SIR 6973GH-25-R-00206 signed 092425.pdf

SEE ADDENDUMIS CHECKED.

CODE 17a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE 16a. CONTRACTOR/

TELEPHONE NO.

16b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

AAQ720-AFN

BLDG 014-AHQ, ROOM 233A

PO BOX 25082

FAA AERONAUTICAL CENTER

AAQ-720 DIVERSIFIED FRANCHISE ACQ

W693190M

WASHINGTON DC 205910001

800 INDEPENDENCE AVE SW

MAILROOM FL 1

693190 DOT FAA

W693190M

CODE 15. ADMINISTERED BYCODE 14. DELIVER TO

X

X

X

SEE SCHEDULE

BLOCK IS MARKED

221114

SIZE STANDARD:

% FORSET ASIDE

UNRESTRICTED

AAQ720-AFN

OKLAHOMA CITY OK 73125

BLDG 014-AHQ, ROOM 233A

PO BOX 25082

FAA AERONAUTICAL CENTER

AAQ-720 DIVERSIFIED FRANCHISE ACQ

RFPIFB

11. DELIVERY FOR FOB10. THIS ACQUISITION ISCODE 9. ISSUED BY

RFQ

13. METHOD OF SOLICITATION

DESTINATION UNLESS

SIC:

SMALL BUSINESS

12. DISCOUNT TERMS

1400 ES405-954-8204Sheryl Gregory (No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBER a. NAME

4. ORDER NUMBER3. AWARD/ 2. CONTRACT NO.

7.

6. SOLICITATION

6973GH-25-R-00206

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 2WA-25-07202

OFFEROR TO COMPLETE BLOCKS 12, 16, 22, 23, & 28

OKLAHOMA CITY OK 73125

EFFECTIVE DATE

17b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 17a. UNLESS BLOCK BELOW

ISSUE DATE

23.

AMOUNT

22.

UNIT PRICE

21.

UNIT

20.

QUANTITY

19.

SCHEDULE OF SUPPLIES/SERVICES

18.

ITEM NO.

Procurement of two (2) Portable DER units

Continued ...

27. AWARD OF CONTRACT: REFERENCE

HEREIN, IS ACCEPTED AS TO ITEMS:

X

DATED

Stefanie Wiles

. YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

40d. TOTAL CONTAINERS40c. DATE REC'D (YY/MM/DD)

40b. RECEIVED AT (Location)

40a. RECEIVED BY (Print)

26. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

38. PAID BY37. S/R VOUCHER NUMBER36. S/R ACCOUNT NUMBER

35. CHECK NUMBER

FINALCOMPLETE PARTIAL

34. PAYMENT

39c. DATE39b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

39a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

32c. DATE32b. SIGNATURE OF AUTHORIZED CONTRACT AUTHORITY

REPRESENTATIVE

FINALPARTIAL

CORRECT FOR

33. AMOUNT VERIFIED 32. VOUCHER NUMBER

CONTRACT, EXCEPT AS NOTED

ACCEPTED, AND CONFORMS TO THEINSPECTEDRECEIVED

30a. QUANTITY IN COLUMN 20 HAS BEEN

29c. DATE SIGNED

28a. SIGNATURE OF OFFEROR/CONTRACTOR 29a. CONTRACT AUTHORITY (SIGNATURE OF CONTRACTING OFFICER)

28c. DATE SIGNED28b. NAME AND TITLE OF SIGNER (Type or Print) 29b. NAME OF CONTRACTING OFFICER (Type or Print)

31. SHIP NUMBER

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET FORTH

OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND

CONDITIONS SPECIFIED HEREIN.

25. TOTAL AWARD AMOUNT (For Contract Authority Use Only)24. ACCOUNTING AND APPROPRIATION DATA

OFFER

ITEM NO.

