PN70551_100_SPEC.pdf

PN70551 Child Development Center, Schofield Barracks 125679

PROJECT TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 32 00 03/17 PROJECT SCHEDULE

01 33 00 03/17 SUBMITTAL PROCEDURES

01 33 29 02/21 SUSTAINABILITY REQUIREMENTS AND

REPORTING

01 33 39.00 10 12/17 ADVANCED MODELING (BIM/CIM/GIS/CAD)

REQUIREMENTS

01 35 26 11/20 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00 03/17 RMS3 - CONTRACTOR MODE (RMS3/CM)

01 45 04 11/16 CONTRACTOR QUALITY CONTROL

01 45 35 02/20 SPECIAL INSPECTIONS

01 57 19 11/15, CHG 4: 08/20 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 02/19, CHG 1: 08/20 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 78 00 05/19 CLOSEOUT SUBMITTALS

01 78 23 08/15 OPERATION AND MAINTENANCE DATA

01 90 00 01/18 MISCELLANEOUS PROVISIONS

01 91 00.15 10 05/19 TOTAL BUILDING COMMISSIONING

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00 05/10 DEMOLITION

02 61 13 02/10 EXCAVATION AND HANDLING OF

CONTAMINATED MATERIAL

02 81 00 11/18 TRANSPORTATION AND DISPOSAL OF

HAZARDOUS MATERIALS

02 82 00 11/18 ASBESTOS REMEDIATION

02 83 00 11/18 LEAD REMEDIATION

02 84 16 05/20 HANDLING OF LIGHTING BALLASTS AND

LAMPS CONTAINING PCBs AND MERCURY

DI VI SI ON 03 - CONCRETE

03 23 00 05/16, CHG 1: 08/18 STRESSED TENDON REINFORCING

03 30 00 02/19, CHG 1: 02/21 CAST-IN-PLACE CONCRETE

03 42 13.00 10 05/16 PLANT-PRECAST CONCRETE PRODUCTS FOR

BELOW GRADE CONSTRUCTION

DI VI SI ON 04 - MASONRY

04 20 00 11/15, CHG 2: 05/19 UNIT MASONRY

DI VI SI ON 05 - METALS

05 05 23.16 08/18 STRUCTURAL WELDING

05 12 00 08/18, CHG 1: 11/18 STRUCTURAL STEEL

05 30 00 05/15, CHG 2: 08/18 STEEL DECKS

05 40 00 05/15, CHG 1: 08/18 COLD-FORMED METAL FRAMING

05 50 13 05/17, CHG 1: 08/18 MISCELLANEOUS METAL FABRICATIONS

05 51 33 02/16, CHG 2: 02/18 METAL LADDERS

05 52 00 02/18, CHG 1: 02/20 METAL RAILINGS

DI VI SI ON 06 - WOOD, PLASTI CS, AND COMPOSI TES

06 41 16.00 10 08/10, CHG 1: 11/18 PLASTIC-LAMINATE-CLAD ARCHITECTURAL

CABINETS

PROJECT TABLE OF CONTENTS Page 1

06 61 16 08/20 SOLID SURFACING FABRICATIONS

DI VI SI ON 07 - THERMAL AND MOI STURE PROTECTI ON

07 05 23 08/19 PRESSURE TESTING AN AIR BARRIER SYSTEM

FOR AIR TIGHTNESS

07 21 16 11/11, CHG 4: 08/18 MINERAL FIBER BLANKET INSULATION

07 24 00 05/11, CHG 4: 08/18 DIRECT APPLIED EXTERIOR FINISH SYSTEMS

07 27 10.00 10 08/19, CHG 1: 02/20 BUILDING AIR BARRIER SYSTEM

07 27 19.01 05/17, CHG 2: 08/20 SELF-ADHERING AIR BARRIERS

07 27 36 05/17, CHG 2: 08/20 SPRAY FOAM AIR BARRIERS

07 54 19 02/13 THERMOPLASTIC POLYOLEFIN (TPO) ROOFING

07 60 00 05/17, CHG 2: 11/18 FLASHING AND SHEET METAL

07 61 15.00 20 08/16, CHG 2: 11/18 ALUMINUM STANDING SEAM ROOFING

07 84 00 05/10, CHG 1: 08/13 FIRESTOPPING

07 92 00 08/16, CHG 3: 11/18 JOINT SEALANTS

DI VI SI ON 08 - OPENI NGS

08 11 13 08/20 STEEL DOORS AND FRAMES

08 14 00 08/16, CHG 1: 08/18 WOOD DOORS

08 31 00 05/17, CHG 1: 08/18 ACCESS DOORS AND PANELS

08 34 73 11/19, CHG 1: 02/21 SOUND CONTROL DOOR ASSEMBLIES

08 41 13 08/18, CHG 1: 08/18 ALUMINUM-FRAMED ENTRANCES AND

STOREFRONTS

08 51 13 05/19 ALUMINUM WINDOWS

08 71 00 02/16, CHG 3: 08/20 DOOR HARDWARE

08 81 00 05/19 GLAZING

08 91 00 08/20 METAL WALL LOUVERS

DI VI SI ON 09 - FI NI SHES

09 22 00 02/10, CHG 2: 08/18 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 08/16, CHG 4: 02/20 GYPSUM BOARD

09 30 10 08/20 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 08/20 ACOUSTICAL CEILINGS

