W912P520R0004-0002.pdf

CONTRACTING BRANCH (EJC)

EUGENIA.J.CORDER@USACE.ARMY.MIL

110 NINTH AVE SOUTH, ROOM A405

NASHVILLE TN 37203-3817

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0002:

Solicitation W912P520R0004 for the Construction of the Dow nstream Monoliths at the Kentucky Lock, Grand Rivers, Kentucky is hereby amended as follow s:

SEE CONTINUATION PAGE

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 10-May-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912P520R0004

X 9B. DATED (SEE ITEM 11)

20-Apr-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

10-May-2021

CODE

US ARMY CORPS OF ENGINEERS-CELRN-RC-N

DIRECTORATE OF CONTRACTING

110 9TH AVENUE SOUTH, RM A680

NASHVILLE TN 37203

W912P5 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W912P5

FACILITY CODECODE

EMAIL:TEL:

W912P520R0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0002

1. The Synopsis has been updated from: “The estimated performance period for this contract is 56 months.” TO “The estimated performance period for this contract is 1,795 days after Notice to Proceed.”

2. In Block 13 of the solicitation, the due date for proposals is hereby extended from 4 June 2021 at 10:00 AM Central Time to 14 June 2021 at 10:00 AM Central Time.

3. In Section 00 10 00 Solicitation, Delivery Information, the delivery date has been updated for CLIN 0001, 1001, 2001, 3001, 4001, 5001, 6001 and 7001 from “11-OCT-2021 to 30-SEP-2026” TO “11- OCT-2021 to 10-SEP-2026”.

4. In Section 00 21 00, Instructions, Section 1.10, the due date for questions is hereby extended from 10

May 2021 at 10:00 AM Central Time to 17 May 2021 at 10:00 AM Central Time.

5. Virtual Pre-Bid Presentation and attendees list are hereby incorporated as part of this solicitation.

6. Site Visit attendee sign-in sheet are hereby incorporated as part of this solicitation.

7. The following documents are hereby incorporated and made a part of this solicitation:

a. Virtual Pre-Bid Presentation: KYL_Lock DSLM_4May2021 PreBid Presentation.pdf

b. Virtual Contractor Attendee List: KYL_Lock DSLM_4May2021_Contractor List.pdf

c. Site Visit Contractor Sign-In Sheet: KYL_Lock DSLM_6May2021_Site Visit Contractor

Sign In Sheets.pdf

8. Update FAR 52.236-4, replace “Lake Superior” with “the Kentucky Lock”.

9. FAR 52.252-3, Alterations in Solicitation is hereby updated.

--- END OF AMENDMENT 0002---

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 04-Jun-2021 10:00 AM to 14-Jun-2021 10:00 AM.

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236 FOB: Destination

W912P5

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 1001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 2001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 3001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 4001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 5001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 6001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

The following Delivery Schedule item for CLIN 7001 has been changed from:

CAGE

POP 11-OCT-2021 TO

30-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

CAGE

POP 11-OCT-2021 TO

10-SEP-2026

N/A WEST KY AREA OFC,KENTUCKY LOCK

CHRISTOPHER MARSHALL

265 KENTUCKY LOCK ROAD

GRAND RIVERS KY 42045-9706

270-362-4236

SECTION 00 21 00 - INSTRUCTIONS

The following have been modified:

INSTRUCTIONS

INSTRUCTIONS, CONDITIONS & NOTICES TO OFFERORS

PART 1 OVERVIEW

1.0 Intent

This solicitation is to select one (1) contractor for the construction of the Downstream Monolith at the Kentucky Lock, Grand Rivers, Kentucky.

1.1 Type of Contract

The Government intends to award one (1) Firm-Fixed Price Construction Contract.