SUPPLIES/SERVICES

QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-25-R-00206

(A) (B) (C) (D) (E) (F)

JCN: 25016200

00001 The Contractor must furnish all resources, labor, materials, equipment, and services necessary to deliver and commission two (2) fully operational portable PV+BESS unit solution described in the

SOW.

The unit price must include the following items:

-System Design Documentation

-Technical Specifications

-Instruction Manuals

-Operation and Maintenance (O&M) manuals

-Warranty certificates

-Product Certificates

Technical Support Contact Details and response time

-System product part list

-Stowing and Shipping Instructions

Electronic & IT: 03

00002 Vendor training at Mike Monroney Aeronautical

Center (MMAC)

Training materials and session for FAA staff

Maximum of ten (10) FAA attendees

00003 On-Site Training and Technical Assistance of new equipment at Georgetown Bahamas

Electronic & IT: 03

Section A - Solicitation/Contract Form

Section B - Supplies or Services/Prices Section B - Schedule

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

The contractor must furnish all labor and materials to manufacture two (2) Portable PV BESS units as well as all other terms and conditions set forth herein:

o See SOW for Two Portable Distributed Energy Resource (DER) Units JCN 25016200; 8/17/2025; 6 pages

Clause List

AC4548 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

(JUL 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel not being subject to the direction and control of Government personnel when performing non-personal contract services in FAA facilities.

(b) All contractor personnel at a FAA work site or facility during an actual emergency shall conform to the procedures posted or directed by FAA officials responsible for emergency response at that site or facility. Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, etc.

(c) Contractor personnel shall participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions and based on advance arrangements that are then announced at the time of an exercise, contractor personnel will be excused from evacuations.

(d) Contractor management/supervisors shall ensure that each contractor employee assigned work in FAA facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Information on emergency procedures may be requested from the Contracting Officer’s Representative (COR) or a designated FAA contact point at the work site.

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.10.4-2 INSPECTION OF SUPPLIES - FIXED PRICE (NOV 1997)

3.10.4-16 RESPONSIBILITY FOR SUPPLIES (APR 1996)

AC1908 INSPECTION AND ACCEPTANCE AT DESTINATION (JUN 2015)

(a) Final inspection and acceptance shall be at destination.

(b) Although source inspection by the Government is not anticipated under this contract, the provisions of this clause shall in no way be construed to limit the rights of the Government under the clause entitled 3.10.4-2

INSPECTION OF SUPPLIES - FIXED PRICE

Section F - Deliveries or Performance Clause List

SCHEDULES AND MILESTONES

Table 1

3.10.1-9 STOP-WORK ORDER (APR 2025)

3.11-34 F.O.B. DESTINATION (APR 1999)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

F.1 F.O.B DESTINATION

ATTN: Joseph Vincent, AJW-22 Address: 6201 SW 61st St Bldg. 260 Oklahoma City, OK 73169-6958 Cell: (405) 549-6520

The remainder of this page has been intentionally left blank.

Schedule Due Date Production Schedule No later than 15 business days after award.

Post award submittals No later the 30 business days after award.

Manufacturer progress report Weekly from award to delivery (via email).

Manufacturer facility tour (Demonstration)

No more than 45 business days from award.

Unit delivery (MMAC, OKC) Final Deliverables Provided during unit delivery.

Vendor training (MMAC, OKC) No more than 10 business days after delivery.

Initial unit deployment support (Georgetown, Bahamas)

Within 6 months from unit delivery to OKC.

Section G - Contract Administration Data Clause List

AC4530 WARRANTY - COMMERCIAL PRODUCTS (JUN 2015)

(a) The contractor warrants that the products (‘products’ includes equipment, fabrication processes, raw or finished materials, and intermediate assemblies) conform to contract requirements. The contractor also warrants that products are free of design defects (except defects in FAA-provided final designs) and defects in materials or workmanship.

(b) The contractor shall replace or repair any products which fail in operation within 12 months from the date of receipt. The Contracting Officer will give written notice of any defect or nonconformance to the contractor within a reasonable period of time after discovery. Replacements of contract items shall be made promptly and on an FOB destination basis. FAA will install replacements at no expense to the contractor.

