Attachment 2 Past Performance References.docx

ATTACHMENT 02: PAST PERFORMANCE REFERENCES

Solicitation Number:

Offeror Name:

OVERVIEW AND INSTRUCTIONS

Offerors shall provide documentation outlining past performance with contracts, as a prime or major subcontractor, which is the same or similar in nature, size, and complexity to the services being procured.

1. Recency: Efforts must be ongoing or performed within the past three (3) years from the issuance date of this solicitation.

2. Relevancy: Offerors must explain what aspects of the contracts are deemed relevant to the proposed effort (e.g., work under state-issued environmental permits, large-scale groundwater monitoring, remote installation operations).

3. Quantity: Provide up to three (3) references for the Prime and three (3) for each Major Subcontractor (performing >10% of the effort).

CONTRACT REFERENCE DATA

1. Contract Identification

· Contract Number: __________________________

· Award Date: __________________________

· Contract Type (e.g., FFP, CPFF): __________________________

2. Price / Cost Data

· Original Awarded Price: $__________________________

· Final (or Projected Final) Price: $__________________________

· Explain any cost growth (if applicable): _________________________________________________

3. Performance Period / Delivery Schedule

· Original Completion Date: __________________________

· Final (or Projected Final) Completion Date: __________________________

· Explain any schedule delays (if applicable): _________________________________________________

4. Contact Information

· Procuring Contracting Officer (PCO): Name/Phone/Email: _____________________________________

· Administrative Contracting Officer (ACO): Name/Phone/Email: ___________________________________

· Technical Rep / COR: Name/Phone/Email: __________________________________________________

RELEVANCY AND PERFORMANCE NARRATIVE

5. Relevancy Description

In the space below, identify in specific detail why this effort is relevant to the DPG PWS. Address specific similarities in: (a) CHWSF/Hazardous Waste management under state permits; (b) Groundwater/UST/TSCA monitoring; and (c) Performance in isolated/remote environments.

6. Narrative Explanation of Objectives Achieved Provide a brief summary of the technical objectives achieved. If original requirements for cost, schedule, or technical performance were not met, explain the reason and the demonstrated corrective actions taken to avoid recurrence.

7. Negative Performance Documentation Identify if the offeror received any Cure Notices, Show Cause Letters, or Contract Discrepancy Reports (CDRs) on this contract. If so, attach a copy and describe the corrective actions taken.

AUTHORIZATION

By submission of this proposal, the Offeror grants the Government permission to contact the references listed above to verify performance history and technical acceptability.