26R0234 General Requirements .pdf

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234 of Storage Space; NUWC, Naval Station Newport, Newport, RI Work Order No.: 1814702

NAVAL FACILITIES ENGINEERING SYSTEMS COMMAND, MID-ATLANTIC

9324 VIRGINIA AVE, BLDG Z-140

NAVAL STATION NORFOLK, NORFOLK, VA 23511

POC: Chamel Adams, chamel.r.adams.civ@us.navy.mil (757) 341-1667

INDEFINITE DELIVERY/INDEFINITE QUANTITY (IDIQ) MULTIPLE AWARD CONSTRUCTION

CONTRACT (MACC) FOR FACILITIES IN THE NORTH AREA OF RESPONSIBILITY (AOR) TO

INCLUDE CONNECTICUT, DELAWARE, MAINE, MASSACHUSETTS, NEW HAMPSHIRE, NEW

JERSEY, NEW YORK, PENNSYLVANIA, RHODE ISLAND, AND VERMONT

MACC GROUP: MACC ML-C00068

SOLICITATION NUMBER: N4008526R0234

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization of Storage

Space, Naval Undersea Warfare Center, Naval Station Newport, Newport, RI

DATE OF SOLICITATION: 29 July 2026

NORTH AOR MACC CONTRACT HOLDERS:

N4008521D0052

Benaka Inc.

7 Lawrence Street

New Brunswick, New Jersey 08901

POC: C.N. Manjunath

Phone: (732) 246-7060

Email: benaka@benakainc.com

N4008521D0053

CCI Utility and Construction Services, LLC

111 W. 16th Avenue, Suite 402

Anchorage, AK 99501

POC: Jim Henebury

Jeffrey Eaton

Tim Nichols

Phone: (207) 485-6701

Email: jhenebury@bbch-llc.com jeaton@bbch-llc.com

Const-estimating@bbch-llc.com

Const-proposals@bbch-llc.com

N4008521D0054

Kunj Construction Corporation

163 B Paris Avenue

Northvale, NJ 07647

POC: Neekunj Bhanderi

Yatin Gajera

Raghav Krish

Phone: (201) 694-7617

Email: neekunjb@gmail.com

Yatin@kunjcc.com

Krish@kunjcc.com

N4008521D0055

Ocean Construction Services

104 Aragona Boulevard, Suite 101

Virginia Beach, VA 23462

POC: Kara Laskowski

Phone: (757) 200-9590

Email: bids@ocsinc.us mailto:benaka@benakainc.com mailto:jhenebury@bbch-llc.com mailto:jeaton@bbch-llc.com mailto:Const-estimating@bbch-llc.com mailto:Const-proposals@bbch-llc.com mailto:neekunjb@gmail.com mailto:Yatin@kunjcc.com mailto:Krish@kunjcc.com mailto:bids@ocsinc.us

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

N40085-21-D-0056

PEM-Harkins Joint Venture

6161 Busch Boulevard, Suite 255

Columbus, OH 43229

POC: Radagodage Sumanaweera

Phone: (614) 573-7299

Email: tsumanaweera@peminc.biz

N40085-21-D-0057

Tantara Corporation

54 Mason Street

Worcester, MA 01610

POC: Dawn Dearborn

Phone: (508) 752-5599

Email: DDearborn@tantaracorp.com

N40085-21-D-0066

J&J Contractors, Inc.

101 Billerica Avenue, Building 5, Suite 205

North Billerica, MA 01862

POC: Kamlesh Patel

Phone: (978) 259-2454

Email: kamp@jjcontractor.com

GENERAL REQUIREMENTS

All terms and conditions of N40085-21-D-0052/0053/0054/0055/0056/0057/0066 IDIQ Contract apply to this solicitation. Please review your MACC award document for guidance on contract clauses and requirements that may pertain to this order. You are responsible for adhering to all applicable clauses, even if they are not restated in this RFP package or the Task Order award document. For clarification on any clause or other contractual issue please contact Chamel Adams at chamel.r.adams.civ@us.navy.mil

Amendments will be posted directly to PIEE, Sam.gov and sent directly via email to MACC Holders. It is ultimately the responsibility of the MACC Holders to monitor SAM.gov for any updates.