(c) Products replaced under the provisions of this warranty shall remain the property of FAA unless the contractor wishes to obtain ownership. In this case, the contractor shall notify FAA of such in writing not later than the date of receipt by FAA of the replacement products. The contractor is responsible for packaging and shipping costs.

(d) The rights and remedies of FAA provided in this clause are in addition to and do not limit any rights afforded to FAA by any other clause of this contract or under applicable Federal or State law, including the Uniform Commercial Code.

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations

Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-1 PAYMENTS (JUL 2018)

3.3.1-6 DISCOUNTS FOR PROMPT PAYMENT (JUL 2018)

3.3.1-8 EXTRAS (OCT 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-17 PROMPT PAYMENT (OCT 2024)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (OCT 2024)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2025)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JUL 2023)

3.6.2-4 WALSH-HEALEY PUBLIC CONTRACTS ACT (APR 2025)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 2025)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2024)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (APR 2025)

3.6.4-8 BUY AMERICAN ACT AND FAA BUY AMERICAN PREFERENCE - USMCA

IMPLEMENTATION ACT - BALANCE OF PAYMENTS PROGRAM (JAN 2024)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-12 CHANGES - FIXED-PRICE (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-28 CHANGES REQUIRED BY AMS (JAN 2024)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT

1996)

3.10.6-4 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (JAN 2020)

3.11-62 PREFERENCE FOR PRIVATELY OWNED U.S. FLAG COMMERCIAL VESSELS (APR

2025)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (OCT 2024)

(a) Definitions.

(1) "The Act," as used in this clause, means section 1352, title 31, United States Code.

(2) "Agency," as used in this clause, means executive agency, within the meaning of 5 U.S.C. 101, 102, and

104(I), and any wholly owned Government corporation within the meaning of 31 U.S.C. 9101.

(3) "Covered Federal action," as used in this clause, means any of the following Federal actions:

(i) The awarding of any Federal contract.

(ii) The making of any Federal grant.

(iii) The making of any Federal loan.

(iv) The entering into of any cooperative agreement.

(v) The extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

(4) "Indian tribe" and "tribal organization," as used in this clause, have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 5304) and include Alaskan Natives.

(5) "Influencing or attempting to influence," as used in this clause, means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

(6) "Local government," as used in this clause, means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

(7) "Officer or employee of an agency," as used in this clause, includes the following individuals who are employed by an agency:

(i) An individual who is appointed to a position in the Government under title 5, United States Code, including a position under a temporary appointment.

(ii) A member of the uniformed services, as defined in subsection 101(3), title 37, United States Code.

(iii) A special Government employee, as defined in section 202, title 18, United States Code.

(iv) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, title 5, United States Code, appendix 2.

(8) "Person," as used in this clause, means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(9) "Reasonable compensation," as used in this clause, means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

(10) "Reasonable payment," as used in this clause, means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

(11) "Recipient," as used in this clause, includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(12) "'Regularly employed," as used in this clause, means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person must be considered to be regularly employed as soon as the officer or employee is employed by such person for 130 working days.

(13) "State," as used in this clause, means a State of the United States, the District of Columbia, the Commonwealth of Puerto Rico, a territory or possession of the United States, an agency or instrumentality of a State, and multi-State, regional, or interstate entity having governmental duties and powers.

(b) Prohibitions. The offeror, by signing its offer, hereby certifies to the best of his or her knowledge and belief that:

(1) No Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement;

(2) If any funds other than Federal appropriated funds (including profit or fee received under a covered Federal action) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the screening information request (SIR), the offeror must complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and

(3) The offeror will include the language of this clause in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 must disclose accordingly.

(4) This certification and disclosure is a prerequisite for making or entering into this contract imposed by the Act. Any person who makes a prohibited expenditure or fails to file or amend a disclosure form, must be subject to a civil penalty of not less than $10,000 and not more than $100,000, for each such failure.

