191BWC26B0001.pdf

Document Number: 191BWC26B0001 PROCESSED Page 1 of 42

SOLICITATION,OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER

191BWC26B0001 X

SEALED BID (IFB)

INVITATION TO BID

NEGOTIATED (RFP)

REQUEST FOR

PROPOSAL

2. TYPE OF SOLICITATION 3. DATE ISSUED

04/30/2026

PAGE OF PAGES

1 42

IMPORTANT -The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER

FY254121002

6. PROJECT NUMBER

CODE IBWC_

International Boundary and Water Commission (IBWC)

USIBWC - ACQUISITIONS DIV

4191 NORTH MESA ST

EL PASO, TX 79902-1441

7. ISSUED BY

See Block #14

8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME

Angelica Baca

b. TELEPHONE NO. (Include area code)(NO COLLECT CALLS) c. EMAIL

BacaAX@state.gov

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The Contractor shall begin performance within calendar days and complete it within calendar days after receiving10 award, X notice to proceed. This performance period is X mandatory negotiable. (See __________________________.)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12b).

X YES NO

12b. CALENDAR DAYS

Sealed offers in original and copies to perform the work required are due at the place specified in item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

12:00 MTa.

06/09/2026

b. An offer guarantee X is, is not required.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.c.

30d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

13. ADDITIONAL SOLICITATION REQUIREMENTS:

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

CGFS // CGFS

Document Number: 191BWC26B0001 PROCESSED Page 2 of 42

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CONTACT:

CODE FACILITY CODE

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ___________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY

IPP

Invoices to be uploaded to Invoice Processing Platform at http://www.ipp.gov

CHARLESTON, SC 29415

27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __________ copies to issuing office) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a.NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

Angelica Baca

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 04/30/2026 31c. DATE

STANDARD FORM 1442 (REV. 12/2022)BACK

Document Number: 191BWC26B0001 PROCESSED Page 3 of 42

Table of Contents

Section Description Page Number

B Supplies or Services and Prices/Costs E Inspection and Acceptance

52.246-12 Inspection of Construction (Aug 1996) F Deliveries or Performance

52.211-13 Time Extensions (Sept 2000) 52.236-15 Schedules for Construction Contracts (DEVIATION JUL 2025) 52.242-14 Suspension of Work (Apr 1984) 52.211-12 Liquidated Damages-Construction (Sept 2000)

I Contract Clauses 52.202-1 Definitions (Jun 2020) 52.203-3 Gratuities (Apr 1984) 52.203-5 Covenant Against Contingent Fees (May 2014) 52.203-6 Restrictions on Subcontractor Sales to the Government (Jun 2020) 52.203-7 Anti-Kickback Procedures (Jun 2020) 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (May 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (May 2014) 52.203-12 Limitation On Payments to Influence Certain Federal Transactions (Jun 2020) 52.203-16 Preventing Personal Conflicts of Interest (Jun 2020) 52.203-17 Contractor Employee Whistleblower Rights (Nov 2023) 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) 52.204-2 Security Requirements (Mar 2021) 52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011) (DEVIATION) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (DEVIATION JAN 2026) 52.204-13 System for Award Management-Maintenance (DEVIATION JAN 2026) 52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014) 52.204-21 Basic Safeguarding of Covered Contractor Information Systems (Nov 2021) 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021) 52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded (DEVIATION JAN 2026) 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (DEVIATION

JAN 2026)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (DEVIATION JAN 2026) 52.219-6 Notice of Total Small Business Set-Aside (DEVIATION FEB 2026) 52.219-8 Utilization of Small Business Concerns (DEVIATION FEB 2026) 52.222-3 Convict Labor (DEVIATION FEB 2026) 52.222-4 Contract Work Hours and Safety Standards--Overtime Compensation (DEVIATION FEB 2026) 52.222-7 Withholding of Funds (DEVIATION FEB 2026) 52.222-8 Payrolls and Basic Records (DEVIATION FEB 2026) 52.222-10 Compliance with Copeland Act Requirements (DEVIATION FEB 2026) 52.222-11 Subcontracts (Labor Standards) (DEVIATION FEB 2026) 52.222-12 Contract Termination-Debarment (MAY 2014)(DEVIATION FEB 2025) 52.222-15 Certification of Eligibility (May 2014) 52.222-20 Contracts for Materials, Supplies, Articles, and Equipment (DEVIATION FEB 2026)..