NAVFAC Solicitation No.: N4008526R0234

NAVFAC Specification/Drawing: Work Order No. 1814702

Title: Design-Build, Special Project RM25-4593 – Building 47 Upgrades/Modernization of Storage Space

Location of the work: Naval Undersea Warfare Center, Naval Station Newport, Newport, RI

Description of the work: The purpose of this project is to improve the life safety of the warehouse while strategically providing access to additional spaces and consolidating spaces to get more footprint. The project will replace the existing fire alarm and mass notification systems with a new combined addressable fire alarm and mass notification system. The existing systems will remain in place and active until the new system has finished final acceptance testing. The existing dry pipe sprinkler system will be replaced with a wet-pipe sprinkler systems utilizing ESFR (Early Suppression Fast Response) sprinklers. A fire pump room will be installed to serve the building sprinkler systems. The fire doors separating bays B and bay C will be replaced. New central emergency inverters will be installed in each bay to provide one or several branch circuits with emergency power. This will address the emergency lighting in the warehouse. Ventilation units will be installed in each bay of the warehouse to bring in more outside air. Air currents will be installed on the overhead doors that are primarily used to better maintain the interior warehouse temperature. An opening will be installed in the CMU wall in Bay A to give access to the currently unoccupied space. The mailto:tsumanaweera@peminc.biz mailto:DDearborn@tantaracorp.com mailto:kamp@jjcontractor.com mailto:chamel.r.adams.civ@us.navy.mil

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234 unoccupied space will be renovated to meet the needs of the warehouse operations and will provide additional office and laydown space. The existing two-story office space and the restroom in Bay A will be removed to allow for more laydown space for the warehouse operations. The break room and office space in Bay C will be combined into a two-story facility. Site/civil work includes new utility pole with utility risers for proposed electrical service and underground PVC piping, fire water service and sanitary sewer to service new fire pumproom. Base Bid includes all Hazardous Materials abatement and disposal.

Estimated Price Range: The estimated price range for this project is between $10,000,000 and

$25,000,000.

Time for completion: The duration of this task order for the base bid work is 365 calendar days. The duration will be extended an additional 365 calendar days if option work is to be included in the original award, or modified to be included in the contract. If options are awarded, the overall contract completion date will be 730 calendar days from date of contract award. (includes 15 calendar days for submission and approval of bonds and insurance).

Wage Rate Requirements: Department of Labor (DoL) General Decision Number: RI20260001 dated

05/18/2026 (Attachment B) applies to this work. Should this wage determination be modified by DoL prior to award, the most current wage determination will be incorporated in the award.

Liquidated damages: In accordance with FAR 52.211-12 Liquidated Damages (DEVIATION 2026-

O0038), if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,018 for each calendar day of delay for base work and $2,781 for each day of delay for option work, until the work is completed or accepted in accordance with the time for completion for base and option work stated above.

Utilities: .In accordance with FAR 52.236-14 (DEVIATION 2026-O0038) Availability and Use of Utility

Services - The Government shall make all reasonably required amounts of utilities available to the

Contractor from existing outlets and supplies, as specified in the contract. Unless otherwise provided in the contract, the amount of each utility service consumed shall be charged to or paid for by the Contractor at prevailing rates charged to the Government or, where the utility is produced by the Government, at reasonable rates determined by the Contracting Officer. The Contractor shall carefully conserve any utilities furnished without charge.

Record Shop Drawings: In accordance with FAR 52.236-21(DEVIATION 2026-O0038) Specifications and Drawings for Construction Alternate I (Apr 1984) record shop drawings are required. Reproducible copies of these record drawings are required to be provided to the Government as deliverables under the task order.

Government Furnished Property: There is no Government Furnished Property.

Bond Requirements: In accordance with FAR 52.228-1 (DEVIATION 2026-O0038), Bid Guarantees, each offeror shall submit with its offer a guarantee bond (Standard Form 24) in a penal sum equal to at least

20 percent of the offer price or $3,000,000, whichever is less.

Performance and Payment Bonds are required from the contract task order awardee ten (10) calendar days after date of award.