09 65 00 08/10 RESILIENT FLOORING

09 65 66 08/16, CHG 1: 08/18 RESILIENT ATHLETIC FLOORING

09 68 00 11/17, CHG 2: 08/20 CARPETING

09 90 00 05/11 PAINTS AND COATINGS

09 97 13.13 05/11 INTERIOR COATING OF CONCRETE WATER TANK

DI VI SI ON 10 - SPECI ALTI ES

10 14 00.10 08/17, CHG 1: 11/18 EXTERIOR SIGNAGE

10 14 00.20 08/17 SIGNAGE

10 21 13 08/17 TOILET COMPARTMENTS

10 22 13 08/16, CHG 1: 08/18 WIRE MESH PARTITIONS

10 26 00 08/17 WALL AND DOOR PROTECTION

10 28 13 08/17 TOILET ACCESSORIES

10 44 16 11/19 FIRE EXTINGUISHER CABINETS

10 51 13 05/11 PLASTIC LOCKERS

DI VI SI ON 11 - EQUI PMENT

11 05 40 08/17 COMMON WORK RESULTS FOR FOODSERVICE

EQUIPMENT

11 06 40.13 08/17 FOODSERVICE EQUIPMENT SCHEDULE

11 41 11 08/17 REFRIGERATED AND FROZEN FOOD STORAGE

PROJECT TABLE OF CONTENTS Page 2

EQUIPMENT

11 42 00 08/17 FOOD PREPARATION EQUIPMENT

11 44 00 08/17 FOOD COOKING EQUIPMENT

11 47 00 08/17, CHG 1: 08/18 ICE MACHINES

11 48 00 08/17, CHG 1: 08/18 CLEANING AND DISPOSAL EQUIPMENT

11 68 13 08/17 PLAYGROUND EQUIPMENT

DI VI SI ON 12 - FURNI SHI NGS

12 21 00 08/17, CHG 2: 11/18 WINDOW BLINDS

12 48 13 08/17 ENTRANCE FLOOR MATS AND FRAMES

DI VI SI ON 13 - SPECI AL CONSTRUCTI ON

13 48 73 05/20, CHG 1: 08/20 SEISMIC CONTROL FOR MECHANICAL

EQUIPMENT

DI VI SI ON 21 - FI RE SUPPRESSI ON

21 13 13 08/20 WET PIPE SPRINKLER SYSTEMS, FIRE

PROTECTION

21 30 00 04/08 FIRE PUMPS

DI VI SI ON 22 - PLUMBI NG

22 00 00 11/15 PLUMBING, GENERAL PURPOSE

DI VI SI ON 23 - HEATI NG, VENTI LATI NG, AND AI R CONDI TI ONI NG ( HVAC)

23 05 48.19 05/18 SEISMIC BRACING FOR HVAC

23 05 93 11/15 TESTING, ADJUSTING, AND BALANCING FOR

HVAC

23 07 00 02/13 THERMAL INSULATION FOR MECHANICAL

SYSTEMS

23 09 00 02/19 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 11/15 INSTRUMENTATION AND CONTROL DEVICES

FOR HVAC

23 09 23.02 02/19 BACNET DIRECT DIGITAL CONTROL FOR HVAC

AND OTHER BUILDING CONTROL SYSTEMS

23 23 00 10/07 REFRIGERANT PIPING

23 30 00 05/20 HVAC AIR DISTRIBUTION

23 64 10 11/16 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 64 26 08/09 CHILLED, CHILLED-HOT, AND CONDENSER

WATER PIPING SYSTEMS

23 81 00 05/18 DECENTRALIZED UNITARY HVAC EQUIPMENT

DI VI SI ON 25 - I NTEGRATED AUTOMATI ON

25 05 11.01 05/21 CYBERSECURITY FOR HVAC DDC CONTROLS

25 05 11.02 05/21 CYBERSECURITY FOR MASS NOTIFICATION

SYSTEM

25 10 10 02/19, CHG 1: 05/21 UTILITY MONITORING AND CONTROL SYSTEM

(UMCS) FRONT END AND INTEGRATION

DI VI SI ON 26 - ELECTRI CAL

26 05 19.10 10 05/16 INSULATED WIRE AND CABLE

26 05 48.00 10 10/07 SEISMIC PROTECTION FOR ELECTRICAL

EQUIPMENT

PROJECT TABLE OF CONTENTS Page 3

26 08 00 08/08, CHG 2: 08/21 APPARATUS INSPECTION AND TESTING

26 12 19.10 05/19, CHG 1: 11/19 THREE-PHASE, LIQUID-FILLED PAD-MOUNTED

TRANSFORMERS

26 13 01 08/13, CHG 1: 02/20 PAD-MOUNTED DEAD-FRONT AIR INSULATED

SWITCHGEAR

26 20 00 08/19, CHG 2: 05/21 INTERIOR DISTRIBUTION SYSTEM

26 28 00.00 10 10/07 MOTOR CONTROL CENTERS, SWITCHBOARDS

AND PANELBOARDS

26 28 01.00 10 08/21 COORDINATED POWER SYSTEM PROTECTION

26 29 23 02/20 ADJUSTABLE SPEED DRIVE (ASD) SYSTEMS

UNDER 600 VOLTS

26 41 00 11/13 LIGHTNING PROTECTION SYSTEM

26 51 00 05/20, CHG 2: 11/21 INTERIOR LIGHTING

26 56 00 08/21 EXTERIOR LIGHTING

DI VI SI ON 27 - COMMUNI CATI ONS

27 05 13.43 05/20 TELEVISION DISTRIBUTION SYSTEM

27 10 00 08/11 BUILDING TELECOMMUNICATIONS CABLING

SYSTEM

DI VI SI ON 28 - ELECTRONI C SAFETY AND SECURI TY

28 10 05 05/16 ELECTRONIC SECURITY SYSTEMS (ESS)

28 31 76 08/20 INTERIOR FIRE ALARM AND MASS

NOTIFICATION SYSTEM, ADDRESSABLE

DI VI SI ON 31 - EARTHWORK

31 00 00 08/08 EARTHWORK

31 05 22 08/08 GEOTEXTILES USED AS FILTERS

31 11 00 11/18 CLEARING AND GRUBBING

31 31 16.13 08/16 CHEMICAL TERMITE CONTROL

31 31 16.19 02/16 TERMITE CONTROL BARRIERS

DI VI SI ON 32 - EXTERI OR I MPROVEMENTS

32 05 33 08/17 LANDSCAPE ESTABLISHMENT

32 11 23 08/17 AGGREGATE BASE COURSES

32 12 13 05/17 BITUMINOUS TACK AND PRIME COATS

32 12 16 08/09 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 13.06 05/20 PORTLAND CEMENT CONCRETE PAVEMENT FOR