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method) (Aug 2018) 52.222-35 Equal Opportunity for Veterans (DEVIATION FEB 2026) 52.222-36 Equal Opportunity for Workers with Disabilities (DEVIATION FEB 2026) 52.222-37 Employment Reports on Veterans (DEVIATION FEB 2026)

Document Number: 191BWC26B0001 PROCESSED Page 4 of 42

52.222-40 Notification of Employee Rights Under the National Labor Relations Act (DEVIATION

FEB 2026)

52.222-50 Combating Trafficking in Persons (DEVIATION FEB 2026) 52.222-54 Employment Eligibility Verification (DEVIATION FEB 2026) 52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026 (DEVIATION FEB 2026) 52.222-62 Paid Sick Leave Under Executive Order 13706 (DEVIATION FEB 2026) 52.223-5 Pollution Prevention and Right-to-Know Information (May 2024) 52.224-3 Privacy Training (JAN 2017)(DEVIATION) 52.225-10 Notice of Buy American Requirement-Construction Materials (May 2014) 52.225-13 Restrictions on Certain Foreign Purchases (Feb 2021) 52.227-17 Rights in Data - Special Works (Dec 2007) 52.228-2 Additional Bond Security (Oct 1997) 52.228-5 Insurance-Work on a Government Installation (Jan 1997) 52.228-11 Individual Surety-Pledge of Assets (Feb 2021) 52.228-14 Irrevocable Letter of Credit (Nov 2014) 52.228-15 Performance and Payment Bonds-Construction (Jun 2020) 52.229-3 Federal, State and Local Taxes (Feb 2013) 52.232-5 Payments under Fixed-Price Construction Contracts (May 2014) 52.232-17 Interest (May 2014) 52.232-23 Assignment of Claims (May 2014) 52.232-27 Prompt Payment for Construction Contracts (Jan 2017) 52.232-33 Payment by Electronic Funds Transfer-System for Award Management (Oct 2018) 52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) 52.233-1 Disputes (DEVIATION JAN 2026) 52.233-1 Alt I Disputes - Alternate I (DEVIATION JAN 2026) 52.233-3 Protest after Award (DEVIATION JAN 2026) 52.233-4 Applicable Law for Breach of Contract Claim (DEVIATION JAN 2026) 52.236-5 Material and Workmanship (DEVIATION JUL 2025) 52.236-6 Superintendence by the Contractor (DEVIATION JUL 2025) 52.236-7 Permits and Responsibilities (DEVIATION JUL 2025) 52.236-8 Other Contracts (DEVIATION JUL 2025) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

(DEVIATION JUL 2025)

52.236-10 Operations and Storage Areas (DEVIATION JUL 2025) 52.236-11 Use and Possession Prior to Completion (DEVIATION JUL 2025) 52.236-12 Cleaning Up (DEVIATION JUL 2025) 52.236-13 Accident Prevention (DEVIATION JUL 2025) 52.236-16 Quantity Surveys (DEVIATION JUL 2025) 52.236-17 Layout of Work (DEVIATION JUL 2025) 52.236-21 Specifications and Drawings for Construction (DEVIATION JUL 2025) 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) - Alternate I (Apr 1984) 52.236-26 Preconstruction Conference (Feb 1995) 52.242-5 Payments to Small Business Subcontractors (Jan 2017) 52.242-13 Bankruptcy (July 1995) 52.243-4 Changes (DEVIATION JUN 2025) 52.243-5 Changes and Changed Conditions (DEVIATION JUN 2025) 52.244-6 Subcontracts for Commercial Products and Commercial Services (DEVIATION JAN 2026) 52.246-21 Warranty of Construction (Mar 1994) 52.249-10 Default (Fixed-Price Construction) (Apr 1984) 52.253-1 Computer Generated Forms (DEVIATION FEB 2026) 52.203-14 Display of Hotline Poster(s) (Nov 2021) 52.219-14 Limitations on Subcontracting (DEVIATION FEB 2026) 52.219-28 Postaward Small Business Program Rerepresentation (DEVIATION FEB 2026) 52.222-6 Construction Wage Rate Requirements (DEVIATION FEB 2026) 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)

