1.0. Solicitation W50SLF20R0001 0002.pdf

KABD152001, Repair HVAC System, Maui, HI

This project requires all labor, tools, equipment, transportation, and supervision; as required for the project elements as described in the attached specif ication and plans to repair the existing HVAC system for Bldg 501 at the 292nd Combat Communications Squadron in Kahului Maui, HI.

This action is being solicited as a set-aside 100% for Women Owned Small Business. The North American Industry Classif ication (NAICS) Code is 238220 and the Size Standard for is $16.5M average total revenue for the past three years. Project magnitude is between $500,000.00 and $1,000,000.00. A single award is contemplated. Offerors intending on submitting proposals should attend the Pre-Proposal Conference. See Section 00100 for specific registration information and base access requirements. Failure to submit an offer on all items shall result in rejection of the proposal. Solicitation and all information, notices, amendments for this solicitation w ill be posted at https://beta.sam.gov/. Instructions for obtaining plans and specif ications and other secured documents for this solicitation are located in Section 00100.

Funds are not presently available for this contract. Currently, the Government anticipates funds will become available prior to, but no later than, midnight 30 September 2020. This action has been identified on the National Guard priority list for award if funds become available and the prices received are within an awardable range.

Award will be made to the offeror who represents the best value to the Government as outlined in accordance with the criteria set forth within the solicitation.

MSGT CEZAR Y. DEVEAS 808-844-6422

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

03-Aug-2020

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________180 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________3 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________03 Sep 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USPFO HI 154 MSC

360 MALAMA BAY DRIVE

JBPHH HI 96853-5517

W50SLF

PAGE OF PAGES

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W50SLF20R0001 1 OF 88

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W50SLF20R0001

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job KABD152001, Repair HVAC System, Maui, HI

FFP

THIS CLIN IS A TOTAL OF 000101, 000102, 000103, 000104, 000105, and 000106 Construction FFP- Contractor shall provide all labor, tools, equipment, transportation, and supervision; as required for the project elements as described in the attached specification and plans to repair the existing HVAC system for Bldg 501 at the 292nd Combat Communications Squadron in Kahului Maui, HI.

FOB: Destination

SIGNAL CODE: A

PSC CD: Z2AZ

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Contractor Manpower Reporting

FFP

The contractor shall report ALL contractor labor hours (including subcontractor Labor hours) required for performance of services provided under this contract via a secure data collection site. The contractor is required to completely fill in all required data fields using the following web address : https://www.sam.gov/SAM/.

Reporting inputs will be for the labor executed during the period of performance during the Government fiscal year (FY), which runs October 1 through September

30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year, beginning with October 31, 2020.

Contractors may direct questions to the help desk at https://www.sam.gov/SAM/.

FOB: Destination

SIGNAL CODE: A

PSC CD: Z2AZ

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 180 dys. ANP 1 F7C31A-154 CES

RAY OLIVEIRA

75 KULEANA ST

KAHULUI HI 96732-2330

808-789-0106 FOB: Destination

F7C31A

0002 180 dys. ANP 1 F7C31A-154 CES

RAY OLIVEIRA

75 KULEANA ST

KAHULUI HI 96732-2330

808-448-8241 X4446611 FOB: Destination

F7C31A

SECTION 00010

SECTION 00010 Solicitation Contract Form

CLIN Description

QTY

UNIT PRICE

0001 BASE BID-Total of all sub line items listed below

JOB $

000101 BASE BID-Equipment - Air Handling Units, 6 qty (Including shipping and delivery)

000102 BASE BID-Equipment - Fan Coil Unit, 1 qty

000103 BASE BID-Equipment - Split AC Units, 3 qty

000104 BASE BID-Other Material/Equipment

000105 BASE BID-Labor (Demolition and Renovation)

000106 BASE BID-Other Direct Costs

TABLE OF CONTENTS

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00010 - PRICING SCHEDULE, NOTES

SECTION 00100 - INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

SECTION 00600 – REPRESENTATIONS & CERTIFICATIONS

SECTION 00700 - CONTRACT CLAUSES

SECTION 00800 – Wage Determination

ATTACHMENT 1 – STATEMENT OF WORK Project No. KABD152001 dated 26 March 2020 ATTACHMENT 2 – SPECIFICATIONS Project No. KABD152001 dated May 2017 ATTACHMENT 3 – REFERENCE DRAWINGS dated 1 June 1982/ISSUE FOR CONSTRUCTION 20 August 2014