ROADS AND SITE FACILITIES

32 16 19 05/18 CONCRETE CURBS, GUTTERS AND SIDEWALKS

32 17 23 08/16, CHG 5: 11/18 PAVEMENT MARKINGS

32 18 16.13 08/17 PLAYGROUND PROTECTIVE SURFACING

32 31 13 11/16 CHAIN LINK FENCES AND GATES

32 84 23 04/08 UNDERGROUND SPRINKLER SYSTEMS

32 92 26 08/17, CHG 1: 08/21 SPRIGGING

32 93 00 08/17 EXTERIOR PLANTS

32 96 00 08/17, CHG 1: 08/21 TRANSPLANTING EXTERIOR PLANTS

DI VI SI ON 33 - UTI LI TI ES

33 11 00 02/18 WATER UTILITY DISTRIBUTION PIPING

33 30 00 05/18 SANITARY SEWERAGE

33 40 00 02/10, CHG 6: 02/19 STORM DRAINAGE UTILITIES

33 71 02 08/21 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 04/06 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

PROJECT TABLE OF CONTENTS Page 4

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 5

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS Page 6

SECTION 01 32 00

PROJECT SCHEDULE

03/17

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AACE INTERNATIONAL (AACE)

AACE 29R-03 (2011) Forensic Schedule Analysis

AACE 52R-06 (2006) Time Impact Analysis - As Applied in Construction

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1-1-11 (1995) Administration -- Progress, Schedules, and Network Analysis Systems

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Project Scheduler Qualifications; G

Preliminary Project Schedule; G

Initial Project Schedule; G

SD-06 Test Reports

Narrative Report

Schedule Reports

Periodic Schedule Updates

1.3 PROJECT SCHEDULER QUALIFICATIONS

Designate an authorized representative to be responsible for the preparation of the schedule and all required updating and production of reports. The authorized representative must have a minimum of 2-years experience scheduling construction projects similar in size and nature to this project with scheduling software that meets the requirements of this specification. Representative must have a comprehensive knowledge of CPM scheduling principles and application.

SECTION 01 32 00 Page 1

PART 2 PRODUCTS

2.1 SOFTWARE

The scheduling software utilized to produce and update the schedules required herein must be capable of meeting all requirements of this specification.

2.1.1 Government Default Software

The Government intends to use Primavera P6.

2.1.2 Contractor Software

Scheduling software used by the contractor must be commercially available from the software vendor for purchase with vendor software support agreements available. The software routine used to create the required SDEF file must be created and supported by the software manufacturer.

2.1.2.1 Primavera

If Primavera P6 is selected for use, provide the native schedule file (or XER export file) in a version of P6 importable by the Government system.

2.1.2.2 Other Than Primavera

If the contractor chooses software that is compliant with this specification but is other than Primavera P6, the software must be capable of generating a data file in the Standard Data Exchange Format (SDEF) as described in paragraph STANDARD ACTIVITY CODING DICTIONARY.

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

Prepare for approval a Project Schedule, as specified herein, pursuant to FAR Clause 52.236-15, SCHEDULE FOR CONSTRUCTION CONTRACTS. Show in the schedule the proposed sequence to perform the work and dates contemplated for starting and completing all schedule activities. The scheduling of the entire project is required. The scheduling of construction is the responsibility of the Contractor. Contractor management personnel must actively participate in its development. Subcontractors and suppliers working on the project must also contribute in developing and maintaining an accurate Project Schedule. Provide a schedule that is a forward planning as well as a project monitoring tool. Use the Critical Path Method (CPM) of network calculation to generate all Project Schedules.

Prepare each Project Schedule using the Precedence Diagram Method (PDM).

3.2 BASIS FOR PAYMENT AND COST LOADING

The schedule is the basis for determining contract earnings during each update period and therefore the amount of each progress payment. The aggregate value of all activities coded to a contract CLIN must equal the value of the CLIN.

3.2.1 Activity Cost Loading

Activity cost loading must be reasonable and without front-end loading.

All materials and procurement costs shall be loaded onto installation

SECTION 01 32 00 Page 2 activities only. Provide additional documentation to demonstrate reasonableness if requested by the Contracting Officer.

3.2.2 Withholdings / Payment Rejection

Failure to meet the requirements of this specification may result in the disapproval of the preliminary, initial or periodic schedule updates and subsequent rejection of payment requests until compliance is met.

In the event that the Contracting Officer directs schedule revisions and those revisions have not been included in subsequent Project Schedule revisions or updates, the Contracting Officer may withhold 10 percent of pay request amount from each payment period until such revisions to the project schedule have been made.

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

Develop the Project Schedule to the appropriate level of detail to address major milestones, all Definable Features of Work (FOW), and to allow for satisfactory project planning and execution. Failure to develop the Project Schedule to an appropriate level of detail will result in its disapproval. The Contracting Officer will consider, but is not limited to, the following characteristics and requirements to determine appropriate level of detail:

3.3.2 Activity Durations

Reasonable activity durations are those that allow the progress of ongoing activities to be accurately determined between update periods.

Less than 2 percent of all non-procurement activities may have Original Durations (OD) greater than 20 work days or 30 calendar days.

3.3.3 Permit Activities

Include permit activities with the necessary conferences and follow-up actions and design package submission dates.

3.3.4 Procurement Activities

Include activities associated with the critical submittals and their approvals, procurement, fabrication, and delivery of long lead materials, equipment, fabricated assemblies, and supplies. Long lead procurement activities are those with an anticipated procurement sequence of over 90 calendar days.