(c) The prohibitions of the Act do not apply under the following conditions:

(1) Agency and legislative liaison by its own employees.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of a payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action if the payment is for agency and legislative liaison activities not directly related to a covered Federal action.

(ii) For purposes of subdivision (c)(1)(i) of this clause, providing any information specifically requested by an agency or Congress is permitted at any time.

(iii) The following agency and legislative liaison activities are permitted at any time where they are not related to a specific solicitation for any covered Federal action:

(A) Discussing with an agency the qualities and characteristics (including individual demonstrations) of the person's products or services, conditions or terms of sale, and service capabilities.

(B) Technical discussions and other activities regarding the application or adaptation of the person's products or services for an agency's use.

(iv) The following agency and legislative liaison activities are permitted where they are prior to the Screening Information Request (SIR) of any covered Federal action:

(A) Providing any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;

(B) Technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and

(C) Capability presentations by persons seeking awards from an agency pursuant to the provisions of a law authorizing such actions;

(2) Professional and technical services.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of:

(A) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.

(B) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.

(ii) For purposes of subdivision (c)(2)(i) of this clause, 'professional and technical services' must be limited to advice and analysis directly applying any professional or technical discipline. For example, drafting of a legal document accompanying a submittal/offer by a lawyer is allowable.

Similarly, technical advice provided by an engineer on the performance or operational capability of a piece of equipment rendered directly in the negotiation of a contract is allowable. However, communications with the intent to influence made by a professional (such as a licensed lawyer) or a technical person (such as a licensed accountant) are not allowable under this section unless they provide advice and analysis directly applying their professional or technical expertise and unless the advice or analysis is rendered directly and solely in the preparation, submission or negotiation of a covered Federal action. Thus, for example, communications with the intent to influence made by a lawyer that do not provide legal advice or analysis directly and solely related to the legal aspects of his or her client's submittal/offer, but generally advocate one proposal over another are not allowable under this section because the lawyer is not providing professional legal services.

Similarly, communications with the intent to influence made by an engineer providing an engineering analysis prior to the preparation or submission of a submittal/offer are not allowable under this section since the engineer is providing technical services but not directly in the preparation, submission or negotiation of a covered Federal action.

(iii) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.

(iv) The reporting requirements herein must not apply with respect to payments of reasonable compensation made to regularly employed officers or employees of a person.

(3) Only those communications and services expressly authorized by paragraphs (c)(1) and (2) of this clause are permitted under this clause.

(d) Disclosure.

(1) If the Contractor, who requests or receives from an agency a Federal contract, has made or has agreed to make any payment using non-appropriated funds (to include profits from any Covered Federal action), to any person for the purpose of influencing or attempting to influence an officer or employee of any Agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with a Covered Federal action, the Contractor must file with that agency a disclosure form, OMB Standard Form LLL, Disclosure of Lobbying Activities..

(2) The Contractor must file a disclosure form at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the information contained in any disclosure form previously filed by such person under subparagraph (d)(1) of this clause. An event that materially affects the accuracy of the information reported includes:

(i) A cumulative increase of $25,000 or more in the amount paid or expected to be paid for influencing or attempting to influence a covered Federal action; or

(ii) A change in the person(s) or individual(s) influencing or attempting to influence a covered Federal action; or

(iii) A change in the officer(s), employee(s), or Member(s) contacted to influence or attempt to influence a covered Federal action.

(3) The Contractor must require the certification, and if required, a disclosure form by any person who requests or receives any subcontractor exceeding $150,000 under the Federal contract.

(4) All subcontractor disclosure forms must be forwarded from tier to tier until received by the prime Contractor. The prime Contractor must submit all disclosures to the Contracting Officer at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor.

(e) Agreement. The Contractor agrees not to make any payment prohibited by this clause.

(f) Penalties.