Document Number: 191BWC26B0001 PROCESSED Page 5 of 42

52.222-14 Disputes Concerning Labor Standards (DEVIATION FEB 2026) 52.222-32 Construction Wage Rate Requirements-Price Adjustment (Actual Method) (DEVIATION

FEB 2026)

52.225-9 Buy American-Construction Materials (DEVIATION FEB 2026) 52.232-16 Progress Payments (DEVIATION FEB 2026) 52.232-16 Alt I Progress Payments (Nov 2021) - Alternate I (Mar 2000) 52.236-1 Performance of Work by the Contractor (Apr 1984) 52.236-2 Differing Site Conditions (DEVIATION JUL 2025) 52.236-3 Site Investigation and Conditions Affecting the Work (DEVIATION JUL 2025) 52.236-4 Physical Data (Apr 1984)

K Representations, Certifications, and Other Statements of Offerors or Respondents 52.204-8 Annual Representations and Certifications (Mar 2026) 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021) 52.209-7 Information Regarding Responsibility Matters (DEVIATION JAN 2026) 52.209-13 Violation of Arms Control Treaties or Agreements-Certification (DEVIATION JAN 2026)

L Instructions, Conditions, and Notices to Offerors and Respondents 52.252-1 Solicitation Provisions Incorporated by Reference (Feb 1998) 52.204-7 System for Award Management - REGISTRATION (DEVIATION JAN 2026) 52.204-22 Alternative Line Item Proposal (Jan 2017) 52.214-4 False Statements in Bids (Apr 1984) 52.214-3 Amendments to Invitations for Bids (DEVIATION FEB 2026) 52.214-5 Submission of Bids (DEVIATION FEB 2026) 52.214-6 Explanation to Prospective Bidders (Apr 1984) 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids (DEVIATION FEB 2026)...

52.214-18 Preparation of Bids-Construction (Apr 1984) 52.214-19 Contract Award-Sealed Bidding-Construction (Aug 1996) 52.216-1 Type of Contract (DEVIATION FEB 2026) 52.228-1 Bid Guarantee (Sept 1996) 52.233-2 Service of Protest (DEVIATION JAN 2026) 52.236-27 Site Visit (Construction) (Feb 1995)

Document Number: 191BWC26B0001 PROCESSED Page 6 of 42

Section B - Supplies or Services and Prices/Costs

Line Item Summary

Solicitation Number:

191BWC26B0001

Contract Number: Title:

Amistad Tainter Gates Sandblasting and pai

Date of Solicitation:

04/30/2026

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

1.0 LS $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 1.000000 Destination

Description: MOBILIZATION/DEMOBILIZATION - As per Scope of Work attached

Reference Line: FY254121002 - 001

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

8.0 EA $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 8.000000 Destination

Description: RADIAL GATES SEAL ASSEMBLY REPLACEMENT - As per Scope of Work attached

Reference Line: FY254121002 - 002

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

8.0 EA $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 8.000000 Destination

Description: RADIAL GATES PRESSURE WASH, SANDBLAST, REPAIR, LUBRICATE AND PAINT - As per Scope of Work attached

Reference Line: FY254121002 - 003

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

8.0 EA $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 8.000000 Destination

Description: REPLACE ANODES - As per Scope of Work attached

Reference Line: FY254121002 - 004

Document Number: 191BWC26B0001 PROCESSED Page 7 of 42

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

1.0 LS $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 1.000000 Destination

Description: WELD INSPECTION REPAIRS - As per Scope of Work attached

Reference Line: FY254121002 - 005

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

16.0 EA $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 16.000000 Destination

Description: TRUNNION PIN REHABILITATION - As per Scope of Work attached

Reference Line: FY254121002 - 006

Number Supplies or Services Qty Unit Unit Price Total (Inc. disc., tax, and fees)

PSC: Z1PZ

PSC Description: MAINTENANCE OF OTHER NON-

BUILDING FACILITIES

Type of Contract Pricing: Firm Fixed Price

1.0 LS $0.00 $0.00

Delivery Schedule:

