Attachment 3 Supplemental Contract Requirements.pdf
PDF 50 KB Posted
- Attached to
- North Apron Repairs Federal contract opportunity
- Solicitation number
- W9123822R0003
About this file
This document outlines requirements for a federal construction contract opportunity. The contractor will perform repairs to the North Apron at Hill Air Force Base in Davis County, Utah, including replacement of existing Portland cement concrete slabs and structural base work, as well as providing grounding points, pavement markings, and replacement of an adjacent drainage swale and asphalt pavement. Demolition is required to remove existing apron slabs, drainage swale, and a five foot strip of adjacent asphalt. The performance period is 365 calendar days, with liquidated damages of $2,974.34 per day of delay. Only the contracting officer may modify the contract terms. Wage determinations from the Service Contract Act apply. The document includes anticipated weather delay work days by month.
View the file
Other files for this federal contract opportunity
Show all 27
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 3
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 365 calendar days.
2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-
Construction. Liquidated damages for this work are $2,974.34 for each day of delay.
3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the
Contracting Officer.”
Wage Determination: General Decision No: UT20220091 01/07/2022, or its most current modification atthe time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at:
SAM.gov
6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249-10, Default (Fixed- Priced
Construction). All weather delay will need to be submitted and approved by the Contracting Officer
Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://sam.gov/wage-determination/UT20210083/5
File details come from the government source that posted it. Updated .