(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or fails to file or amend the disclosure form to be filed or amended by paragraph (b) must be subject to civil penalties as provided for by 31 U.S.C. 1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.

(2) Contractors may rely without liability on the representations made by their subcontractors in the certification and in the disclosure form.

(g) Cost allowability. Nothing in this clause makes allowable or reasonable any costs which would otherwise be unallowable or unreasonable. Conversely, costs made specifically unallowable by the requirements in this clause will not be made allowable under any other provision.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JAN 2024)

(a) Definitions. As used in this clause

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the Unique Identity Identifier (UEI) or the Electronic Funds Transfer indicator, into the SAM database.

"System for Award Management (SAM) database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

"Unique Entity Identifier (UEI)" (also known as the Unique Entity ID) means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

"Electronic Funds Transfer indicator" means a 4-character suffix to the Unique Entity Identifier. This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the UEI or EFT indicator that identifies the offeror's name and address exactly as stated in the offer. The UEI will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a UEI, it should contact www.sam.gov directly to obtain one.

The offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company Physical Street Address, City, State, and ZIP Code.

(4) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(5) Company Telephone Number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran- Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are certified as an SDVOSB under the Small Business Administration's Veteran Small Business Certification Program (VetCert).

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.3.2-1 FAA COST PRINCIPLES (OCT 2019)

(a) Federal Aviation Administration (FAA) "Contract Cost Principles" must be used for:

(1) The pricing of contracts, subcontracts, and modifications to contracts and subcontracts whenever cost analysis is performed; and

(2) The determination, negotiation, or allowance of costs when required by a contract clause.

(b) The Contracting Officer will incorporate the FAA cost principles and procedures in contracts with commercial organizations as the basis for:

(1) Determining reimbursable costs under

(i) Cost-reimbursement contracts and cost-reimbursement subcontracts under these contracts performed by commercial organizations and

(ii) The cost-reimbursement portion of time-and-materials contracts except when material is priced on a basis other than at cost;

(2) Negotiating indirect cost rates, when:

(i) FAA has division or corporate contract administration responsibilities;

(ii) Quick Close-out procedures are used; or

(iii) Indirect rate caps are negotiated in the contract.

(3) Proposing, negotiating, or determining costs under terminated contracts;

(4) Price revision of fixed-price incentive contracts;

(5) Price redetermination of price redetermination contracts; and

(6) Pricing changes and other contract modifications.

(c) When division or corporate contract administration responsibilities rest with another Government agency, the FAA will apply the cost principles of the administering agency for the determination or negotiation of indirect rates not covered by (2)(ii) or (2)(iii) above.

(d) Upon request, the Contracting Officer will provide a copy of the FAA "Contract Cost Principles."

(End of clause)

3.6.2-14 EMPLOYMENT REPORTS ON VETERANS (APR 2022)

(a) Unless the contractor is a State or local government agency, the contractor must report at least annually, as required by the Secretary of Labor, on:

(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are protected veterans (i.e., active duty wartime or campaign badge veterans, Armed Forces service medal veterans, disabled veterans, and recently separated veterans),

(2) The total number of new employees hired during the period covered by the report, and of the total, the number of protected veterans; and

(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.

(b) The above items must be reported by completing the VETS-4212 "Federal Contractor Veterans' Employment Report" (see "VETS-4212 Federal Contractor Reporting" and "Filing Your VETS-4212 Report" at http://www.dol.gov/vets/vets4212.htm).'

(c) The Contractor must submit VETS-4212 Reports no later than September 30 of each year.

(d) The employment activity report required by paragraphs (a)(2) and (a)(3) of this clause shall reflect total new hires, and maximum and minimum number of employees, during the most recent 12-month period preceding the ending date selected for the report. Contractors may select an ending date:

(1) As of the end of any pay period between July 1 and August 31 of the year the report is due; or

(2) As of December 31, if the Contractor has prior written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).

(e) The count of veterans reported must be based on data known to the contractor when completing the VETS-4212.

