA Medical Center.

The Contractor shall furnish all materials, supplies, equipment , personnel and supervision to accomplish Project Number 632-25-001 Mill and Fill in accordance with the statement of work, specifications and drawings at the Northport VAMC, 79 Middleville Rd, Northport, NY 11768.Completion Time is 15 calendar days from the the notice to proceed date.

Contractor will be responsible to coordinate and schedule work starting on Friday's at 7:00 pm working only on weekends noted in the general conditions. Work shall comply with VA Specifications & regulations, all applicable Federal, State and Local codes, including specific regulations related to working at the Northport VAMC.

As set forth in 38 U.S.C. 8127 the requirement is a 100% set aside to Service Disabled Veteran Owned Small Business.

All prospective bidders must be registered in SAM (https://www.sam.gov) and verified/visible/certified in SBA VetCert (https://veterans.certify.sba.gov) at the time of offer submission and before award of this procurement. Offerors must submit their annual Vets4212 Report.

The NAICS Code is 237310 and business size standard is $45.0 Million.

Project magnitude of construction is between $500,000 and $1,000,000.

A prebid site visit is scheduled for February 25, 2025 at 10:00 am at Northport VAMC, 79 Middleville Rd.

Northport, NY 1176, meeting VA escort at Building 10, 1st floor lobby.

NOTE: NO OTHER SITE VISIT WILL BE SCHEDULED. Interested Bidders are strongly encouraged to attend.

Refer to page 8 for Pre-Bid Site Visit Instructions.

Questions must be received no later than Mar 11, 2025 by 4:00 pm EST. Refer to page 8 and 9 for Virtual Bid Opening instructions.

A Bid Bond must be submitted with bid.

All bidders are required to complete and sign VAAR 852.219-75 VA Notice of Limitations in Subcontracting Compliance (Attached) & 52.225-2 Buy America Certificate (Attached) along with bid.

IAW FAR 36.209, No contract for the construction of a project shall be awarded to the firm that designed the project or its subsidiaries or affiliates, except with the approval of the head of the agency or authorized representative.

NOTE: CONTRACTORS MUST ACKNOWLEDGE ALL SOLICITATION AMENDMENTS

To preserve the integrity of the procurement process, all prebid questions and request for information must be submitted to Torell Camp, Contract Specialist via email at torell.camp@va.gov.

X X 52.211-10 X

10:00 AM

EST

03-17-2025 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

36C242 Department of Veterans Affairs Vladimir Stoyanov James J. Peters VA Medical Center 130 West Kingsbridge Road Bronx

NY

10468-3904 Tungsten Network https://www.tungsten-network.com/ customer-campaigns/veteransaffairs/

Vladimir Stoyanov

CONTRACTING OFFICER

Table of Contents

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE AND BONDS

(a) Bidding materials consisting of Invitation for Bids, drawings, specifications and contract forms will be available on https://sam.gov in electronic format only. All interested parties (subs & primes) should register at https://sam.gov as an “Interested Vendor” so that others will know of your interest in participating in this procurement. A Bidder’s mailing list WILL NOT BE prepared by the Contract Specialist. SOLICITATION AMENDMENTS: Amendments to the solicitation will be posted at https://sam.gov. Paper copies of the amendments will NOT be individually mailed. By registering to “Receive Notification”, you will be notified by e-mail of any new amendments that have been issued and posted. No other notification of amendments will be provided. Offerors are reminded that they are responsible for obtaining and acknowledging all amendments to this solicitation prior to the time for receipt of offers.

(b) If bid exceeds $150,000 a bid bond must be submitted. A bid guarantee is required in an amount not less than 20 percent of the bid price but shall not exceed $3,000,000. Failure to furnish the required bid guarantee in the proper form and amount, by the time set for opening of bids, will require rejection of the bid in all cases except those listed in FAR 28.101-4, and may be cause for rejection even then.

(c) If the contract will exceed $150,000 (see FAR 28.102-1 for lesser amount), the bidder to whom award is made will be required to furnish two bonds, a Payment Bond, SF 25A, and a Performance Bond, SF 25, each in the penal sum as noted in the General Conditions of the Specification. Copies of SFs 25 and 25A may be obtained upon application to the issuing office.