EXHIBIT A- Performance Relevancy Questionnaire EXHIBIT B- Subcontractor Information and Consent Form EXHIBIT C- Reference Questionnaire package

SECTION 00010 NOTES

NOTES

1. Instructions for the preparation of proposals are located in Sections 00100, 00110 and 00120.

2. Offeror’s attention is invited to the insurance requirement contained in this solicitation (FAR Clause 52.228-5 Insurance – Work on a Government Installation). Certification of the required coverage for the prime contractor shall be furnished prior to beginning work on this contract, and the Contracting Officer may request evidence of the required insurance at any time during the life the contract.

3. Reference DFARS Provision 252.236-7008, Contract Prices – Bidding Schedules. The term “Bidding Schedule” shall also be construed to mean “Offer Schedule” or “Schedule”. The terms “bid” and “offer”, and “bidder” and “offeror” shall be construed as having the same meaning in this solicitation and resulting contract.

Section 00100 - Bidding Schedule/Instructions to Bidders

SECTION 00100

Section 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. SCOPE

1.1. You are invited to submit a proposal in response to our Request for Proposal W50SLF-20-R-0001 for Project No. KABD152001 at 292nd Combat Communications Squadron in Kahului, Maui, HI. As a result of this solicitation, the Government intends to award a single Firm Fixed Price (FFP) contract to the responsible offeror whose proposal represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

1.2. This solicitation is set-aside 100% for women owned small business.

2. NOTICE OF PRE-PROPOSAL CONFERENCE

2.1. A pre-proposal conference will be conducted on 10-Aug-2020 at 11:30am for the purposes of briefing on the proposal requirements and answering questions regarding this solicitation. This conference will be held at 292nd Combat Communications Squadron, 75 Kuleana St, Kahului, HI 96732. Interested Contractors are highly encouraged to attend the pre-proposal conference. The site visit will be held following the conference.

2.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to cezar.y.deveas.mil@mail.mil and copy to russell.s.redila.mil@mail.mil.

Full Name (First, Middle, Last) Last Four Digits of Social Security No.

Driver’s License No. or State Issued ID Number and Expiration Date Date of Birth Citizenship

2.3. This information must be provided in advance, not later than (3) business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.4. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.6. A record of the conference shall be made and furnished to all prospective offerors via posting to https://beta.sam.gov/. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS

3.1. Submit all questions via email to the contracting office at the address shown below. Do NOT contact the A-E or Engineering personnel directly. Doing so will only delay the response to your question.

Subject Line: Reference No. W50SLF-20-R-0001 Email: cezar.y.deveas.mil@mail.mil and copy to manuel.llanes.mil@mail.mil

INQUIRIES SHALL BE SUBMITTED VIA EMAIL AND INCLUDE THE FOLLOWING INFORMATION:

Date of Proposal Inquiry:

From: ______________________________

Company Name: ___________________________

Phone Number: ____________________________

Email address: _____________________________

Proposal Inquiry: Be specific as to part of solicitation you are questioning.

3.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach offerors before the submission of their offer.

3.3. The Contracting Officer reserves the right to address questions received after the fifth day prior to solicitation closing with those offers deemed compliant and/or in the competitive range after closing. All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to closing and will be posted not later than two working days prior to closing. OFFERORS ARE STRONGLY ENCOURAGED

TO SUBMIT QUESTIONS EARLY IN THIS PROCESS.

3.4. Any interpretations made will be in the form of an amendment of the solicitation, drawings, specifications, etc., and will be furnished to all prospective offerors via posting to https://beta.sam.gov/.

3.4.1. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of proposals. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding. Questions (on a non-attribution basis) and answers shall be furnished to all prospective offerors via the web site.

3.4.2. For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (https://beta.sam.gov/) system. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Plans and specifications are locked on FBO and require Contractors to request explicit access from the Contracting Officer OR export controlled access through DLA. See the instructions on FBO regarding registration as Interested bidders/offerors must register with FedBizOpps before accessing the system. (Please note the registration for access to the secure site takes approximately 15 business days, so plan accordingly.)

3.4.2.2. Interested offerors must be registered in the System for Award Management (SAM). To register go to:

www.sam.gov. You will need your DUNS number to register. Instructions for registering are on the web page.

