Amend 1_FA461326Q00070001 SF 30.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

J

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

22 Apr 2026

4. REQUISITION/PURCHASE

REQUISITION NUMBER

5. PROJECT NUMBER (if applicable)

6. ISSUED BY CODE FA4613

FA4613 90 CONS PK

CP 307 773 3888, 7505 BARNES LOOP BLDG 208

FE WARREN AFB, WY 82005-2860

UNITED STATES

NATALIE MARTINEZ, Email: andrea.mccurry@us.af.mil Telephone: 0004813017 Andrea McCurry, Email: andrea.mccurry@us.af.mil Telephone: 0004813017

7. ADMINISTERED BY (if other than Item 6)

CODE

SCD: PAS:

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code)

CODE: FACILITY CODE:

9A. AMENDMENT OF SOLICITATION NUMBER

FA461326Q0007

9B. DATED (SEE ITEM 11)

22 Apr 2026

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; 1 or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required) See Section G - Contract Administration Data

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK

ONE

A.THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.)

SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Addition of missing clause.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Andrea M. McCurry

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

22 Apr 2026

Computer generated. Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA-FAR (48 CFR) 53.243

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Contract Clauses

Additional Regulation or Supplemental Clauses Incorporated by Full Text

The following Clause(s) were added:

FAR Clauses Incorporated by Full Text 52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. (Sep 2000)

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $ per calendar day of delay.843.98

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

FA461326Q00070001