3.3.5 Mandatory Tasks

Include the following activities/tasks in the initial project schedule and all updates.

a. Submission, review and acceptance of SD-01 Preconstruction Submittals (individual activity for each).

b. Submission, review and acceptance of features require design completion

c. Submission of mechanical/electrical/information systems layout

SECTION 01 32 00 Page 3 drawings.

d. Long procurement activities

e. Submission and approval of O & M manuals.

f. Submission and approval of as-built drawings.

g. Submission and approval of installed equipment lists.

h. Submission and approval of testing and air balance (TAB).

i. Submission of TAB specialist design review report.

j. Submission and approval of fire protection specialist.

k. Submission and approval of Building Commissioning Plan, test data, and reports: Develop the schedule logic associated with testing and commissioning of mechanical systems to a level of detail consistent with the contract commissioning requirements. All tasks associated with all building testing and commissioning will be completed prior to submission of building commissioning report and subsequent contract completion.

l. Air and water balancing.

m. Building commissioning - Functional Performance Testing.

n. Controls testing plan submission.

o. Controls testing.

p. Performance Verification testing.

q. Other systems testing, if required.

r. Contractor's pre-final inspection.

s. Correction of punch list from Contractor's pre-final inspection.

t. Government's pre-final inspection.

u. Correction of punch list from Government's pre-final inspection.

v. Final inspection.

3.3.6 Government Activities

Show Government and other agency activities that could impact progress.

These activities include, but are not limited to: approvals, environmental permit approvals by State regulators, inspections, utility tie-ins, road closures, Government Furnished Equipment (GFE) and Notice to Proceed (NTP) for phasing requirements.

3.3.7 Standard Activity Coding Dictionary

Use the activity coding structure defined in the Standard Data Exchange Format (SDEF) in ER 1-1-11 . This exact structure is mandatory. Develop and assign all Activity Codes to activities as detailed herein.

SECTION 01 32 00 Page 4

Additional information is available on the RMS web site:

http://rms.usace.army.mil/QCS/Guides .

The SDEF format is as follows:

Field Activity Code Length Description

1 WRKP 3 Workers per day

2 RESP 4 Responsible party

3 AREA 4 Area of work

4 MODF 6 Modification Number

5 BIDI 6 Bid Item (CLIN)

6 PHAS 2 Phase of work

7 CATW 1 Category of work

8 FOW 30 Feature of work*

*Some systems require that FEATURE OF WORK values be placed in several activity code fields. The notation shown is for Primavera P6. Refer to the specific software guidelines with respect to the FEATURE OF WORK field requirements.

3.3.7.1 Workers Per Day (WRKP)

Assign Workers per Day for all field construction or direct work activities, if directed by the Contracting Officer. Workers per day is based on the average number of workers expected each day to perform a task for the duration of that activity.

3.3.7.2 Responsible Party Coding (RESP)

Assign responsibility code for all activities to the Prime Contractor, Subcontractor(s) or Government agency(ies) responsible for performing the activity.

a. Activities coded with a Government Responsibility code include, but are not limited to: Government approvals, environmental permit approvals by State regulators, Government Furnished Property/Equipment (GFP) and Notice to Proceed (NTP) for phasing requirements.

b. Activities cannot have more than one Responsibility Code. Examples of acceptable activity code values are: ELEC (for the electrical subcontractor); MECH (for the mechanical subcontractor); and GOVT (for USACE). Unacceptable code values are abbreviations of the the names of subcontractors.

SECTION 01 32 00 Page 5

3.3.7.3 Area of Work Coding (AREA)

Assign Work Area code to activities based upon the work area in which the activity occurs. Define work areas based on resource constraints or space constraints that would preclude a resource, such as a particular trade or craft work crew from working in more than one work area at a time due to restraints on resources or space. Examples of Work Area Coding include different areas within a floor of a building, different floors within a building, and different buildings within a complex of buildings.

Activities cannot have more than one Work Area Code.

Not all activities are required to be Work Area coded. A lack of Work Area coding indicates the activity is not resource or space constrained.

3.3.7.4 Modification Number (MODF)

Assign a Modification Number Code to any activity or sequence of activities added to the schedule as a result of a Contract Modification, when approved by Contracting Officer. Key all Code values to the Government's modification numbering system. An activity can have only one Modification Number Code.

3.3.7.5 Bid Item Coding (BIDI)

Assign a Bid Item Code to all activities using the Contract Line Item Schedule (CLIN) to which the activity belongs, even when an activity is not cost loaded. An activity can have only one BIDI Code.

3.3.7.6 Phase of Work Coding (PHAS)

Assign Phase of Work Code to all activities. Examples of phase of work are procurement phase and construction phase. Each activity can have only one Phase of Work code.

b. If the contract specifies phasing with separately defined performance periods, identify a Phase Code to allow filtering and organizing the schedule accordingly.

3.3.7.7 Category of Work Coding (CATW)

Assign a Category of Work Code to all activities. Category of Work Codes include, but are not limited to construction submittal, procurement, fabrication, weather sensitive installation, non-weather sensitive installation, start-up, and testing activities. Each activity canhave no more than one Category of Work Code.

3.3.7.8 Feature of Work Coding (FOW)

Assign a Feature of Work Code to appropriate activities based on the Definable Feature of Work to which the activity belongs based on the approved QC plan.

Definable Feature of Work is defined in Section 01 45 04 QUALITY CONTROL.

An activity can have only one Feature of Work Code.

3.3.8 Contract Milestones and Constraints

Milestone activities are to be used for significant project events

SECTION 01 32 00 Page 6 including, but not limited to, project phasing, project start and end activities, or interim completion dates. The use of artificial float constraints such as "zero free float" or "zero total float" are prohibited.

Mandatory constraints that ignore or affect network logic are prohibited.