4. AMENDMENTS PRIOR TO DATE SET FOR RECEIPT OF PROPOSALS

4.1. The right is reserved, as the interest of the Government may require, to revise or amend, the specifications or drawings or both prior to and/or after the date set for receipt of proposals as necessary. Such amendments, if any, will be announced by an amendment or amendments to this Request for Proposal. All information relating to this RFP, including pertinent changes/amendments and information prior to the date set for receipt of proposals will be posted at https://beta.sam.gov/.

4.2. Offerors are strongly cautioned to check this site frequently and to “refresh” their web page to ensure they have the lasted information.

5. HAND CARRIED PROPOSALS/INVITATIONS

5.1. A bid repository is provided for hand carried proposals and is located at: USPFO HAWAII, 91-1179 Enterprise Ave. Kapolei, HI 96707-2150.

5.2. Hand carried proposals must be deposited in the repository prior to the time established for receipt of proposals.

5.3. Offerors are cautioned that approval to enter the base must be obtained prior to the closing date for receipt of proposals. Follow the procedures outlined below in paragraph 5.3.1. for entry. Delays are probable at the entry point and should be accounted for. Late receipt of proposals due to base entry delays may not be deemed excusable and the Contracting Officer may declare the proposal late and remove it from consideration.

5.3.1 In order to obtain approval to enter the base at Kapolei to deliver a hand carried proposal, visitors must provide the following information to cezar.y.deveas.mil@mail.mil and a copy to manuel.llanes.mil@mail.mil no less than 24 hours prior to the closing date and time listed on https://beta.sam.gov/ for the receipt of proposals:

Full Name (First, Middle, Last) Last Four Digits of Social Security No.

Driver’s License No. or State Issued ID Number and Expiration Date Date of Birth Citizenship

6. WAGE DETERMINATION

6.1. The Construction Wage Rate Requirements formerly known as Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are HI20200001 07/24/2020 for Maui County, Hawaii.

In the event the current prevailing Wage Determination is changed by the Department of Labor prior to the closing date of the solicitation, the most current wage determination is in effect. Should the wage rate change after closing, but prior to award, the updated Wage Determination will be incorporated by amendment and issued to all offerors that have not been eliminated from the competition. If applicable, these offerors/contractors will be given a reasonable opportunity to provide revised proposals solely to amend proposals due to Wage Determination changes.

If the wage determination modification does not change any affected wage rates, then the provisions of FAR 22.404- 5(c)(4) will apply.

6.2. Applicable wage rates can be found at https://beta.sam.gov/.

7. PROPOSAL EXPENSES AND PRE-CONTRACT COSTS

This RFP does not commit the Government to pay costs incurred in preparation and submission of initial and subsequent proposals or for other costs incurred prior to award of a formal contract.

8. REMOVAL OF SECTIONS AT TIME OF AWARD

Sections 00100, 00110, 00120, 00600 and all exhibits will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

9. DISPOSITION OF UNSUCCESSFUL PROPOSALS

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful proposals. The

Government will destroy extra copies of unsuccessful proposals. No destruction certificate will be provided.

10. INFORMATION REGARDING AVAILABILITY OF UTILITY SERVICES

It has been determined that all temporary utilities shall be the responsibility of the contractor. The contractor will pay all charges (hook-up fees, metering, monthly usage, etc.) resulting from temporary utilities. The offerors shall take this into consideration when computing their offers. (FAR Clause 52.236-14, Availability and Use of Utility Services.)

11. BID BONDS

An Original Bid bond is required with submission of the proposal. The bid bond is due on the date as stated on the SF1442 block 13. The bid bond must be on a SF24 form. Rejection of a bid bond shall be in accordance with FAR 28.101-4 Noncompliance with bid guarantee requirements.

12. EXCEPTIONS

If the offeror takes exception to any of the requirements specified in this solicitation, the offeror shall clearly identify each such exception and include a complete explanation of why the exception was taken and what benefit accrues to the Government. All exceptions to the solicitation requirements (Sections 00010 through 00800) and supporting rationale shall be included in an addendum to the proposal and clearly labeled "Exceptions". An addendum is only required if the offeror takes exception to any requirement in the solicitation. (The Addendum does not have a page limitation, but shall only include information relevant to exceptions taken to the solicitation requirements.) The Government will assume an offeror takes no exceptions to any solicitation requirement if the offeror does not submit an Addendum identifying exceptions. Offerors are advised that solicitation requirements are not necessarily negotiable and such exceptions may render an offeror's proposal unacceptable and ineligible for award.