Delivery Number Quantity FOB Point 1 1.000000 Destination

Description: DISPOSAL, TESTING, AND FINAL INSPECTION - As per Scope of Work attached

Reference Line: FY254121002 - 007

Invoices to be uploaded to Invoice Processing Platform at http://www.ipp.gov

CLIN Funding: Cost:

Base Totals: $0.00 $0.00

Exercised Options Totals: $0.00 $0.00

Unexercised Options Totals: $0.00 $0.00

Base and Options Totals: $0.00 $0.00

Section E - Inspection and Acceptance

Clause Title Fill-ins

52.246-12 Inspection of Construction (Aug 1996)

Section F - Deliveries or Performance

Clause Title Fill-ins

52.211-13 Time Extensions (Sept 2000)

Document Number: 191BWC26B0001 PROCESSED Page 8 of 42

52.236-15 Schedules for Construction Contracts (DEVIATION JUL 2025)

52.242-14 Suspension of Work (Apr 1984)

52.211-12 - Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of Construction Daily Rate $1,349.49, Closeout Daily Rate $403.64 [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

Section I - Contract Clauses

Clause Title Fill-ins

52.202-1 Definitions (Jun 2020)

52.203-3 Gratuities (Apr 1984)

52.203-5 Covenant Against Contingent Fees (May 2014)

52.203-6 Restrictions on Subcontractor Sales to the Government (Jun 2020)

52.203-7 Anti-Kickback Procedures (Jun 2020)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper

Activity (May 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (May 2014)

52.203-12 Limitation On Payments to Influence Certain Federal Transactions (Jun 2020)

52.203-16 Preventing Personal Conflicts of Interest (Jun 2020)

52.203-17 Contractor Employee Whistleblower Rights (Nov 2023)

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (Jan 2017)

52.204-2 Security Requirements (Mar 2021)

52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011)

(DEVIATION)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

(DEVIATION JAN 2026)

52.204-13 System for Award Management-Maintenance (DEVIATION JAN 2026)

Document Number: 191BWC26B0001 PROCESSED Page 9 of 42

52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems (Nov 2021)

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video

Surveillance Services or Equipment (Nov 2021)

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors

Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

(DEVIATION JAN 2026)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

(DEVIATION JAN 2026)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations

(DEVIATION JAN 2026)

52.219-6 Notice of Total Small Business Set-Aside (DEVIATION FEB 2026)

52.219-8 Utilization of Small Business Concerns (DEVIATION FEB 2026)

52.222-3 Convict Labor (DEVIATION FEB 2026)

52.222-4 Contract Work Hours and Safety Standards--Overtime Compensation

(DEVIATION FEB 2026)

52.222-7 Withholding of Funds (DEVIATION FEB 2026)

52.222-8 Payrolls and Basic Records (DEVIATION FEB 2026)

52.222-10 Compliance with Copeland Act Requirements (DEVIATION FEB 2026)

52.222-11 Subcontracts (Labor Standards) (DEVIATION FEB 2026)

52.222-12 Contract Termination-Debarment (MAY 2014)(DEVIATION FEB 2025)

52.222-15 Certification of Eligibility (May 2014)

52.222-20 Contracts for Materials, Supplies, Articles, and Equipment (DEVIATION

FEB 2026)

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or

Separately Specified Method) (Aug 2018)

52.222-35 Equal Opportunity for Veterans (DEVIATION FEB 2026)

52.222-36 Equal Opportunity for Workers with Disabilities (DEVIATION FEB 2026)

Document Number: 191BWC26B0001 PROCESSED Page 10 of 42

52.222-37 Employment Reports on Veterans (DEVIATION FEB 2026)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

(DEVIATION FEB 2026)

52.222-50 Combating Trafficking in Persons (DEVIATION FEB 2026)

52.222-54 Employment Eligibility Verification (DEVIATION FEB 2026)

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026

(DEVIATION FEB 2026)

52.222-62 Paid Sick Leave Under Executive Order 13706 (DEVIATION FEB 2026)

52.223-5 Pollution Prevention and Right-to-Know Information (May 2024)