1.2 Availability of Plans (Drawings), Technical Specifications and Additional Documents

All drawings, technical specifications, and additional documents relating to this Request for Proposal (RFP) are available for download at this solicitation posting on the Beta SAM website, beta.SAM.gov. No printed copies of the aforementioned documents will be provided by the Government. Although provided as separate attachments, the following documents are considered an official part of the solicitation.

a) PLANS: UAW Certified Final Plans:

W912P520R0004 TPlans – Folio 1 of 4 - RTA.pdf W912P520R0004 TPlans – Folio 2 of 4 - RTA.pdf W912P520R0004 TPlans – Folio 3 of 4 - RTA.pdf W912P520R0004 TPlans – Folio 4 of 4 - RTA.pdf

b) SPECIFICATIONS: UAW Certified Final Specs:

W912P520R0004 TSpecs – RTA.pdf W912P520R0004 TSpecs – APP A - RTA.pdf

c) PRICE SCHEDULE: W912P520R0004 Price Schedule.xls

d) SITE VISIT DIRECTIONS: Directions to USACE West Kentucky Resident Office.pdf

e) WAGE DETERMINATIONS: WD KY20210061 dated 19 February 2021.pdf

1.3 Project Description

The contractor shall supply all labor, materials, supplies, management and oversight to construct the Downstream Monolith at the Kentucky Lock, Grand Rivers, Kentucky.

1.4 Basis of Award

This is a “Best Value-Tradeoff” solicitation, as it may be in the best interest of the Government to consider award to other than the lowest priced Offeror or other than the highest technically rated Offeror.

1.5 Who May Submit

This procurement is unrestricted to obtain full and open competition. Proposals from firms organized as joint ventures (JV) that have associated specifically for this project must include a copy of the legal joint venture agreement in the proposal submission.

1.6 North American Industry Classification System (NAICS) and Small Business Size Standard

The NAICS code for this project is 237990, entitled “Other Heavy and Civil Engineering Construction”, which has a Small Business Administration (SBA) size standard of $39.5 Million.

1.7 System for Award Management (SAM) Registration

As mandated by law, this agency cannot award a contract to a contractor who is not registered in the SAM database (www.sam.gov). If submitting as a joint venture, ensure that the joint venture business name is registered in like manner in the SAM database (www.sam.gov).

In accordance with FAR 52.204-7 System for Award Management, An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. Any offeror not registered in the System for Award Management (SAM) when submitting a proposal will be considered not incompliance with the solicitation and may not be considered for evaluation or award.

1.8 Pre-Proposal Site Visit

A Pre-Bid Video Conference Presentation and an organized Site Visit has been scheduled during this solicitation period. Offerors should inspect the job site prior to submitting a proposal. Offerors should take such other steps as may be reasonably necessary to ascertain the nature and location of the work and the general and local conditions that can affect the work or the cost thereof. Failure to do so will not relieve Offerors from the responsibility for properly estimating the difficulty or cost of successfully performing the work. The Government assumes no responsibility for any understanding or representations concerning conditions made by any of its officers, agents or employees, unless included in the solicitation, the specifications or related documents.

Due to COVID-19, this project will have a Pre-Bid Site Visit with a video conference presentation that shall be held on May 4, 2021 at 9:00 AM Local Time (CST). This invitation will be sent to the contractor after the Site Visit Registration has been approved.

An organized site visit has been scheduled for—

May 6, 2021 at 9:00 AM Local Time (CST)

The location for the site visit is the USACE West KY Resident Office:

193 Taylor Park Rd., Grand Rivers, KY 42045

Phone: (270) 362-2163

Coordinates: 37.015635, -88.261287

Directions to this site visit can be located on the attached document: Directions to USACE West Kentucky Resident Office.pdf.

POINT-OF-CONTACT: For questions and /or concerns regarding the video conference presentation, please contact Eugenia J. Corder at Eugenia.J.Corder@usace.army.mil.

This will be the only site visit for this project. If you miss the scheduled site visit, no other arrangements will be made due to personnel and time restrictions.

1.9 Requirements to Attend the Site Visit

Additional Information for attendance to the site visit is included under FAR clause 52.236-27 Alt I.

1.10 POC for Communication/Questions: Any communications regarding this procurement must be made in writing to the Nashville Contracting Branch, Attn: Eugenia Corder via email at Eugenia.J.Corder@usace.army.mil.

Inquiries must identify the solicitation number, the requestor’s company name, address, email address, telephone and facsimile numbers to include area code.

Phone calls or requests to arrange meetings at the Nashville District during the solicitation period to discuss project requirements or company’s capabilities are highly discouraged and will not be scheduled.

QUESTIONS: Questions regarding the solicitation must be submitted to Eugenia Corder via email at Eugenia.J.Corder@usace.army.mil no later than 10:00 AM CST on 17 May 2021.