Proposal Acceptance Period: Proposal acceptance period shall be 120 days from receipt of offers.

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

Definitization Of Equitable Adjustments For Change Orders Under Construction Contracts

No data is available regarding the timely definitization of equitable adjustments for change orders under construction contracts. The REA definitization information referenced in Navy Marine Corps Acquisition

Regulation Supplement (NMCARS) 5236.211(b)(2), should not be utilized. There are no agency-specific policies and procedures that apply to the definitization of equitable adjustments for change orders under construction contracts. This Contract contains rated order quantities certified for national defense use, and you are required to follow all the provisions of the DPAS regulation (DPAS Regulation - 15 CFR Part

700.12) only as it pertains to the rated quantities.

Pre-Proposal Inquiries (PPIs): Offerors who determine that the technical and or contractual requirements of this RFP require clarification(s) in order to permit submittal of a responsive proposal shall submit all questions in writing. All inquiries shall be submitted via email to Chamel Adams at chamel.r.adams.civ@us.navy.mil. no later than, fourteen (14) calendar days prior to proposal due date.

Additionally, all inquiries shall be submitted using the Pre-Proposal Inquiry (PPI) form (Attachment C).

Do not submit the same inquiry more than once. Please verify that inquiries submitted by you on behalf of your subcontractors are not duplicates. A response will be published via an amendment by email to MACC holders.

Site Visit: All MACC holders are invited to attend the Site Visit for this project. Firms participating in the site visit will not be directly compensated for their participation.

The Contractor site visit is scheduled for August 13, 2026 at 1000.

All Contractors and their subcontractors shall follow NSN Base Access procedures noted below and once persons are fully vetted prior, on day of site walk through obtain contractor one-day pass at Naval Station

Newport (NSN) Pass and ID Office B1377. The Pass and ID Office is located on Cloyne Court off

Training Station Road just before the bridge outside of Gate 1, Naval Station Newport.

Visitors and contractors will need to present MINIMUM TWO (2) FORMS OF ID to obtain one-day pass at the Pass and ID Office prior to driving to Gate 1.

Visitors and contractors will proceed to NAVAL STATION NEWPORT (NOT NUWC) B47

WAREHOUSE located at WEST INDUSTRIAL ROAD, LOADING DOCK SIDE, BAY B.

Visitors and contractors will meet with project Point of Contacts NSN NAVFAC Contracting Officer

Representative, NSN NAVFAC Design Manager Bethany Collard, and other NUWC Tenant

Representatives.

Refer to attached map.

ALL persons requesting NSN base access MUST follow ALL procedures:

1) For those persons currently not vetted at Naval Station Newport Security Office, must request base access by submitting form 5512 MINIMUM 7 BUSINESS DAYS PRIOR TO

REQUESTED BASE ACCESS. Send to base sponsor Bethany Collard, Bethany.a.collard.civ@us.navy.mil 401-841-7611. See documents “SECNAV Form 5512-

NSNPT- JUL-2024-HIGHLIGHTED”. Please note all blocks MUST be properly completed, INCLUDING SOCIAL SECURITY NUMBER, and hand initialed/signed where requested.

FORM SF 5512 MUST BE EMAILED AS PASSWORD PROTECTED EMAIL, WITH

PASSWORD IN A SEPARATE EMAIL.

mailto:Bethany.a.collard.civ@us.navy.mil

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

ALL REQUESTED BASE ACCESS FORMS SF5512 MUST BE COMPLETED AND SUBMITTED

TO BETHANY COLLARD BY NOON August 4, 2026.

2) All contractors must submit a separate email with a complete list of names/companies of those persons, including their subcontractors, planning to attend the site visit, to base sponsor Bethany

Collard Bethany.a.collard.civ@us.navy.mil by Noon August 4, 2026

3) Contractor to wear appropriate business casual dress

Site Visit POCs:

a. Ms. Bethany Collard:(401)-841-7611 / bethany.a.collard.civ@us.navy.mil

Proposal Due Date: 01 September 2026 at 02:00PM EST. LATE RESPONSES WILL BE HANDLED

IN ACCORDANCE WITH FAR 15.107(b) (DEVIATION 2026-O0048)

Proposal Submission Instructions: The Offeror shall submit an electronic copy of the proposal in accordance with the instructions below by the proposal due date.