No constrained dates are allowed in the schedule other than those specified herein. Submit additional constraints to the Contracting Officer for approval on a case by case basis.

3.3.8.1 Project Start Date Milestone and Constraint

The first activity in the project schedule must be a start milestone titled "NTP Acknowledged," which must have a "Start On" constraint date equal to the date that the NTP is acknowledged.

3.3.8.2 End Project Finish Milestone and Constraint

The last activity in the schedule must be a finish milestone titled "End Project."

Constrain the project schedule to the Contract Completion Date in such a way that if the schedule calculates an early finish, then the float calculation for "End Project" milestone reflects positive float on the longest path. If the project schedule calculates a late finish, then the "End Project" milestone float calculation reflects negative float on the longest path. The Government is under no obligation to accelerate Government activities to support a Contractor's early completion.

3.3.8.3 Interim Completion Dates and Constraints

Constrain contractually specified interim completion dates to show negative float when the calculated late finish date of the last activity in that phase is later than the specified interim completion date.

3.3.8.3.1 Start Phase

Use a start milestone as the first activity for a project phase. Call the start milestone "Start Phase X" where "X" refers to the phase of work.

3.3.8.3.2 End Phase

Use a finish milestone as the last activity for a project phase. Call the finish milestone "End Phase X" where "X" refers to the phase of work.

3.3.9 Calendars

Schedule activities on a Calendar to which the activity logically belongs. Develop calendars to accommodate any contract defined work period such as a 7-day calendar for Government Acceptance activities, concrete cure times, etc. Develop the default Calendar to match the physical work plan with non-work periods identified including weekends and holidays. Develop Seasonal Calendar(s) and assign to seasonally affected activities as applicable.

3.3.10 Open Ended Logic

Only two open ended activities are allowed: the first activity "NTP Acknowledged" may have no predecessor logic, and the last activity -"End

SECTION 01 32 00 Page 7

Project" may have no successor logic.

Predecessor open ended logic may be allowed in a time impact analyses upon the Contracting Officer's approval.

3.3.11 Default Progress Data Disallowed

Actual Start and Finish dates must not automatically update with default mechanisms included in the scheduling software. Updating of the percent complete and the remaining duration of any activity must be independent functions. Disable program features that calculate one of these parameters from the other. Activity Actual Start (AS) and Actual Finish (AF) dates assigned during the updating process must match those dates provided in the Contractor Quality Control Reports. Failure to document the AS and AF dates in the Daily Quality Control report will result in disapproval of the Contractor's schedule.

3.3.12 Out-of-Sequence Progress

Activities that have progressed before all preceding logic has been satisfied (Out-of-Sequence Progress) will be allowed only on a case-by-case basis subject to approval by the Contracting Officer.

Propose logic corrections to eliminate out of sequence progress or justify not changing the sequencing for approval prior to submitting an updated project schedule. Address out of sequence progress or logic changes in the Narrative Report and in the periodic schedule update meetings.

3.3.13 Added and Deleted Activities

Do not delete activities from the project schedule or add new activities to the schedule without approval from the Contracting Officer. Activity ID and description changes are considered new activities and cannot be changed without Contracting Officer approval.

3.3.14 Original Durations

Activity Original Durations (OD) must be reasonable to perform the work item. OD changes are prohibited unless justification is provided and approved by the Contracting Officer.

3.3.15 Leads, Lags, and Start to Finish Relationships

Lags must be reasonable as determined by the Government and not used in place of realistic original durations, must not be in place to artificially absorb float, or to replace proper schedule logic.

a. Leads (negative lags) are prohibited.

b. Start to Finish (SF) relationships are prohibited.

3.3.16 Retained Logic

Schedule calculations must retain the logic between predecessors and successors ("retained logic" mode) even when the successor activity(s) starts and the predecessor activity(s) has not finished (out-of-sequence progress). Software features that in effect sever the tie between predecessor and successor activities when the successor has started and the predecessor logic is not satisfied ("progress override") are not be allowed.

SECTION 01 32 00 Page 8

3.3.17 Percent Complete

Update the percent complete for each activity started, based on the realistic assessment of earned value. Activities which are complete but for remaining minor punch list work and which do not restrain the initiation of successor activities may be declared 100 percent complete to allow for proper schedule management.

3.3.18 Remaining Duration

Update the remaining duration for each activity based on the number of estimated work days it will take to complete the activity. Remaining duration may not mathematically correlate with percentage found under paragraph entitled Percent Complete. The Remaining Duration for each activity shall, at all times, equal its Original Duration for all unstarted activities.

3.3.19 Cost Loading of Closeout Activities

Cost load the last "Correction of punch list from Government pre-final inspection" activity not less than 1 percent of the present contract value. The activity may be declared 100 percent complete upon the Government's verification of completion and correction of all punch list work identified during Government pre-final inspection(s). Partial payments will not be considered.

3.3.19.1 As-Built Drawings

If there is no separate contract line item (CLIN) for as-built drawings, cost load the "Final approval of as-built drawings" activity not less than $35,000 or 1 percent of the present contract value, which ever is greater, up to $200,000. Activity will be declared 100 percent complete upon the Government's acceptance of the completed final as-built drawings. Partial payments will not be considered.

3.3.19.2 O & M Manuals

Cost load the "Final approval of O & M manuals" activity not less than $20,000. Activity will be declared 100 percent complete upon the Government's acceptance of all O & M manuals. Partial payments will not be considered.

3.3.20 Anticipated Adverse Weather

Paragraph applicable to contracts with clause S-36.5 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (Section 01 90 00). Original durations must account for anticipated adverse weather. All work periods not identified as non-work periods on each calendar will be interpreted as a Contractor-intended work period.

