Att9_170123_Liquidated Damages Signed.pdf
PDF 185 KB Posted
- Solicitation number
- FA8137-26-R-0035
About this file
This is a Liquidated Damages assessment document for a roof repair project at a logging facility. Project WWYK170123 concerns repair work on the roof of the Log Facility Department Operations Building B201. The document establishes liquidated damages of $227.75 per calendar day for any delay in completing the work, assessed in accordance with FAR 36.206 and DFARS 236.206.
The daily liquidated damages calculation comprises two components: engineering costs totaling $122.36 per day and government costs totaling $105.39 per day. Engineering costs include 0.5 hours of Engineering Manager time at $57.69/hour, 1 hour of Project Manager time at $36.06/hour, 1 hour of Engineering Tech/Inspector time at $28.52/hour, 0.5 hours of Project Engineers time at $38.46/hour, and 0.5 hours of Clerical time at $19.41/hour. Government costs include 0.5 hours of FAS (GS-12/5) time at $39.19/hour, 1 hour of Legal (GS-13/5) time at $46.60/hour, and 1 hour of Contracting (GS-12/5) time at $39.19/hour. The assessment is justified based on the contractor's complete control of work pace, the contract's provision for daily liquidated damages, and the reasonableness of the rate relative to project requirements. The document was signed by Contracting Officer Sara Hinds on 8 May 2026.
View the file
Other files
Show all 27
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PROJECT NUMBER & TITLE: WWYK170123_REPAIR ROOF, LOG FCLTY DEP OPS B201
FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$
ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$
SUBTOTAL 122.36$
GOVERNMENT TITLE Hrs RATE TOTAL
FAS (GS-12/5) 0.5 39.19$ 19.60$
Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$
SUBTOTAL 105.39$
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$
Contracting Officer (Signature)
Contracting Officer (Print)
Date: 8 May 2026
LIQUIDATED DAMAGES
In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work.
b. The contract provides for LDs for delay of work for each calendar day of the contract.
c. Considering the requirement, the rate of assessment is reasonable.
Sara Hinds
Sheet1
| 2026-05-08T11:04:06-0500 | |
| HINDS.SARA.MUSE.1150957075 |
File details come from the government source that posted it. Updated .