Electronic Copies: OFFERORS SHALL SUBMIT ELECTRONIC PROPOSAL (.PDF FORMAT)

IN RESPONSE TO THIS SOLICITATION. Only the PIEE Solicitation Module is authorized for the submission of electronic proposals in response to this solicitation. Electronic proposal submissions should be no larger than 1.9 GB per file. Offerors shall ensure that the Government has received the electronic proposal prior to the date and time specified. PIEE Solicitation Vendor Access Instructions are provided via Attachment E. Emailed, mailed, and hand-delivered submissions will not be accepted.

Offerors shall allow adequate time to upload files which may be slower for non-DoD users and to avoid other technical difficulties that may be encountered. Offerors are also responsible for submitting files in the format specified and consistent with requirements stated elsewhere in this solicitation. Files that cannot be opened or are otherwise missing the required content are the responsibility of the Offeror.

The PIEE system will record the date and time of package submittal. Upon successful receipt of the proposal through PIEE, the Offeror should receive an email confirmation. Please keep this for your records. The date and time of package receipt recorded in PIEE shall govern the timeliness of any proposal submission.

Evaluation Factors for Award:

1. The proposed task order will be awarded to the responsible Offeror offering the best value to the

Government. The lowest price source selection process is selected as appropriate for this acquisition because the best value is expected to result from selection of the proposal with the lowest evaluated price. To make a determination of best value, the Government shall evaluate each Offeror on price only.

2. Basis of Evaluation and Submittal Requirements.

Price:

Solicitation Submittal Requirements:

Price shall be submitted on the Price Proposal Form included in the solicitation. The offeror shall submit one (1) electronic copy via The Procurement Integrated Enterprise Environment (PIEE), with the solicitation submittal requirements identified below:

mailto:Bethany.a.collard.civ@us.navy.mil mailto:bethany.a.collard.civ@us.navy.mil

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

a. Cover page with solicitation number, solicitation title, offeror name, address, phone number, Employer Identification Number (EIN), Unique Entity Identifier (UEI) in SAM, CAGE code, Federal Tax ID number, Point of Contact (POC), POC phone number, and POC email address;

b. All amendments acknowledged;

c. Attachment D: B47- Price Proposal Form;

d. Copy of Representation and Certifications and proof of registration in System for Award

Management (SAM); Please also submit the representation and certification for 52.209-13 -

Violation of Arms Control Treaties or Agreements- Certification separately. It is not included in the annual representations and certifications in the System for Award Management.

e. Confirmation of filing of Veterans’ Employment and Training (VETS) VETS-4212 for the

2024/2025 filing cycle; and

f. Bid Guarantee in accordance with FAR 52.228-1(DEVIATION 2026-O0038), Bid Guarantee.

Amount shall be at least twenty percent (20%) of the proposed price, but shall not exceed $3 million.

g. This solicitation includes CMMC Level 1 (Self- Assessment) Requirements in accordance with

DFARS 252.204-7025 AND 252.204-7021.

The Offeror is required to submit a complete Price Proposal Form that includes completion of all line-item numbers. All required proposal documents shall be submitted in accordance with FAR 15.107

(DEVIATION 2026-O0048).

i. Basis of Evaluation:

The Government will evaluate price based on the total lump sum price. Analysis will be performed by one or more of the following tecniques to ensure a fair and reasonable price:

a. Comparison of proposed prices received in response to the RFP.

b. Comparison of the proposed prices with the Independent Government Cost Estimate (IGCE).

c. Comparison of proposed prices with available historical information.

d. Comparison of market survey results.

Evaluation:

The Government reserves the right to eliminate from consideration for award any or all offers at any time prior to award of the contract; to negotiate with offerors in the competitive range; and to award the contract to the Offeror submitting the lowest price proposal.

The Government intends to evaluate proposals and award a contract without discussions with offerors

(except clarifications as described in FAR 15.202(a)(2)) (DEVIATION 2026-O0048). The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary.