3.3.21 Early Completion Schedule and the Right to Finish Early

An Early Completion Schedule is an Initial Project Schedule (IPS) that indicates all scope of the required contract work will be completed before the contractually required completion date.

a. No IPS indicating an Early Completion will be accepted without being fully resource-loaded (including crew sizes and manhours) and the

SECTION 01 32 00 Page 9

Government agreeing that the schedule is reasonable and achievable.

b. The Government is under no obligation to accelerate work items it is responsible for to ensure that the early completion is met nor is it responsible to modify incremental funding (if applicable) for the project to meet the contractor's accelerated work.

c. The Government shall be exempt from liability for early completion delay damages. No claim shall be made by or allowed to the Contractor for any damages which may arise out of any delay to early completion.

3.4 PROJECT SCHEDULE SUBMISSIONS

Provide the submissions as described below. The data CD/DVD, reports, and network diagrams required for each submission are contained in paragraph SUBMISSION REQUIREMENTS. If the Contractor fails or refuses to furnish the information and schedule updates as set forth herein, then the Contractor will be deemed not to have provided an estimate upon which a progress payment can be made.

Review comments made by the Government on the schedule(s) do not relieve the Contractor from compliance with requirements of the Contract Documents.

3.4.1 Preliminary Project Schedule Submission

Within 15 calendar days after the NTP is acknowledged submit the Preliminary Project Schedule defining the planned operations detailed for the first 90 calendar days for acceptance. The accepted Preliminary Project Schedule will be used for payment purposes not to exceed 90 calendar days after NTP. Completely cost load the Preliminary Project Schedule to balance the contract award CLINS shown on the Price Schedule.

The Preliminary Project Schedule may be summary in nature for the remaining performance period. It must be early start and late finish constrained and logically tied as specified. The Preliminary Project Schedule forms the basis for the Initial Project Schedule specified herein and must include all of the required plan and program preparations, submissions and approvals identified in the contract (for example, Quality Control Plan, Safety Plan, and Environmental Protection Plan) as well as permitting activities, and other non-construction activities intended to occur within the first 90 calendar days. Government acceptance of all other specified Program and Plan approvals must occur prior to any planned construction activities. Activity code any activities that are summary in nature after the first 90 calendar days with Bid Item (CLIN) code (BIDI), Responsibility Code (RESP) and Feature of Work code (FOW).

3.4.2 Initial Project Schedule Submission

Submit the Initial Project Schedule for acceptance within 42 calendar days after notice to proceed is issued. The schedule must demonstrate a reasonable and realistic sequence of activities which represent all work through the entire contract performance period. No payment will be made for work items not fully detailed in the Project Schedule.

3.4.3 Periodic Schedule Updates

Update the Project Schedule on a regular basis, monthly at a minimum.

Provide schedule updates for review at the schedule update meeting using the previous month's unaltered Project Schedule. If schedule logic changes are being proposed, provide a separate draft Periodic Schedule Update with

SECTION 01 32 00 Page 10 all updates and logic changes for review at the schedule update meetings as prescribed in the paragraph PERIODIC SCHEDULE UPDATE MEETINGS. Logic changes include, but are not limited to, any modifications to the schedule's activity names, relationships, durations (for unstarted activities), lags, added/deleted activities, calendars, or similar.

These updates will enable the Government to assess Contractor's Actual vs.

Planned progress.

a. Update information including Data Date (DD), Actual Start Dates (AS), Actual Finish Dates (AF), Remaining Durations (RD), and Percent Complete is subject to the approval of the Government at the meeting.

b. AS and AF dates must match the date(s) reported on the Contractor's Quality Control Report for an activity start or finish.

3.5 SUBMISSION REQUIREMENTS

Submit the following items for the Preliminary Schedule, Initial Schedule, and every Periodic Schedule Update throughout the life of the project:

3.5.1 Data CD/DVDs

Provide two sets of data CD/DVDs containing the current project schedule and all previously submitted schedules in the format of the scheduling software (e.g. .XER). Also include on the data CD/DVDs the Narrative Report and all required Schedule Reports. Label each CD/DVD indicating the type of schedule (Preliminary, Initial, Update), full contract number, Data Date, Contract ID, and file name. Each schedule must have a unique Contract ID and file name and use project specific settings.

3.5.2 Narrative Report

Provide a Narrative Report with each schedule submission. The Narrative Report is expected to communicate to the Government the thorough analysis of the schedule output and the plans to compensate for any problems, either current or potential, which are revealed through that analysis.

Include the following information as minimum in the Narrative Report:

a. Identify and discuss the work scheduled to start in the next update period.

b. A description of activities along the two most critical paths where the total float is less than or equal to 20 work days.

c. A description of current and anticipated problem areas or delaying factors and their impact and an explanation of corrective actions taken or required to be taken.

d. Identify and explain why activities based on their calculated late dates should have either started or finished during the update period but did not.

e. Identify and discuss all schedule changes by activity ID and activity name including what specifically was changed and why the change was needed. Include at a minimum new and deleted activities, logic changes, duration changes, calendar changes, lag changes, resource changes, and actual start and finish date changes.

SECTION 01 32 00 Page 11

f. Identify and discuss out-of-sequence work.

3.5.3 Schedule Reports

The format, filtering, organizing and sorting for each schedule report will be as directed by the Contracting Officer. Typically, reports contain Activity Numbers, Activity Description, Original Duration, Remaining Duration, Early Start Date, Early Finish Date, Late Start Date, Late Finish Date, Total Float, Actual Start Date, Actual Finish Date, and Percent Complete. Provide the reports electronically in .pdf format. The following lists typical reports that will be requested:

3.5.3.1 Activity Report

List of all activities sorted according to activity number.

3.5.3.2 Logic Report

List of detailed predecessor and successor activities for every activity in ascending order by activity number.

3.5.3.3 Total Float Report

A list of all incomplete activities sorted in ascending order of total float. List activities which have the same amount of total float in ascending order of Early Start Dates. Do not show completed activities on this report.