13. CLAUSES

12.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

12.2. Clauses and provisions in this document may not appear in consecutive order.

14. BRAND NAME REQUIREMENTS

None

End of Section 00100

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.204-24 Representation Regarding Certain Telecommunications and

Video Surveillance Services or Equipment.

DEC 2019

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.215-16 Facilities Capital Cost of Money JUN 2003

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a FIRM FIXED PRICE contract resulting from this solicitation.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

61.9% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is 292nd Combat Communications Squadron, State of Hawaii, Counties: Hawaii Statewide, Kahului 96732-2330.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR

52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Office of Chief Counsel ATTN: NGB Protest Decision Authority 111 South George Mason Drive Bldg 2 Arlington, VA 22204-1373 FAX (703) 607-3684 or -3682

OR

Protests to the Contracting Officer shall be filed at:

United States Property and Fiscal Officer for Hawaii ATTN: Manuel LLanes 91-1179 Enterprise Ave Kapolei HI 96707-2150

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 10-Aug-2020, 11:30am

(c) Participants will meet at 292nd Combat Communications Squadron, 75 Kuleana St, Kahului, HI 96732.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/content/regulations

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

NONE

252.211-7002 AVAILABILITY FOR EXAMINATION OF SPECIFICATIONS, STANDARDS, PLANS,

DRAWINGS, DATA ITEM DESCRIPTIONS, AND OTHER PERTINENT DOCUMENTS (DEC. 1991)

The specifications, standards, plans, drawings, data item descriptions, and other pertinent documents cited in this solicitation are not available for distribution but may be examined at the following location:

https://beta.sam.gov/

SECTION 00110

Section 00110

1. PROPOSAL PREPARATION INSTRUCTIONS

1.1. These instructions prescribe the format of proposals, and describe the approach for the development and presentation of the proposal data. They are designed to ensure the submission of necessary information to provide for the understanding and comprehensive evaluation of proposals. Carefully review this section prior to commencing proposal preparation. All solicitation amendments must be acknowledged in accordance with Section 00100, FAR Provision 52.215-1, Instruction to Offerors – Competitive Acquisition.

1.2. Offerors are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete proposal. Failure to furnish a complete proposal, at the time of proposal submission, may result in the proposal being unacceptable to the Government and eliminated from consideration for award.

2. PROPOSAL CONTENT

2.1. Prospective offerors shall submit the following volumes in two separate packages:

2.1.1. Submit Volume 1, Price proposal, pro forma documents, in original and (3) three hard copies, in accordance with instructions contained herein.

Volume 2, Part 1 – Technical Capability Proposal, in original, (3) hard copies and one CD.

Subfactor 1 – Experience and Capability (limited to 10 single pages, excluding table of contents, tabs, indexes and resumes; limit resumes to 2 pages each) Subfactor 2- Construction Schedule and Commissioning Approach/timeline (schedule no page limit;

narrative – no more than 5 pages) Subfactor 3 – Quality Control (limited to 5 single pages, excluding tabs and idexes)

Volume 2, Part 2 – Past/Present Performance Information

Exhibit A - Performance Relevancy Questionnaire should provide questionnaire responses to the Contracting Officer not later than the closing date.

2.3. After compiling all required information, submit original and specified number of copies to the following office: USPFO Hawaii, 91-1179 Enterprise Ave., Kapolei, HI 96707-2150 ATTN MANUEL LLANES. Mark the front of the envelope/box with the following: “PROPOSAL No. W50SLF-20-R-0001, DO NOT OPEN--- Competitive Acquisition”.

2.4. PROPOSAL FORMAT

2.4.1. Purpose: These instructions prescribe the format of proposals, and describe the approach for the development and presentation of the proposed data. The proposal shall include all of the information requested in the specific instructions. Failure to include all information requested may adversely affect the evaluation.

2.4.2. A proposal that merely reiterates or promises to accomplish the requirements of the RFP will be considered unacceptable. A proposal that is orderly and sufficiently documented will be easy for the Government to understand and will enable the Government to perform a thorough and fair evaluation.