The Contractor's knowledge of veterans status may be obtained in a variety of ways, including an invitation to applicants to self-identify (in accordance with 41 CFR 60-300.42), voluntary self-disclosure by employees, or actual knowledge of veteran status by the contractor. This paragraph does not relieve the employer of liability for a determination under 38 U.S.C. 4212.

(f) Subcontracts. The Contractor must include the terms of this clause in every subcontract or purchase order of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor.

(End of clause)

3.6.4-5 FAA BUY AMERICAN PREFERENCE - STEEL AND MANUFACTURED GOODS (APR

2022)

(a) Section 9129 of the Aviation Safety and Capacity Expansion Act of 1990 (Subtitle B of Title IX of Pub. L. 101- 508, the Omnibus Budget Reconciliation Act of 1990) requires the use of steel and manufactured goods produced in the United States when a project such as that covered by this contract receives funding.

(b) The Contractor must deliver only steel and manufactured goods produced in the United States. This requirement will not apply where the FAA Acquisition Executive (FAE) or his or her designee has found--

(1) That its application would be inconsistent with the public interest;

(2) That such materials are not produced in the United States in sufficient and reasonably available quantities or of satisfactory quality. In accordance with AMS Guidance T3.6.4A.2 b(2), if the request is based on the steel and manufactured goods not produced in the U.S. in sufficient and reasonably available quantities or of a satisfactory quality, the use of the proposed foreign construction material must be approved by the FAA Acquisition Executive (FAE) and reviewed by the Office of Management and Budget (OMB) Made in America Office (MIAO);

(3) For facilities and equipment (F&E) funded acquisitions under AMS Guidance T3.6.4A.1.c(2)-(4)-

(i) the cost of components and subcomponents which are produced in the United States is more than 60 percent of the cost of all components to be delivered under this contract with labor costs involved in the final assembly not included in calculating the cost of components, and

(ii) final assembly of the facility or equipment to be delivered under this contract has taken place in the United States; or

(4) That inclusion of domestic material will increase the cost of the overall contract by more than 25 percent.

(c) This clause takes precedence over the provisions of clause "Buy American Act--Supplies" and clause "Buy American Act--Construction Materials" in respect to their applicability to steel and manufactured goods.

(d) The offeror warrants that steel and manufactured goods to be used in the project are produced in the United States, and that components of unknown origin are considered to have been produced or manufactured outside the United States. Should any end product be of foreign origin, the Contractor must identify, in writing, such goods and country of origin to the Contracting Officer prior to contract award. Such information is required in implementation of Section 9129 of the Aviation Safety and Capacity Expansion Act of 1990, (Subtitle B of Title IX of P. L. 101- 508, the Omnibus Budget Reconciliation Act of 1990).

(End of clause)

3.8.9-4 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB ENTITIES (JAN 2024)

(a) Definitions. As used in this clause-

Kaspersky Lab covered article means any hardware, software, or service that-

(1) Is developed or provided by a Kaspersky Lab covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a Kaspersky Lab covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a Kaspersky Lab covered entity.

Kaspersky Lab covered entity means-

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab, including any change in name, e.g. "Kaspersky";

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any Kaspersky Lab covered article. The Contractor is prohibited from-

(1) Providing any Kaspersky Lab covered article that the Government will use; and

(2) Using any Kaspersky Lab covered article in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractor identifies a Kaspersky Lab covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor must report this in writing to the Contracting Officer. For indefinite delivery contracts, the Contractor must report this in writing to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order.

(2) The Contractor must report the following information pursuant to paragraph (c) (1) of this clause:

(i) Within 3 business days from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor must describe the efforts it undertook to prevent use or submission of a Kaspersky Lab covered article, any reasons that led to the use or submission of the Kaspersky Lab covered article, and any additional efforts that will be incorporated to prevent future use or submission of Kaspersky Lab covered articles.

(d) Subcontracts. The Contractor must insert the…