3.5.3.4 Earnings Report by CLIN

A compilation of the Total Earnings on the project from the NTP to the data date, which reflects the earnings of activities based on the agreements made in the schedule update meeting defined herein. Provided a complete schedule update has been furnished, this report serves as the basis of determining progress payments. Group activities by CLIN number and sort by activity number. Provide a total CLIN percent earned value, CLIN percent complete, and project percent complete. The printed report must contain the following for each activity: the Activity Number, Activity Description, Original Budgeted Amount, Earnings to Date, Earnings this period, Total Quantity, Quantity to Date, and Percent Complete (based on cost).

3.5.3.5 Schedule Log

Provide a Scheduling/Leveling Report generated from the current project schedule being submitted.

3.5.4 Network Diagram

The Network Diagram is required for the Preliminary, Initial and Periodic Updates. Depict and display the order and interdependence of activities and the sequence in which the work is to be accomplished. The Contracting Officer will use, but is not limited to, the following conditions to review compliance with this paragraph:

3.5.4.1 Continuous Flow

Show a continuous flow from left to right with no arrows from right to left. Show the activity number, description, duration, and estimated

SECTION 01 32 00 Page 12 earned value on the diagram.

3.5.4.2 Project Milestone Dates

Show dates on the diagram for start of project, any contract required interim completion date(s), and contract completion date(s).

3.5.4.3 Critical Path

Show all activities on the critical path. The critical path is defined as the longest path.

3.5.4.4 Banding

Organize activities using the WBS or as otherwise directed to assist in the understanding of the activity sequence. Typically, this flow will group activities by major elements of work, category of work, work area and/or responsibility.

3.5.4.5 Cash Flow / Schedule Variance Control (SVC) Diagram

With each schedule submission, provide a SVC diagram showing 1) Cash Flow S-Curves indicating planned project cost based on projected early and late activity finish dates, and 2) Earned Value to-date.

3.6 PERIODIC SCHEDULE UPDATE

3.6.1 Periodic Schedule Update Meetings

Conduct periodic schedule update meetings for the purpose of reviewing the proposed Periodic Schedule Update, Narrative Report, Schedule Reports, and progress payment. Conduct meetings at least monthly within five days of the proposed schedule data date. Provide a computer with the scheduling software loaded and a projector which allows all meeting participants to view the proposed schedule during the meeting. The Contractor's authorized scheduler must organize, group, sort, filter, perform schedule revisions as needed and review functions as requested by the Contractor and/or Government. The meeting is a working interactive exchange which allows the Government and Contractor the opportunity to review the updated schedule on a real time and interactive basis. The meeting will last no longer than 8 hours. Provide a draft of the proposed narrative report and schedule data file to the Government a minimum of two workdays in advance of the meeting. The Contractor's Project Manager and scheduler must attend the meeting with the authorized representative of the Contracting Officer. Superintendents, foremen and major subcontractors must attend the meeting as required to discuss the project schedule and work.

Following the periodic schedule update meeting, make corrections to the draft submission. Include only those changes approved by the Government in the submission and invoice for payment.

3.6.2 Update Submission Following Progress Meeting

Submit the complete Periodic Schedule Updates of the Project Schedule containing all approved progress, revisions, and adjustments, pursuant to paragraph SUBMISSION REQUIREMENTS together with the monthly progress payment request.

SECTION 01 32 00 Page 13

3.7 WEEKLY PROGRESS MEETINGS

Conduct a weekly meeting with the Government (or as otherwise mutually agreed to) between the meetings described in paragraph entitled PERIODIC SCHEDULE UPDATE MEETINGS for the purpose of jointly reviewing the actual progress of the project as compared to the as planned progress and to review planned activities for the upcoming two weeks. Use the current approved schedule update for the purposes of this meeting and for the production and review of reports. At the weekly progress meeting, address the status of RFIs, RFPs and Submittals.

3.8 REQUESTS FOR TIME EXTENSIONS

Provide a justification of delay to the Contracting Officer in accordance with the contract provisions and clauses for approval within 10 days of a delay occurring. Also prepare a time impact analysis for each Government request for proposal (RFP) to justify time extensions.

3.8.1 Justification of Delay

Provide a description of the event(s) that caused the delay and/or impact to the work. As part of the description, identify all schedule activities impacted. Show that the event that caused the delay/impact was the responsibility of the Government. Provide a time impact analysis that demonstrates the effects of the delay or impact on the project completion date or interim completion date(s). Evaluate multiple impacts chronologically; each with its own justification of delay. With multiple impacts consider any concurrency of delay. A time extension and the schedule fragnet becomes part of the project schedule and all future schedule updates upon approval by the Contracting Officer.

3.8.2 Time Impact Analysis (Prospective Analysis)

Prepare a time impact analysis for approval by the Contracting Officer based on industry standard AACE 52R-06 . Utilize a copy of the last approved schedule prior to the first day of the impact or delay for the time impact analysis. If Contracting Officer determines the time frame between the last approved schedule and the first day of impact is too great, prepare an interim updated schedule to perform the time impact analysis. Unless approved by the Contracting Officer, no other changes may be incorporated into the schedule being used to justify the time impact.

3.8.3 Forensic Schedule Analysis (Retrospective Analysis)

Prepare an analysis for approval by the Contracting Officer based on industry standard AACE 29R-03 .

3.8.4 Fragmentary Network (Fragnet)

Prepare a proposed fragnet for time impact analysis consisting of a sequence of new activities that are proposed to be added to the project schedule to demonstrate the influence of the delay or impact to the project's contractual dates. Clearly show how the proposed fragnet is to be tied into the project schedule including all predecessors and successors to the fragnet activities. The proposed fragnet must be approved by the Contracting Officer prior to incorporation into the project schedule.

SECTION 01 32 00 Page 14

3.8.5 Time Extension

The Contracting Officer must approve the Justification of Delay including the time impact analysis before a time extension will be granted. No time extension will be granted unless the delay consumes all available Project Float and extends the projected finish date ("End Project" milestone) beyond the Contract Completion Date. The time extension will be in calendar days.