2.4.3. Offerors are cautioned to submit enough information to enable the evaluation committee to fully ascertain each offeror’s capability to perform all of the requirements contemplated by this solicitation. All commitments made in the proposal may become a part of the resultant contract. The data submitted with each proposal should be complete and concise, but not overly elaborate. Excessive reliance on promotional brochures is discouraged.

2.4.4. Written proposals shall be prepared on standard 8.5 x 11 inch paper (charts may be landscaped but must be on 8.5 x 11 inch paper) and shall be in a legible font size (10 min.). All pages of each proposal shall be appropriately numbered, and identified with the RFP number. For ease of reference, consecutive page numbering with tabs is required. Type size for graphics, charts, diagrams and tables shall be of an appropriate font and size for the application, and must be clearly readable without magnification assistance to the normal eye. Text lines will be no less than single-space. To the maximum extent practicable, proposal submission shall be double sided. Where page limits exist a page is defined as one single side of a page. Double sided pages count as 2 pages. Unless otherwise stated, tabs, indexes and dividers do not count in the page count.

2.4.5. Binding: Elaborate format and binding are neither necessary nor desirable. All binders will be capable of lying flat when opened. Three ring binders are preferred. The cover and spine of each binder will clearly identify the offeror’s name, Project number, RFP number, RFP title and copy number, (e.g. copy 2 of 3). The original for each volume will be clearly identified on the cover and the spine. All binders will allow for easy removal and replacement of pages.

2.4.6. Indexing: Each binder will contain a “Table of Contents” for that volume. The “Table of Contents” will identify major areas, paragraphs and subparagraphs by number and title, as well as by page number and volume locations. Tab indexing will be used to identify Sections as appropriate.

2.4.7. Electronic Copy: Provide one (1) electronic copy of all of the Volume 2 proposal information. Electronic copies shall be submitted on CD/DVD saved in Microsoft Word format or Adobe Acrobat. (“Read Only” files are acceptable).

2.4.10. The offeror shall be held responsible for the validity of all information supplied in his/her proposal, including that provided by potential subcontractors. Should subsequent investigation disclose that the facts and conditions were not as stated, the proposal may be rejected.

2.5. PROPOSAL VOLUME CONTENTS: Each offeror’s proposal shall be submitted as set forth below and all information shall be confined to the appropriate part to facilitate independent evaluation. Proposals, which do not include the requested minimum information, may be eliminated from further consideration for award.

2.5.1. VOLUME 1, PRICE/COST INFORMATION AND PRO FORMA DOCUMENTS

2.5.1.1. Offerors shall provide all price/cost information necessary to provide a meaningful basis for Government's analysis and evaluation of price/cost for the project set forth in Section 00120 of this solicitation. The Government is not, and does not intend on, requesting certified cost or pricing data.

2.5.1.2. Provide an introductory page to include Cage Code, DUNS Number, Tax Identification Number (TIN), points of contact, authorized negotiators, contact phone, and email addresses. Also, include your business socioeconomic status, e.g. small business, woman-owned small business, HUBZone small business, etc.

2.5.1.3. Offer and Section 00010 – Complete in its entirety the “Offeror” portion of the Standard Form (SF) 1442.

An official having the authority to contractually bind your company must sign the SF 1442 in accordance with FAR

4.102. One copy of the SF 1442 is required to have an original signature.

2.5.1.4. Section 00010 – Insert the price/cost associated with the project in the line items. All line items (CLINs) must be priced to be considered.

2.5.1.5. Representations and Certifications- Section 00600- insert the required certifications and representations and return only those shown in section 00600. Return the entire Section 00600 with your proposal. All other required representations and certifications are to be completed on line in the System for Award Management (SAM) www.sam.gov.

2.5.1.6. All potential offerors are required to register in the System for Award Management. See FAR Provision 52.204-7 System for Award Management.

2.5.1.8. Joint Venture Requirements - Parties wishing to propose as a joint venture must submit, with the Pro Forma documents, an executed copy of the joint venture agreement. The joint venture agreement shall be executed in accordance with FAR 4.102(d). Each joint venture partner shall submit evidence satisfactory to the Contracting Officer that its Board of Directors has approved its participation in the joint venture or by an instrument of similarly binding character in the case of an unincorporated entity. Offerors are reminded that to obtain an award the awardee, to include a joint venture, must be registered in the System for Award Management (SAM) database. Applicable to set-aside solicitations: Joint Ventures must meet applicable size standards (See FAR Subpart 19.1). Submit with the proposal any size determination for the Joint Venture entity received from the Small Business Administration. A Joint Venture where-in one party is not a small business may be referred to the Small Business Administration ( IAW FAR 19.302 (b)) to determine eligibility. All questions regarding Joint Ventures must be directed to the Small Business Administration (SBA) and not the Contracting Officer.