In addition, if the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the

Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

ATTACHMENTS:

ATTACHMENT A: Building 47 Specifications

ATTACHMENT B:Building 47 Drawings

ATTACHMENT C: Wage Determination

ATTACHMENT D: Pre-Proposal Inquiry (PPI) form

ATTACHMENT E: B47- Price Proposal Form

ATTACHMENT F: PIEE Vendor Access Instructions

ATTACHMENT G: SECNAV Form 5512

ATTACHMENT H – Site Visit Map

ATTACHMENT I - J&A No. ML-26-04 – Redacted

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

Attachment A

Specifications

See separately attached PDF File labeled as follows:

ATTACHMENT A: Building 47 Specifications

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

Attachment B

Drawings

See separately attached PDF File labeled as follows:

ATTACHMENT B: Building 47 Drawings

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

Attachment C

Wage Determination

"General Decision Number: RI20260001 05/18/2026

State: Rhode Island

Construction Types: Building, Heavy and Highway

Counties: Rhode Island Counties of

Bristol, Kent, Newport, Providence and

Washington

Includes Marine Construction Projects

Modification Number Publication Date

2 01/30/2026

3 05/18/2026

ASBE0006-006 09/01/2024

Rates Fringes

HAZARDOUS MATERIAL HANDLER (INCLUDES PREPARATION,

WETTING, STRIPPING, REMOVAL SCRAPPING, VACUUMING,

BAGGING & DISPOSING OF ALL INSULATION MATERIALS,

WHETHER THEY CONTAIN ASBESTOS OR NOT, FROM

MECHANICAL SYSTEMS).................................$ 49.91 36.63

ASBE0006-008 09/01/2024

ASBESTOS WORKER/INSULATOR (INCLUDES APPLICATION OF

ALL INSULATING MATERIALS, PROTECTIVE COVERINGS,

COATINGS & FINISHES TO ALL TYPES OF MECHANICAL

SYSTEMS)............................................$ 49.91 36.63

BOIL0029-001 01/01/2025

BOILERMAKER.........................................$ 50.62 28.82

BRRI0003-001 06/01/2022

BRICKLAYER, STONEMASON, POINTER, CAULKER & CLEANER..$ 46.86 29.14

BRRI0003-002 09/01/2022

MARBLE SETTER, TERRAZZO WORKER & TILE SETTER........$ 46.54 30.34

BRRI0003-003 09/01/2022

MARBLE, TILE & TERRAZZO FINISHER....................$ 38.78 29.61

CARP0330-001 01/01/2023

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP0330-001 06/02/2025

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP1121-002 04/21/2025

MILLWRIGHT..........................................$ 45.72 31.50

ELEC0099-002 06/01/2025

TELEDATA SYSTEM INSTALLER FOOTNOTES: WORK OF

A HAZARDOUS NATURE, OR WHERE THE WORK HEIGHT IS 30

FT. OR MORE FROM THE FLOOR, EXCEPT WHEN WORKING

OSHA-APPROVED LIFTS: 20% PER HOUR ADDITIONAL.

WORK IN TUNNELS BELOW GROUND LEVEL IN COMBINED

SEWER OUTFALL: 20% PER HOUR ADDITIONAL..............$ 42.09 19.71

ELECTRICIAN FOOTNOTES: WORK OF A HAZARDOUS

NATURE, OR WHERE THE WORK HEIGHT IS 30 FT. OR MORE

FROM THE FLOOR, EXCEPT WHEN WORKING OSHA-APPROVED

LIFTS: 20% PER HOUR ADDITIONAL. WORK IN TUNNELS

BELOW GROUND LEVEL IN COMBINED SEWER OUTFALL: 20%

PER HOUR ADDITIONAL.................................$ 56.11 24.74

ELEV0039-001 01/01/2025

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

ELEVATOR MECHANIC FOOTNOTES: A. PAID HOLIDAYS:

NEW YEARS DAY; MEMORIAL DAY; INDEPENDENCE DAY;

LABOR DAY; VETERANS' DAY; THANKSGIVING DAY; THE

FRIDAY AFTER THANKSGIVING DAY; AND CHRISTMAS DAY.