Actual delays that are found to be caused by the Contractor's own actions, which result in a calculated schedule delay will not be a cause for an extension to the performance period, completion date, or any interim milestone date.

3.8.6 Impact to Early Completion Schedule

No extended overhead will be paid for delay prior to the original Contract Completion Date for an Early Completion IPS unless the Contractor actually performed work in accordance with that Early Completion Schedule. The Contractor must show that an early completion was achievable had it not been for the impact.

3.9 FAILURE TO ACHIEVE PROGRESS

Should the progress fall behind the approved project schedule for reasons other than those that are excusable within the terms of the contract, the Contracting Officer may require provision of a written recovery plan for approval. The plan must detail how progress will be made-up to include which activities will be accelerated by adding additional crews, longer work hours, extra work days, etc.

3.9.1 Artificially Improving Progress

Artificially improving progress by means such as, but not limited to, revising the schedule logic, modifying or adding constraints, shortening activity durations, or changing calendars in the project schedule is prohibited. Indicate assumptions made and the basis for any logic, constraint, duration and calendar changes used in the creation of the recovery plan. Any additional resources, manpower, or daily and weekly work hour changes proposed in the recovery plan must be evident at the work site and documented in the daily report along with the Schedule Narrative Report.

3.9.2 Failure to Perform

Failure to perform work and maintain progress in accordance with the supplemental recovery plan may result in an interim and final unsatisfactory performance rating and/or may result in corrective action directed by the Contracting Officer pursuant to FAR 52.236-15 Schedules for Construction Contracts, FAR 52.249-10 Default (Fixed-Price Construction), and other contract provisions.

3.9.3 Recovery Schedule

Should the Contracting Officer find it necessary, submit a recovery schedule pursuant to FAR 52.236-15 Schedules for Construction Contracts.

SECTION 01 32 00 Page 15

3.10 OWNERSHIP OF FLOAT

Except for the provision given in the paragraph IMPACT TO EARLY COMPLETION SCHEDULE, float available in the schedule, at any time, may not be considered for the exclusive use of either the Government or the Contractor including activity and/or project float. However, in accordance with paragraph EARLY COMPLETION SCHEDULE AND THE RIGHT TO FINISH EARLY, the Government is specifically and expressly exempt from liability for early completion delay damages. Activity float (or Free Float) is the number of work days that an activity can be delayed without causing a delay to the "End Project" finish milestone. Project float (or Total Float) is the number of work days between the projected early finish and the contract completion date milestone.

3.11 TRANSFER OF SCHEDULE DATA INTO RMS3/CM

Import the schedule data into RMS3/CM (See Section 01 45 00). This data is considered to be additional supporting data in a form and detail required by the Contracting Officer pursuant to FAR 52.232-5 - Payments under Fixed-Price Construction Contracts. The receipt of a proper payment request pursuant to FAR 52.232-27 - Prompt Payment for Construction Contracts is contingent upon the Government receiving both acceptable and approvable hard copies and matching data in RMS3/CM for the progress payment.

3.12 PRIMAVERA P6 MANDATORY REQUIREMENTS

If Primavera P6 is being used, request a backup file template (.XER) from the Government, if one is available, prior to building the schedule. The following settings are mandatory and required in all schedule submissions to the Government:

a. Activity Codes must be Project Level, not Global or EPS level.

b. Calendars must be Project Level, not Global or Resource level.

c. Activity Duration Types must be set to "Fixed Duration & Units" .

d. Percent Complete Types must be set to "Physical".

e. Time Period Admin Preferences must remain the default "8.0 hr/day, 40 hr/week, 172 hr/month, 2000 hr/year". Set Calendar Work Hours/Day to

8.0 Hour days.

f. Set Schedule Option for defining Critical Activities to "Longest Path".

g. Set Schedule Option for defining progressed activities to "Retained Logic".

h. Set up cost loading using a single lump sum labor resource. The Price/Unit must be $1/hr, Default Units/Time must be "8h/d", and settings "Auto Compute Actuals" and "Calculate costs from units" selected.

i. Activity ID's must not exceed 10 characters.

j. Activity Names must have the most defining and detailed description within the first 30 characters.

SECTION 01 32 00 Page 16

k. The "Link Budget and At Completion for not started activities" option on the "Calculations" tab (Enterprise Level) must remain checked at all times.

-- End of Section --

SECTION 01 32 00 Page 17

THIS PAGE INTENTIONALLY LEFT BLANK

SECTION 01 32 00 Page 18

SECTION 01 33 00

SUBMITTAL PROCEDURES

03/17

PART 1 GENERAL

The Contracting Officer may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective sections.

Units of weights and measures used on all submittals are to be the same as those used in the contract drawings.

Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.

Contractor's Quality Control (CQC) System Manager shall check and approve all items prior to submittal and stamp, sign, and date indicating action taken. Proposed variations from the contract requirements are to be clearly identified and an explanation provided as to why it is being requested. Include within submittals items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves;

test reports; test cylinders; samples; O&M manuals (including parts list);

certifications; warranties; and other such required submittals.

Submittals requiring Government approval are to be scheduled and made prior to the acquisition of the material or equipment covered thereby.

Pick up and dispose of samples not incorporated into the work in accordance with manufacturer's Safety Data Sheets (SDS) and in compliance with existing laws and regulations.

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction (work) or the start of the next major phase of the construction on a multi-phase contract, includes schedules, tabular list of data, or tabular list including location, features, or other pertinent information regarding products, materials, equipment, or components to be used in the work.

Certificates of insurance

Surety bonds

List of proposed Subcontractors

Network Analysis Schedule (NAS)

Submittal register

SECTION 01 33 00 Page 1

Schedule of prices

Accident Prevention plan

Quality Control(QC) plan

Environmental protection plan

Permits

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or…