(d) If the bid/offer is between $30,000 - $150,000 The bidder/offeror to whom award is made will be required to furnish a Payment Bond, Standard Form 25A or alternative payment protection which conforms to the requirements set forth in FAR Clause 52.228-13, Alternative Payment Protections, as noted in the General Conditions of this Specification. Copies of the Standard Form of Payment Bond may be obtained upon application to the Issuing Office.

PROJECT BID ITEMS

A single award will be made on the Base Bid.

BASE BID: All work required in the construction documents (including but not limited to drawings, specifications, addenda, and contract documents).

Fill in price SF 1442 BOX 17, BASE BID (use ink)

In accordance with FAR 36.204, the construction magnitude Between $500,000 and $1,000,000.

BID SUBMISSION

The following documents are to be included in the bid submission:

(a) One (1) signed SF 1442 page 2, Offer page, with blocks 14-20c completed.

(b) Attach Bid Sheet

(c) Acknowledgment of all amendments must be accomplished either via entering data in block nineteen (19) of the SF1442 or completing blocks fifteen (15) a, b, and c of the amendment and attaching it to the SF 1442 Offer page.

(d) One (1) copy of original completed/signed SF24 Bid Bond and Power of Attorney as required.

(e) Buy American Certificate.

(f) One (1) copy of completed signed certificate VA Notice of Limitation on Subcontracting VAAR Clause 852.219-77.

(g) Safety or Environmental Violations and Experience Modification Rate:

1) All Bidders/Offerors shall submit the following information pertaining to their past Safety and Environmental record. The information shall contain, at a minimum, a certification that the bidder/offeror has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years.

2) All Bidders/Offerors shall submit information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information will be obtained from the bidder’s/offeror’s insurance company and be furnished on the insurance carrier’s letterhead.

3) Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead may obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self-insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR will obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

(h) VETS-4212 Reporting Requirement Contractors are required to submit a required annual Form VETS-4212, Federal Contractor Veterans' Employment Report in all cases where the contractor or subcontractor has received an award of $150,000 or more in any fiscal year. Contracting Officers are prohibited from awarding a contract to a contractor that has not submitted a required VETS-4212 Report with respect to the preceding fiscal year if the contractor was subject to the reporting requirement of 38 U.S.C. 4212(d). For more information on this requirement and/or for completing the web-based reporting form, visit the following website https://www.dol.gov/agencies/vets/programs/vets4212. See FAR provision 52.222-38, Compliance with Veterans' Employment Reporting Requirements (FEB 2016) under the Representations, Certifications and Other Statements of Offerors, and FAR clause 52.222-37, Employment Reports on Veterans (FEB 2016) under the General Conditions.

(i) Bidders are responsible for verifying their bid and all required bid documents are received by the date and time specified in the SF 1442 solicitation (subject to amendment).

DELIVERY OF BIDS

Bids in response to this solicitation are to be emailed to:

Torell.Camp@va.gov

The solicitation number and project title must be provided in the subject line of the email.

INSTRUCTIONS TO BIDDERS

A public bid opening will be held on March 10, 2025 @ 10:00 AM (EST), via Microsoft Teams conference call. To access the virtual bid open, the call-in number (audio only) is 205-235-3524. The phone conference ID is 444 651 044#. Please dial in approximately five to ten minutes prior to the official bid open time.

Bids received after this time will be rejected.

Any exception to the terms and conditions of this Invitation for Bid (IFB) will result in a nonresponsive bid.

Failure to provide a definitive price will result in a nonresponsive bid.

Receipt of bids must be in accordance with terms and conditions of this IFB.

Bidders must acknowledge (in writing only) amendments to this solicitation, otherwise a bid may be determined nonresponsive.

The winning bidder must be determined as "responsible" by the Contracting Officer in accordance with FAR Part 9, Contractor Qualifications.

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

GENERAL INTENTION

Contractor will provide construction services to include all tools, labor, materials, equipment, services, and supervision necessary for the Mill and Fill at the Northport VA Medical Center. The period of performance is 15 calendar days after receipt of Notice to proceed. VAMC Project # 632-25-001.

SITE VISIT

Bidders are encouraged to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of performing these services. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

There will only be one (1) organized site visit. It will be held on Tuesday, February 25, 2025, at 10:00 AM. Participants will meet at the Northport VAMC 1st floor in building 10 and will sign in at the front desk to receive a visitor’s badge. Please bring a government issued photo ID.