B. EMPLOYER CONTRIBUTES 8% BASIC HOURLY RATE FOR

5 YEARS OR MORE OF SERVICE OF 6% BASIC HOURLY RATE

FOR 6 MONTHS TO 5 YEARS OF SERVICE AS VACATION PAY

CREDIT..............................................$ 64.52 38.44

ENGI0057-001 12/01/2025

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 9 BOAT & TUG OPERATOR.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET

AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210

FEET AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00

270 FEET AND OVER + $ 7.00 300 FEET AND OVER + $

8.00 350 FEET AND OVER + $ 9.00 400 FEET AND OVER

+ $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 8 HEATER, CONCRETE MIXER, STONE

CRUSHER, WELDING MACHINE, GENERATOR AND LIGHT

PLANT, GAS AND ELECTRIC DRIVEN PUMP AND AIR

COMPRESSOR.

A. BOOM

LENGTHS, INCLUDING JIBS: 150 FEET AND OVER + $

2.00 180 FEET AND OVER + $ 3.00 210 FEET AND OVER

+ $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET AND

OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350 FEET

AND OVER + $ 9.00 400 FEET AND OVER + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 45.00 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 7 UTILITY ENGINEERS AND SIGNAL PERSONS

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

A.

BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER +

$ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 6 WELL-POINT INSTALLATION CREW.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND

OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET

AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270

FEET AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00

350 FEET AND OVER + $ 9.00 400 FEET AND OVER +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 39.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 5 BULLDOZER, BOBCATS, SKID STEER

LOADER, TRACTOR, SCRAPER, COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE-POWERED SWEEPER (3-YD.

CAPACITY), 8-FT. SWEEPER MINIMUM 65 HP).

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.35 29.95

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 4 OILER ON CRAWLER BACKHOE.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER

+ $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 42.07 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 3 OILERS ON CRANES.

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 2 DIGGING MACHINE, ROSS CARRIER,

LOCOMOTIVE, HOIST, ELEVATOR, BIDWELL-TYPE MACHINE,

SHOT & WATER BLASTING MACHINE, PAVER, SPREADER,

GRADERS, FRONT END LOADER (3 YDS. AND OVER),

VIBRATORY HAMMER & VACUUM TRUCK, ROADHEADERS,

FORKLIFTS, ECONOMOBILE TYPE EQUIPMENT, TUNNEL

BORING MACHINES, CONCRETE PUMP AND ON SITE CONCRETE

PLANTS.

A. BOOM LENGTHS, INCLUDING

JIBS: 150 FEET AND OVER + $ 2.00 180 FEET AND

OVER + $ 3.00 210 FEET AND OVER + $ 4.00 240 FEET

AND OVER + $ 5.00 270 FEET AND OVER + $ 7.00 300

FEET AND OVER + $ 8.00 350 FEET AND OVER + $ 9.00

400 FEET AND OVER + $10.00 A. PAID HOLIDAYS: NEW

YEAR'S DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY

FOURTH, VICTORY DAY, LABOR DAY, COLUMBUS DAY,

VETERANS DAY, THANKSGIVING DAY, CHRISTMAS DAY. A:

ANY EMPLOYEE WHO WORKS 3 DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. A.

FOOTNOTES: HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL.......$ 49.30 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS

A. BOOM LENGTHS,

INCLUDING JIBS: 150 FEET AND OVER + $ 2.00 180

FEET AND OVER + $ 3.00 210 FEET AND OVER + $ 4.00

240 FEET AND OVER + $ 5.00 270 FEET AND OVER + $

7.00 300 FEET AND OVER + $ 8.00 350 FEET AND OVER

+ $ 9.00 400 FEET AND OVER + $10.00 A. PAID

HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 51.30 29.95

ENGI0057-003 12/01/2025

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 8 HEATER, CONCRETE MIXER, STONE CRUSHER,

WELDING MACHINE, GENERATOR FOR LIGHT PLANT, GAS AND

ELECTRIC DRIVEN PUMP & AIR COMPRESSOR

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND OVER:

+ $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT. AND

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 44.54 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 7 WELL POINT INSTALLATION CREW

A. BOOM LENTHS,

INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00 180

FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $ 4.00

240 FT. AND OVER: + $ 5.00 270 FT. AND OVER: + $

7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND OVER:

+ $ 9.00 400 FT. AND OVER: + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 47.22 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 6 BULLDOZER,SKID STEER LOADERS,BOBCATS,

TRACTOR, GRADER, SCRAPER,COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE POWERED SWEEPER (3 YDS.