1.11 Where to Submit and Submittal Deadline

The Offeror’s proposal shall be submitted electronically, as described below. The RFP will provide proposal submission instructions and receipt date for proposal submittal. The Offeror’s proposal shall not contain classified data. The use of hyperlinks in proposals is prohibited.

NOTE: The only authorized transmission method for proposals in response to this solicitation is electronically via SAFE online submission. NO OTHER TRANSMISSION METHODS (EMAIL, FACSIMILE, REGULAR MAIL, HAND CARRIED, ETC.) WILL BE ACCEPTED.

The Offeror’s proposal must be received by the Government by the date/time specified in the solicitation. Offerors shall email their proposals using the following link:

https://safe.apps.mil/

Please send proposals using the link above to Contract Specialist Eugenia Corder at Eugenia.J.Corder@usace.army.mil AND to Contracting Officer Stephen Hutchens at Stephen.P.Hutchens@usace.army.mil.

Proposals for this procurement shall be submitted via the above link.

INSTRUCTIONS FOR SUBMITTING ELECTRONIC PROPOSALS:

In an effort to reduce paperwork and cost, all proposals shall be submitted electronically through the SAFE site.

Submission shall be in Adobe PDF format. You are limited to twenty-five (25) maximum files per upload (total size cannot exceed 8GB). If you have a large number of files, recommend that you combine or ZIP your files before uploading to the SAFE site. Offerors may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

REQUEST FOR UPLOAD CODE: Offerors must email Contract Specialist Eugenia Corder at Eugenia.J.Corder@usace.army.mil AND to Contracting Officer Stephen Hutchens at Stephen.P.Hutchens@usace.army.mil no later than five (5) working days prior to the proposal due date to receive a request code which will allow for file uploads via the SAFE site. Offerors that fail to email for request a code five

(5) working days before proposal submission date may not be able to receive a request code in time to upload their submission. THIS MUST BE DONE FOR THIS PROCUREMENT.

FILE DESCRIPTION: Include a “File Description” for each file(s) you upload. The “File Description” will be included in the email notice to each of the recipients you choose to have access your file(s). NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.) Submission shall be in Adobe PDF format.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

Once at the SAFE website select the “Drop-off” icon. This allows users without a CAC or users whose computer is not configured to read a CAC the option to access the SAFE site as a guest. After selecting the “Click Here” link you will be prompted to add your personal information, file information, recipient (Government representative) information and email settings. When completing your file information for transmittal via the SAFE website, you will be required to enter the email address for all recipients. For this solicitation, the recipients are the Contract Specialist, Eugenia Corder, at Eugenia.J.Corder@usace.army.mil, and the Contracting Officer, Stephen Hutchens, at Stephen.P.Hutchens@usace.army.mil. The email address of the Government Employee who initiated the request code will be automatically entered. The Proposer must enter the email address for both the Contracting Officer and Specialist. The Proposer can enter an additional email address if desired. After entering the email address, click the ADD button to add the person(s) email to the “Recipients List” of your response. When your proposal is submitted, a notification will be sent to the recipients you added.

NOTE: Do NOT send the SAFE site packages to group email accounts.

Even if you successfully upload your proposal to the SAFE site, notification will not be sent to the government recipients until you verify your email address. Entering an incorrect email may result in the rejection of your submission for lateness. A Proposer can confirm proper submission by the “Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Offerors will have more success utilizing any particular browser.

RECEIPT OF SUBMISSIONS:

For the purposes of establishing whether a proposal submission is considered timely, the government considers the date and time the submission is completely uploaded into the SAFE website. For proposals larger than the 8GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive proposals. Offerors are responsible for ensuring that proposals are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the proposal to be received in accordance with the instructions provided.

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

Project: Kentucky Lock Downstream Monolith

Amendment 0001

Solicitation W912P520R0004 for the Construction of the Downstream Monoliths at the Kentucky Lock, Grand Rivers, Kentucky is hereby amended as follows:

1. Price Breakout Schedule is hereby deleted and replaced in its entirety with W912P520R0004_Price Schedule_

Amendment 0001.xlsx.