52.224-3 Privacy Training (JAN 2017)(DEVIATION)

52.225-10 Notice of Buy American Requirement-Construction Materials (May 2014)

52.225-13 Restrictions on Certain Foreign Purchases (Feb 2021)

52.227-17 Rights in Data - Special Works (Dec 2007)

52.228-2 Additional Bond Security (Oct 1997)

52.228-5 Insurance-Work on a Government Installation (Jan 1997)

52.228-11 Individual Surety-Pledge of Assets (Feb 2021)

52.228-14 Irrevocable Letter of Credit (Nov 2014)

52.228-15 Performance and Payment Bonds-Construction (Jun 2020)

52.229-3 Federal, State and Local Taxes (Feb 2013)

52.232-5 Payments under Fixed-Price Construction Contracts (May 2014)

52.232-17 Interest (May 2014)

52.232-23 Assignment of Claims (May 2014)

52.232-27 Prompt Payment for Construction Contracts (Jan 2017)

52.232-33 Payment by Electronic Funds Transfer-System for Award Management (Oct

2018)

52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Mar

2023)

52.233-1 Disputes (DEVIATION JAN 2026)

52.233-1 Alt I Disputes - Alternate I (DEVIATION JAN 2026)

Document Number: 191BWC26B0001 PROCESSED Page 11 of 42

52.233-3 Protest after Award (DEVIATION JAN 2026)

52.233-4 Applicable Law for Breach of Contract Claim (DEVIATION JAN 2026)

52.236-5 Material and Workmanship (DEVIATION JUL 2025)

52.236-6 Superintendence by the Contractor (DEVIATION JUL 2025)

52.236-7 Permits and Responsibilities (DEVIATION JUL 2025)

52.236-8 Other Contracts (DEVIATION JUL 2025)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements (DEVIATION JUL 2025)

52.236-10 Operations and Storage Areas (DEVIATION JUL 2025)

52.236-11 Use and Possession Prior to Completion (DEVIATION JUL 2025)

52.236-12 Cleaning Up (DEVIATION JUL 2025)

52.236-13 Accident Prevention (DEVIATION JUL 2025)

52.236-16 Quantity Surveys (DEVIATION JUL 2025)

52.236-17 Layout of Work (DEVIATION JUL 2025)

52.236-21 Specifications and Drawings for Construction (DEVIATION JUL 2025)

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) - Alternate I (Apr

1984)

52.236-26 Preconstruction Conference (Feb 1995)

52.242-5 Payments to Small Business Subcontractors (Jan 2017)

52.242-13 Bankruptcy (July 1995)

52.243-4 Changes (DEVIATION JUN 2025)

52.243-5 Changes and Changed Conditions (DEVIATION JUN 2025)

52.244-6 Subcontracts for Commercial Products and Commercial Services

(DEVIATION JAN 2026)

52.246-21 Warranty of Construction (Mar 1994)

52.249-10 Default (Fixed-Price Construction) (Apr 1984)

52.253-1 Computer Generated Forms (DEVIATION FEB 2026)

52.203-14 - Display of Hotline Poster(s) (Nov 2021)

(a) Definition.

Document Number: 191BWC26B0001 PROCESSED Page 12 of 42

"United States," as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)--

(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites--

(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

(3) Any required posters may be obtained as follows:

Poster(s) Obtain from All related work posters https://www.dol.gov/agencies/whd/posters

(Contracting Officer shall insert- (i) Appropriate agency name(s) and/or title of applicable Department of Homeland Security fraud hotline poster); and

(ii) The website(s) or other contact information for obtaining the poster(s).)

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the threshold specified in Federal Acquisition Regulation 3.1004(b)(1) on the date of subcontract award, except when the subcontract--

(1) Is for the acquisition of a commercial product or commercial service; or

(2) Is performed entirely outside the United States.

