W912P520R0004-0001.pdf

CONTRACTING BRANCH (EJC)

EUGENIA.J.CORDER@USACE.ARMY.MIL

110 NINTH AVE SOUTH, ROOM A405

NASHVILLE TN 37203-3817

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0001

Solicitation W912P520R0004 for the Construction of the Dow nstream Monoliths at the Kentucky Lock, Grand Rivers, Kentucky is hereby amended as follow s:

SEE CONTINUATION PAGE

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 29-Apr-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912P520R0004

X 9B. DATED (SEE ITEM 11)

20-Apr-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

29-Apr-2021

CODE

US ARMY CORPS OF ENGINEERS-CELRN-RC-N

DIRECTORATE OF CONTRACTING

110 9TH AVENUE SOUTH, RM A680

NASHVILLE TN 37203

W912P5 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W912P5

FACILITY CODECODE

EMAIL:TEL:

W912P520R0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0001

AMENDMENT 0001

1. Price Breakout Schedule is hereby deleted and replaced in its entirety with W912P520R0004_Price Schedule_

Amendment 0001.xlsx.

2. W912P520R0004 Solicitation, Section 00 70 00, FAR 52.236-4, Physical Data is hereby amended.

3. The following Specification Sections (W912P520R0004_TSpecs_ Amendment 0001) is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to Specifications Document:

a) Section 01 22 00, Price and Payment Procedures is hereby amended.

“Two (2) inch LDPE Foam Expansion Joint” was removed from the original specification and paragraphs renumbered”.

Specific changes to original document were the removal of paragraphs 1.3.1.20, 1.3.2.4, 1.3.3.4, 1.3.4.4, 1.3.5.4, 1.3.6.4, and 1.3.8.8.

4. The following APPENDIX A (W912P520R0004_TSpecs_App A_Amendment 0001) attachments is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to APPENDIX A Document:

b) Section 01 33 00, Data Dictionary - the Sample Data Dictionary is hereby amended

Removed pages 32 to 131 of the original document, and Replaced with pages 33 to 137.

c) Section 01 33 00, Entity Relationship Diagram is hereby amended, Removed pages 170 to 172, and Replaced with new diagram on page 139.

d) Section 01 33 00, Sample Database Schema is hereby deleted.

Removed pages 132 to 168.

5. The following APPENDIX B, Geotechnical Baseline Report (W912P520R0004_TSpecs_App B_Amendment

0001) is hereby incorporated and made a part of this solicitation as indicated in the Amendment 0001 Summary of Changes to APPENDIX B Document.

6. FAR Clause 52.252-3, Alterations in Solicitation is hereby updated.

--- END OF AMENDMENT 0001---

SECTION 00 21 00 - INSTRUCTIONS

The following have been modified:

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

Project: Kentucky Lock Downstream Monolith

Amendment 0001

Solicitation W912P520R0004 for the Construction of the Downstream Monoliths at the Kentucky Lock, Grand Rivers, Kentucky is hereby amended as follows:

1. Price Breakout Schedule is hereby deleted and replaced in its entirety with W912P520R0004_Price Schedule_

Amendment 0001.xlsx.

2. W912P520R0004 Solicitation, Section 00 70 00, FAR 52.236-4, Physical Data is hereby amended.

3. The following Specification Sections (W912P520R0004_TSpecs_ Amendment 0001) is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to Specifications Document:

a) Section 01 22 00, Price and Payment Procedures is hereby amended.

“Two (2) inch LDPE Foam Expansion Joint” was removed from the original specification and paragraphs renumbered”.

Specific changes to original document were the removal of paragraphs 1.3.1.20, 1.3.2.4, 1.3.3.4, 1.3.4.4, 1.3.5.4, 1.3.6.4, and 1.3.8.8.

4. The following APPENDIX A (W912P520R0004_TSpecs_App A_Amendment 0001) attachments is hereby amended as follows and as indicated in the Amendment 0001 Summary of Changes to APPENDIX A Document:

e) Section 01 33 00, Data Dictionary - the Sample Data Dictionary is hereby amended

Removed pages 32 to 131 of the original document, and Replaced with pages 33 to 137.

f) Section 01 33 00, Entity Relationship Diagram is hereby amended, Removed pages 170 to 172, and Replaced with new diagram on page 139.

g) Section 01 33 00, Sample Database Schema is hereby deleted.

Removed pages 132 to 168.

5. The following APPENDIX B, Geotechnical Baseline Report (W912P520R0004_TSpecs_App B_Amendment

0001) is hereby incorporated and made a part of this solicitation as indicated in the Amendment 0001 Summary of Changes to APPENDIX B Document.

6. FAR Clause 52.252-3, Alterations in Solicitation is hereby updated.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

The table below provides monthly minimum anticipated adverse weather for the project region, scope of work, and anticipated equipment. It is based on National Oceanic and Atmospheric Administration (NOAA) or similar historical data for the region. The anticipated adverse weather is normal for the region and must be anticipated in the project schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS FOR LAKE SUPERIOR BASED ON 7 – 6 – 5 DAY WORK WEEK

7 day 6 day 5 day

January 9 8 6

February 10 9 7

March 12 10 9

April 11 9 8

May 11 9 8

June 10 9 7

July 10 9 7

August 9 8 6

September 8 7 6

October 8 7 6

November 9 8 6

December 10 9 7

At a minimum, the contractor's schedule must incorporate these anticipated adverse weather delays in all on-site, weather-dependent activities. For off-site work, or if the contractor's equipment or methods dictate, the schedule should incorporate anticipated adverse weather for the historically prevalent weather conditions in that region given the equipment being used and work being performed. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Any claim for delay due to unusually severe weather must be submitted in accordance with FAR Clause 52.249-10 Default (Fixed-Price Construction). Include sufficient documentation to facilitate review by the Contracting Officer.

(End of clause)

(End of Summary of Changes)