Atch_2_Supplemental_Contract_Requirements.pdf
PDF 61 KB Posted
- Attached to
- Temporary Lodging Facility
- Solicitation number
- W-091238-15-R-0063
About this file
Attachment 2 - Supplemental Contract Requirements
View the file
Other files
Show all 42
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 2 1 of 1
W91238-15-R-0063 3 December 2014
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period. The performance period for the work stated above shall be 540 calendar days.
2. Liquidated Damages. Liquidated Damages-Construction. Liquidated damages for this work is $2,454 for each day of delay.
3. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.
4. Wage Determination. General Decision No. CA140009 11/07/2014 CA9 , Yuba County, in its most current modification at the time of award is hereby applicable to work performed under this task order. Contractor shall make sure that there is no other general decision superceding the above at time of bid. Please visit www.wdol.gov for additional detail.
5. Time Extensions For Unusually Severe Weather. Refer the original solicitation, Default
(Fixed-Priced Construction). All weather delay will need to be submitted and approved by the
Contracting Officer Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK - Beale AFB, CA
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(07) (06) (05) (04) (01) (00) (00) (00) (01) (02) (05) (07) http://www.wdol.gov/
File details come from the government source that posted it. Updated .