2.5.2. VOLUME 2, PART 1, OFFEROR TECHNICAL CAPABILITY PROPOSAL

2.5.2.1. Volume 2 Part 1 is comprised of three (3) subfactors. Subfactor 1 Experience and Capability; Subfactor 2 Construction Schedule; Subfactor 3 Quality Control

2.5.2.1.1. Government acknowledges that the technical proposal will involve discussion of some of the same projects/contracts discussed in the Past Performance volume. While Past Performance examines how an offeror performed in the past, so as to determine the probability of success on future projects, this subfactor examines the offeror’s experience with complex multidiscipline project management and execution and how the offeror demonstrates an understanding of the contract’s requirements taking this experience into consideration. The Government intends to use Exhibit A Part 1 information in the evaluation of experience for Subfactor 1. A reiteration of the information provided in Exhibit A is neither required nor desired. Offeror should reference this information by providing a short summation of their relevant experience to meet the submission requirements of this subfactor.

2.5.2.2. Subfactor 1 Experience and Capability. The Experience and Capability Proposal is limited to 10 single pages, excluding table of contents, tabs, indexes and resumes as noted below. Pages in excess of the limit will not be evaluated.

2.5.2.2.1 Demonstrate offerors technical experience and capability to perform a project of this magnitude and complexity. Discuss and provide experience of key construction personnel including, but not limited to, Project Manager, Site Superintendent(s), Quality Control Manager (on site) and Safety Manager. Refer to Section 01000, paragraph 36 of RFP, for the minimum qualification requirements for key personnel. Discuss any previous projects that are similar to this project in terms of scope, size and complexity. Specifically discuss repairing existing HVAC systems, construction that required tie in to existing facilities while maintain operations in the existing facility, and construction performed on an island environment or other remote geographic location which poses significant logistical challenges and concerns for material delivery and limited subcontractor availability. If no experience so state and indicate in detail how you plan to overcome this lack of experience. The onus is solely on the offeror to indicate in detail how the offeror plans to overcome this lack of experience. (Resumes or experience cut sheets are limited to 2 pages each and are not part of the page count.) In the event the intended person is not part of the offeror’s organization at the time the proposal is submitted then a completed Exhibit B, “Subcontractor/Team/Key Personnel Information and Consent Form” is also required or the information will not be considered. The Exhibit D Consent form or Letter of Intent is required for the Subcontractor to be considered.

2.5.2.3. Subfactor 2: Construction Schedule and commissioning approach/timeline is obtained for the purposes of evaluating an offerors understanding of the requirements of the schedule and commissioning. The Schedule itself is not subject to page limits; however any narrative accompanying the schedule submission is limited to 5 pages, excluding tabs and indexes.

2.5.2.3.1. Provide Construction Schedule in a Gantt chart that shows the complete project schedule from Notice to Proceed date of 15 October 2020 (estimated) to include all construction activities as well as concurrent activities, and outline the critical path activities that will show successful execution of the construction project within the period of performance requirements per FAR 52.211-10. Also, include a narrative discussing the scheduling processes and resource allocation that ensure completion and control of schedule progress from beginning to the end of the project.

2.5.2.4 Subfactor 3: Quality Control. The Quality Control proposal narrative is limited to 5 single pages, excluding tabs and indexes. The proposal narrative demonstrates that the quality control staff, with lines of authority, is adequate to meet the contract’s requirements. The proposed Quality Control answers should provide a detailed explanation of how quality issues are dealt with on various types of construction projects and as a minimum, meetings, inspections, submittal reviews, correction of non-compliant work and how you intend to ensure non-reoccurrence and reporting of quality problems to Government officials. (Note: A Quality Control Plan is not required with this proposal).

2.5.3. VOLUME 2, PART 2 OFFEROR PAST/PRESENT PERFORMANCE INFORMATION

2.5.3.1. Volume 2 Part 2 is obtained for the purpose of evaluating Past/Present…