(End of clause)

52.219-14 - Limitations on Subcontracting (DEVIATION FEB 2026)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that—

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to—

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with sections 19.105, 19.106, 19.107, and 19.108;

(4) Orders expected to exceed the simplified acquisition threshold and that are set aside for small business concerns under multiple-award contracts, as described in 8.4 and 16.5;

Document Number: 191BWC26B0001 PROCESSED Page 13 of 42

(5) Orders, regardless of dollar value, that are set aside in accordance with sections 19.105, 19.106, 19.107, and

19.108 under multiple-award contracts, as described in 8.4 and 16.5; and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for—

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause—[Contracting Officer check as appropriate.]

X By the end of the base term of the contract and then by the end of each subsequent option period; or

__ By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protégé and its mentor approved by the Small Business Administration, the small business protégé shall perform at least 40 percent of the work performed by the joint venture. Work performed by the small business protégé in the joint venture must be more than administrative functions.

(2) In an 8(a) joint venture, the 8(a) participant(s) shall perform at least 40 percent of the work performed by the joint venture. Work performed by the 8(a) participants in the joint venture must be more than administrative functions.

(End of clause)

52.219-28 - Postaward Small Business Program Rerepresentation (DEVIATION FEB 2026)

(a) Definitions. As used in this clause— Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern—

Document Number: 191BWC26B0001 PROCESSED Page 14 of 42

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others.

In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/ document/support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition—

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph

(b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it __ is, __ is not a small business concern under NAICS Code ____________ assigned to contract number ____________________.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it __ is, __ is not, a small disadvantaged business concern as defined in 13

CFR 124.1001.

(3)Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it __ is, __ is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture:

(4) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it __ is, __ is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture:

(5) Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program.

The Contractor represents that it __ is, __ is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402. [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: ____________________.]

Document Number: 191BWC26B0001 PROCESSED Page 15 of 42

(6) HUBZone joint venture eligible under the HUBZone Program.[ Complete only if the offeror is a HUBZone small business concern. ] The offeror represents, as part of its offer, that It __ is, __ is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [ The Contractor shall enter the name and unique entity identifier of each party to the joint venture: ____________________.] Each HUBZone small business concern participating in the HUBZone joint venture must be certified as a HUBZone concern. [ Contractor to sign and date and insert authorized signer's name and title.

52.222-6 - Construction Wage Rate Requirements (DEVIATION FEB 2026)

(a) Definition.—"Site of the work"— (1) Means—

(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed; and

(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is-

(A) Located in the United States; and

(B) Established specifically for the performance of the contract or project;

(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided-

(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and

(ii) They are adjacent or virtually adjacent to the "primary site of the work" as defined in paragraph (a) (1)(i), or the "secondary site of the work" as defined in paragraph (a)(1)(ii) of this definition;

(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the "site of the work." Such permanent, previously established facilities are not a part of the "site of the work" even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.

(b) (1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR Part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work must be effective from the first day on which work under the contract was performed at that site and must be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work must be paid in accordance with the wage determination applicable to the primary site of the work.

(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.

(3) Such laborers and mechanics must be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill, except as provided in the clause entitled Apprentices and Trainees. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein;

provided that the employer’s payroll records accurately set forth the time spent in each classification in which work is performed.

(4) The wage determination (including any additional classifications and wage rates conformed under paragraph

(c) of this clause) and the Construction Wage Rate Requirements (Davis-Bacon Act) poster (WH-1321) must be

Document Number: 191BWC26B0001 PROCESSED Page 16 of 42 posted at all times by the Contractor and its subcontractors at the primary site of the work and the secondary site of the work, if any, in a prominent and accessible place where it can be easily seen by the workers.

(c) (1) The Contractor must complete and submit to the Contracting Officer the Standard Form (SF) 1444, Request for Authorization of Additional Classification and Rate, if any class of laborers or mechanics that is not listed in the wage determination applicable to the contract is to be employed under the contract. Upon receipt of a complete SF 1444, the Contracting Officer will submit a report to the Administrator, Wage and Hour Division, for approving, modifying, disapproving, or rendering a final determination, of the additional classification and wage rate including any amount designated for fringe benefits.

(2) The wage rate (including fringe benefits, where appropriate) determined pursuant to subparagraph (c) of this clause must be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification.

(d) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor must either pay the benefit as stated in the wage determination or must pay another bona fide fringe benefit or an hourly cash equivalent thereof.