2. W912P520R0004 Solicitation, Section 00 70 00, FAR 52.236-4, Physical Data is hereby amended.

3. The following Specification Sections (W912P520R0004_TSpecs_ Amendment 0001) is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to Specifications Document:

a) Section 01 22 00, Price and Payment Procedures is hereby amended.

“Two (2) inch LDPE Foam Expansion Joint” was removed from the original specification and paragraphs renumbered”.

Specific changes to original document were the removal of paragraphs 1.3.1.20, 1.3.2.4, 1.3.3.4, 1.3.4.4, 1.3.5.4, 1.3.6.4, and 1.3.8.8.

4. The following APPENDIX A (W912P520R0004_TSpecs_App A_Amendment 0001) attachments is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to APPENDIX A Document:

b) Section 01 33 00, Data Dictionary - the Sample Data Dictionary is hereby amended

Removed pages 32 to 131 of the original document, and Replaced with pages 33 to 137.

c) Section 01 33 00, Entity Relationship Diagram is hereby amended, Removed pages 170 to 172, and Replaced with new diagram on page 139.

d) Section 01 33 00, Sample Database Schema is hereby deleted.

Removed pages 132 to 168.

5. The following APPENDIX B, Geotechnical Baseline Report (W912P520R0004_TSpecs_App B_Amendment

0001) is hereby incorporated and made a part of this solicitation as indicated in the Amendment 0001 Summary of Changes to APPENDIX B Document.

6. FAR Clause 52.252-3, Alterations in Solicitation is hereby updated.

1. The Synopsis has been updated from: “The estimated performance period for this contract is 56 months.” TO “The estimated performance period for this contract is 1,795 days after Notice to Proceed.”

2. In Block 13 of the solicitation, the due date for proposals is hereby extended from 4 June 2021 at 10:00 AM Central Time to 14 June 2021 at 10:00 AM Central Time.

3. In Section 00 10 00 Solicitation, Delivery Information, the delivery date has been updated for CLIN 0001, 1001, 2001, 3001, 4001, 5001, 6001 and 7001 from “11-OCT-2021 to 30-SEP-2026” TO “11- OCT-2021 to 10-SEP-2026”.

4. In Section 00 21 00, Instructions, Section 1.10, the due date for questions is hereby extended from 10

May 2021 at 10:00 AM Central Time to 17 May 2021 at 10:00 AM Central Time.

5. Virtual Pre-Bid Presentation and attendees list are hereby incorporated as part of this solicitation.

6. Site Visit attendee sign-in sheet are hereby incorporated as part of this solicitation.

7. The following documents are hereby incorporated and made a part of this solicitation:

a. Virtual Pre-Bid Presentation: KYL_Lock DSLM_4May2021 PreBid Presentation.pdf

b. Virtual Contractor Attendee List: KYL_Lock DSLM_4May2021_Contractor List.pdf

c. Site Visit Contractor Sign-In Sheet: KYL_Lock DSLM_6May2021_Site Visit Contractor

Sign In Sheets.pdf

8. Update FAR 52.236-4, replace “Lake Superior” with “the Kentucky Lock”.

9. FAR 52.252-3, Alterations in Solicitation is hereby updated.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

The table below provides monthly minimum anticipated adverse weather for the project region, scope of work, and anticipated equipment. It is based on National Oceanic and Atmospheric Administration (NOAA) or similar historical data for the region. The anticipated adverse weather is normal for the region and must be anticipated in the project schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS FOR

THE KENTUCKY LOCK BASED ON 7 – 6 – 5 DAY WORK WEEK

7 day 6 day 5 day

January 9 8 6

February 10 9 7

March 12 10 9

April 11 9 8

May 11 9 8

June 10 9 7

July 10 9 7

August 9 8 6

September 8 7 6

October 8 7 6

November 9 8 6

December 10 9 7

At a minimum, the contractor's schedule must incorporate these anticipated adverse weather delays in all on-site, weather-dependent activities. For off-site work, or if the contractor's equipment or methods dictate, the schedule should incorporate anticipated adverse weather for the historically prevalent weather conditions in that region given the equipment being used and work being performed. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Any claim for delay due to unusually severe weather must be submitted in accordance with FAR Clause 52.249-10 Default (Fixed-Price Construction). Include sufficient documentation to facilitate review by the Contracting Officer.

(End of clause)

(End of Summary of Changes)