CAPACITY), 8-FT. SWEEPER (MINIMUM 65 HP)

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 47.65 29.95

GROUP 5 OILER ON CRAWLER BACKHOE

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND

OVER: + $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT.

AND OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270

FT. AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00

350 FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 41.50 29.95

GROUP 4 FIREMAN & OILER ON CRANES

LENTHS, INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.35 29.95

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

GROUP 3 TELEHANDLER EQUIPMENT, FORKLIFT, CONCRETE

PUMP & ON-SITE CONCRETE PLANT

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 48.35 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 2 DIGGING MACHINE, ROSS CARRIER, LOCOMOTIVE,

HOIST, ELEVATOR, BIDWELL-TYPE MACHINE, SHOT & WATER

BLASTING MACHINE, PAVER, SPREADER, FRONT END LOADER

(3 YDS. AND OVER), VIBRATORY HAMMER AND VACUUM

TRUCK

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.57 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS.

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 50.57 29.95

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

ENGI0057-005 12/01/2025

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 8 GAS

AND ELECTRIC DRIVE HEATERS, CONCRETE MIXERS, LIGHT

PLANTS, WELDING MACHINES, PUMPS AND COMPRESSORS

A. FOOTNOTE: A. ANY

EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 38.70 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 7

COMBINATION LOADER / BACKHOES, FRONT-END LOADERS

(LESS THAN 3 YDS.), FORKLIFT, BULLDOZERS, SCRAPERS,

BOATS, ROLLERS, SKID STEER LOADERS (REGARDLESS OF

ATTACHMENTS), STREET SWEEPERS, MECHANICS, WELDERS,

OPERATORS IN MATERIALS YARDS, SHOPS AND GARAGES

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 43.43 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 6

OILERS ON CRANES AND DECKHANDS

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 39.73 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 5

SIGNAL PERSONS

A.

FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 4

UTILITY ENGINEERS

A. FOOTNOTE:

A. ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 25.75 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 3

WELLPOINT INSTALLATION AND DRILL/BORING MACHINE

ASSISTANTS

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 39.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 2

DIGGING MACHINES, EXCAVATORS, LOCOMOTIVES, JOHN

HENRY'S, DIRECTIONAL DRILLING MACHINES, COLD

PLANERS, RECLAIMERS, PAVERS, SPREADERS, GRADERS,

FRONT-END LOADERS (3YDS & OVER), VACUUM TRUCK,

DRILL/BORING MACHINE OPERATORS, VERMEER SAW, WATER

BLASTER, HYDRAULIC-DEMOLITION ROBOT, ROSS CARRIERS,

CONCRETE PUMP OPERATORS, ASPHALT/MATERIAL TRANSFER

MACHINES, ROTATING TELEHANDLERS, SPMT TYPE

EQUIPMENT

A. FOOTNOTE: A.

ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 44.45 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 1

CRANES, PILE DRIVERS, LIGHTERS, BOOM TRUCKS,

HOISTS, DERRICKS

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 46.45 29.95

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

IRON0037-001 09/16/2025

IRONWORKER..........................................$ 43.03 33.53

LABO0271-001 12/03/2023

LABORER GROUP 5 (BUILDING CONSTRUCTION).............$ 39.00 26.90

LABORER GROUP 4 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 3 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 2 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 1 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABO0271-002 11/27/2022

LABORER TEST BORING LABORER.........................$ 41.95 24.15

LABORER TEST BORING DRILLER.........................$ 41.95 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW TOP MAN & LABORER...................$ 35.60 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW BOTTOM MAN..............................$ 41.50 24.15