Masks are required for all personnel. Masks must be FDA approved.

Entry into the Medical Center shall be through the main entrance on Middleville Road. Parking will be on-street as available only. Parking in the Garage or other designated spaces is not allowed. Street parking is metered by the City of Northport. Allow ample time to find parking.

Attendance is not mandatory; however, all bidders are strongly encouraged to attend.

REQUESTS FOR INFORMATION (RFI):

To obtain clarifications and/or additional information concerning the contract requirements or specifications, submit a written RFI via email to Torell.Camp@va.gov.

RFIs will be responded to as necessary in amendment format which will be posted on https://SAM.gov The deadline for submission of RFIs for this solicitation is, March 11th, 2025 at 4:00 PM (EST). No questions will be answered after this date/time unless determined to be in the best interest of the Government as determined by the Contracting Officer. Telephone RFIs will not be accepted or returned.

Virtual Bid Opening Instruction In accordance with FAR 14.202-8, the government is authorizing electronic bids on this solicitation. All bids shall be emailed to Torell Camp, Contract Specialist, at Torell.Camp@va.gov by 10:00 am March 17th, 2025, prior to bid opening time at 11:00 am.

EMAIL SUBJECT LINE: Solicitation 36C24225B0009 Mill and Fill – COMPANY NAME. The bids shall include copies of a bid bond.

The virtual bid opening shall take place on March 17th, 2025, at 11:00 AM EST. No hand-carried or mailed bids will be accepted.

The bid opening will take place on Microsoft Teams. To access the conference:

Microsoft Teams Need help?

Join the meeting now Meeting ID: 210 559 509 792 Passcode: Ea7mh78k

Dial-in by phone +1 205-235-3524,,444651044# United States, Dora Find a local number Phone conference ID: 444 651 044# Bidders should dial in by 10:20 am to take attendance.

BID REQUIREMENTS

The bid, in its entirety, shall not exceed one email to include attachments: Signed SF1442 Cover Sheet with Item 0001 Base Bid Total and all required Representations and Certifications – signed VAAR 852.219-75 VA Notice of Limitations in Subcontracting Compliance (Attachment 4) ,completed and signed FAR 52.225-2 Buy American Certificate (Attachment 5), Copy of Bid Bond, Signed Amendments or acknowledgment on SF1442 if any and Safety or Experience Modification Rate, VETS-4212 Reporting Requirement; Contractors are required to submit a required annual Form VETS-4212.

BASIS FOR AWARD

The Government will award a single contract resulting from this solicitation to the responsive, responsible SDVOSB bidder whose offer conforming to the solicitation will be most advantageous to the Government based on lowest price in accordance with FAR Part 14 – Sealed Bidding.

RESPONSIBILITY REQUIREMENTS

A Determination of Responsibility shall be accomplished for the apparent awardee prior to processing the award. The above information, along with other information obtained from Government systems, such as the OSHA and EPA online inspection history databases will be used to make the Determination of Responsibility. Failure to affirm being within the guidelines above or submit this information may result in a determination of “Non-Responsibility” for the bidder/offeror. NOTE: Any information received by the Government that would cause for a negative Determination of Responsibility may make the bidder/offeror ineligible for award.

This requirement is applicable to all subcontracting tiers, and prospective prime contractors are responsible for determining the responsibility of their prospective subcontractors.

CONSTRUCTION MANAGEMENT PLATFORM REQUIREMENTS:

1. Construction contractors and A/E design firms, selected by award to perform work at VISN 2 VA facilities, are required to utilize VISN 2 Autodesk Build Construction management platform, also called Autodesk Construction Cloud (ACC). Access to the platform and training portal will be provided by VISN 2 through project Contracting Officer Representative (COR) at no cost for the duration of the project. Autodesk Build is the management and collaborative environment that VISN 2 uses for all its Non-Recurring Maintenance (NRM), Minor Program projects, Feasibility Studies, Commissioning and Retro-Commissioning contracts. There is no user, license, or subscription fee to the contractor for using this cloud-based platform.