(e) If the Contractor does not make payments to a trustee or other third person, the Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program; provided, that the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Construction Wage Rate Requirements statute have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

52.222-13 - Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)

All rulings and interpretations of the Construction Wage Rate Requirements and related statutes contained in 29 CFR parts 1, 3, and 5 are hereby incorporated by reference in this contract.

(End of clause)

52.222-14 - Disputes Concerning Labor Standards (DEVIATION FEB 2026)

The United States Department of Labor has set forth in 29 CFR parts 5, 6, and 7 procedures for resolving disputes concerning labor standards requirements. Such disputes must be resolved in accordance with those procedures and not the Disputes clause of this contract. Disputes within the meaning of this clause include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives.

52.222-32 - Construction Wage Rate Requirements-Price Adjustment (Actual Method) (DEVIATION FEB 2026)

(a) The wage determination issued under the Construction Wage Rate Requirements statute by the Administrator, Wage and Hour Division, U.S. Department of Labor, that is effective for an option to extend the term of the contract, will apply to that option period.

(b) (1) The Contractor states that if the prices in this contract contain an allowance for wage or benefit increases, such allowance will not be included in any request for contract price adjustment submitted under this clause.

(2) The Contractor must provide with each request for contract price adjustment under this clause a statement that the prices in the contract do not include any allowance for any increased cost for which adjustment is being requested.

(c) The Contracting Officer will adjust the contract price or contract unit price labor rates to reflect the Contractor’s actual increase or decrease in wages and fringe benefits to the extent that the increase is made to comply with, or the decrease is voluntarily made by the Contractor as a result of—

Document Number: 191BWC26B0001 PROCESSED Page 17 of 42

(1) Incorporation of the Department of Labor’s Construction Wage Rate Requirements wage determination applicable at the exercise of an option to extend the term of the contract; or

(2) Incorporation of a Construction Wage Rate Requirements wage determination otherwise applied to the contract by operation of law.

(d) Any adjustment will be limited to increases or decreases in wages and fringe benefits as described in paragraph

(c) of this clause, and the accompanying increases or decreases in social security and unemployment taxes and workers’ compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.

(e) The Contractor must notify the Contracting Officer of any increase claimed under this clause within 30 days after receiving a revised wage determination unless this notification period is extended in writing by the Contracting Officer. The Contractor must notify the Contracting Officer promptly of any decrease under this clause, but nothing in this clause precludes the Government from asserting a claim within the period permitted by law. The notice must contain a statement of the amount claimed and any relevant supporting data, including payroll records that the Contracting Officer may reasonably require. Upon agreement of the parties, the Contracting Officer will modify the contract price or contract unit price in writing. The Contractor must continue performance pending agreement on or determination of any such adjustment and its effective date.

(f) Contract price adjustment computations must be computed as follows:

(1) Computation for contract unit price per single craft hour for schedule of indefinite-quantity work. For each labor classification, the difference between the actual wage and benefit rates (combined) paid and the wage and benefit rates (combined) required by the new wage determination must be added to the original contract unit price if the difference results in a combined increase. If the difference computed results in a combined decrease, the contract unit price must be decreased by that amount if the Contractor provides notification as provided in paragraph (e) of this clause.

(2) Computation for contract unit price containing multiple craft hours for schedule of indefinite-quantity work.

For each labor classification, the difference between the actual wage and benefit rates (combined) paid and the wage and benefit rates (combined) required by the new wage determination must be multiplied by the actual number of hours expended for each craft involved in accomplishing the unit-priced work item. The product of this computation will then be divided by the actual number of units ordered in the preceding contract period. The total of these computations for each craft will be added to the current contract unit price to obtain the new contract unit price. The extended amount for the line item will be obtained by multiplying the new unit price by the estimated quantity. If actual hours are not available from the preceding contract period for computation of the adjustment for a specific contract unit of work, the Contractor, in agreement with the Contracting Officer, must estimate the total hours per craft per contract unit of work.

Example: Asphalt Paving--Current Price $3.38 per Square Yard

DBA Craft New WD Hourly rate paid

Diff. Actual Hrs Actual units (sq.

yard)

Increase/ sq yard

Equip. Opr. $18.50 - $18.00 = $.50 x…