LABORER FREE AIR GROUP 3............................$ 42.45 24.15

LABORER FREE AIR GROUP 2............................$ 45.00 24.15

LABORER FREE AIR GROUP 1............................$ 46.00 24.15

LABORER COMPRESSED AIR GROUP 3......................$ 42.45 24.15

LABORER COMPRESSED AIR GROUP 2......................$ 52.93 24.15

LABORER COMPRESSED AIR GROUP 1......................$ 55.40 24.15

PAIN0011-005 06/01/2025

PAINTER (SPRAY, SAND & WATER BLASTING)..............$ 42.57 26.60

PAINTER (EPOXY, TANKS, TOWERS, SWING STAGE &

STRUCTURAL STEEL)...................................$ 41.57 26.60

PAINTER (BRUSH AND ROLLER)..........................$ 39.57 26.60

PAIN0011-006 06/01/2024

GLAZIER FOOTNOTES: SWING STAGE: $1.00 PER

HOUR ADDITIONAL. PAID HOLIDAYS: LABOR DAY &

CHRISTMAS DAY.......................................$ 41.63 26.15

PAIN0011-011 06/01/2024

PAINTER (BRIDGE WORK)...............................$ 57.85 26.40

PAIN0035-008 06/01/2011

SIGN PAINTER........................................$ 24.79 13.72

PLAS0040-001 01/01/2025

CEMENT MASON/CONCRETE FINISHER (BUILDING

CONSTRUCTION) FOOTNOTE: CEMENT MASON: WORK ON

FREE SWINGING SCAFFOLDS UNDER 3 PLANKS WIDTH AND

WHICH IS 20 OR MORE FEET ABOVE GROUND AND ANY

OFFSET STRUCTURE: $.30 PER HOUR ADDITIONAL..........$ 44.75 29.10

Design-Build (DB), Special Project RM25-4593 – Building 47 Upgrades/Modernization Solicitation No.: N4008526R0234

PLAS0040-002 01/01/2025

CEMENT MASON/CONCRETE FINISHER (HEAVY AND HIGHWAY

CONSTRUCTION).......................................$ 44.75 29.10

PLAS0040-003 01/01/2025

PLASTERER...........................................$ 45.52 29.43

PLUM0051-002 08/25/2025

PLUMBERS AND PIPEFITTERS............................$ 54.34 34.50

ROOF0033-004 12/01/2025

ROOFER..............................................$ 47.49 31.44

SFRI0669-001 04/01/2025

SPRINKLER FITTER....................................$ 53.76 33.44

SHEE0017-002 06/01/2025

SHEET METAL WORKER..................................$ 44.42 41.94

TEAM0251-001 05/01/2025

TRUCK DRIVER: HEAVY AND HIGHWAY CONSTRUCTION: GROUP

5 FOUR- AND FIVE-AXLE EQUIPMENT

FOOTNOTES:

A. PAID HOLIDAYS: NEW YEAR'S DAY, MEMORIAL DAY,

INDEPENDENCE DAY, LABOR DAY, THANKSGIVING DAY AND

CHRISTMAS DAY, PLUS PRESIDENTS' DAY, COLUMBUS DAY,

VETERAN'S DAY & V-J DAY, PROVIDING THE EMPLOYEE HAS

WORKED AT LEAST ONE DAY IN THE CALENDAR WEEK IN

WHICH THE HOLIDAY FALLS. B. EMPLOYEE WHO HAS

BEEN ON THE PAYROLL FOR 1 YEAR OR MORE BUT LESS

THAN 5 YEARS AND HAS WORKED 150 DAYS DURING THE

LAST YEAR OF EMPLOYMENT SHALL RECEIVE 1 WEEK'S PAID

VACATION; 5 TO 10 YEARS - 2 WEEKS' PAID VACATION;

10 OR MORE YEARS - 3 WEEK'S PAID VACATION. C.

EMPLOYEES ON THE SENIORITY LIST SHALL BE PAID A ONE

HUNDRED DOLLAR ($100.00) BONUS FOR EVERY FOUR

HUNDRED (400) HOURS WORKED, UP TO A MAXIMUM OF FIVE

HUNDRED DOLLARS ($500.00) ALL DRIVERS WORKING ON A

DE…