1. Contractor shall accomplish and complete the following tasks upon award of contract:

1. Request access to ACC platform and Productivity NOW eLearning Site to project VA COR NLT 14 days from contract award.

1. Only staff that shall utilize the platform to be granted access. Examples: Project manager, sub-contractors POC, Site manager, Safety officer, etc.

1. The access request shall be in writing and include a list of staff. The list shall include the following information:

· Full Name

· Company Name

· Email Address

· Role/Position on the project (i.e., Project manager, site super)

1. Upon granting access, staff shall complete required ACC training through Productivity NOW platform within 12 Calendar days.

1. Upon successful completion of training, contractor shall submit certificates of completion to COR NLT 2 business days. \

1. Access to Productivity NOW eLearning will expire after 12 Calendar days after online access is granted. Contractor shall complete ACC training within that period.

1. Additional Staff and Subcontractors can be added at any time with a request submission to the project COR as described above.

1. The contractor shall only use the ACC platform for contract required submissions, official project correspondence to be acknowledged, reviewed, and actioned by the responsible party. No additional time shall be added to the contract, nor an increase in contract amount be provided for the contractor’s failure to utilize the ACC platform as the project’s official communication and collaboration system. Any correspondence out of platform shall not be the governing authority contradicting direction and will be at the contractor’s expense. Official project correspondence and collaboration includes but not limited to: RFIs, submittals, schedules, shutdown requests, actionable tasks, reports, testing, safety inspections, photos, and site surveys.

1. Contractor must inform the COR of any staff changes NLT 2 business days from the change. Staff changes pertains to staff who was granted access to the ACC platform. Contractor shall request termination of access, replacement of personnel and/or any other action that might impact the contractor ability to maintain required utilization of the platform.

1. Contractor submission requirements cannot be accepted for work to begin without meeting all ACC Platform requirements outlined herein, including completing required ACC platform training.

2.1 52.201-1 ACQUISITION 360: VOLUNTARY SURVEY (SEP 2023)

(a) All actual and potential offerors are encouraged to provide feedback on the preaward and debriefing processes, as applicable. Feedback may be provided to agencies up to 45 days after award. The feedback is anonymous, unless the participant self-identifies in the survey. Actual and potential offerors can participate in the survey by selecting the following link: https:// www.acquisition.gov/360.

(b) The Contracting Officer will not review the information provided until after contract award and will not consider it in the award decision. The survey is voluntary and does not convey any protections, rights, or grounds for protest. It creates a way for actual and potential offerors to provide the Government constructive feedback about the preaward and debriefing processes, as applicable, used for a specific acquisition.

(End of Clause)

2.2 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of Provision)

2.3 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

2.4 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Suffolk County, New York

(End of Provision)

2.5 52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

(a) Definitions. As used in this clause— Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is—

(i) A commercial product (as defined in paragraph (1) of the definition of ‘‘commercial product’’ at Federal Acquisition Regulation (FAR) 2.101;

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Component means any article, material, or supply incorporated directly into construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both—

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if—

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of ‘‘cost of components’’.

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

[Contracting Officer to list applicable excepted materials or indicate ‘‘none’’]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable.

(A) For domestic construction material that is not a critical item or does not contain critical components.

(1) The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(2) For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(A)(2) of this clause will no longer apply as of January 1, 2030.

(B) For domestic construction material that is a critical item or contains critical components.

(1) The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds 55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(B)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(B)(2) of this clause will no longer apply as of January 1, 2030.

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

FOREIGN AND DOMESTIC CONSTRUCTION MATERIALS PRICE COMPARISON

Item 1:

Foreign Construction Material.

Domestic Construction Material.

Item 2:

Foreign Construction Material.

Domestic Construction Material.

[*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).] [List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] (End of Clause)

2.6 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

2.7 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Vladimir Stoyanov Torell Camp Hand-Carried Address:

Department of Veterans Affairs James J. Peters VA Medical Center Network Acquisition & Logistics(10N3NAL) 130 West Kingsbridge Road Bronx NY 10468-3904 Mailing Address:

Department of Veterans Affairs James J. Peters VA Medical Center Network Contracting Office 3 (10N3NCO) 130 West Kingsbridge Road Bronx NY 10468-3904

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

2.8 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor's refusal or failure to complete the work within the specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if—

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include—

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

(End of Clause)

2.9 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference,…