6982AF24B000019 A004 SF30 CA ERFO DEVA 2022-1(2).pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

A004

The purpose of this amendment is to amend the IFB as follows:

1. Replace page A-1 with the attached page A-1

2. Replace page C-3 with the attached page C-3

3. Replace page E-16 with the attached page E-16

FEDERAL HIGHWAY ADMINISTRATION CENTRAL

FEDERAL LANDS HIGHWAY DIVISION 12300 WEST

DAKOTA AVENUE, SUITE 360 LAKEWOOD, COLORADO

80228 ATTENTION: KELLY PALMER

6982AF24B000019

5. PROJECT NUMBER (If applicable)

CA ERFO DEVA 2022-1(2)

10/01/2024

09/03/2024

0*

*See Item 14

*FAILURE TO ACKNOWLEDGE THIS AMENDMENT IN BLOCK 19 OF THE SF1442 BY THE DESIGNATED DATE AND HOUR SPECIFIED IN

THE SOLICITATION MAY RESULT IN REJECTION OF YOUR BID (REFER TO ITEM 11.)

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration or Repair)

1. SOLICITATION NO.

6982AF24B000019

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

09/03/2024

PAGE OF

PAGES

IMPORTANT - THE "OFFER SECTION ON THE REVERSE MUST BE FULLY COMPLETED BY OFFEROR.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

HFLCEO240370PR

6. PROJECT NO.

CA ERFO NP DEVA 2022-1(2)

7. ISSUED BY:

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS DIVISION

12300 WEST DAKOTA AVENUE, SUITE 167

LAKEWOOD, COLORADO 80228

CODE: 69050001 8. ADDRESS OFFER TO:

Kelly Palmer, Contract Specialist Federal Highway Administration Central Federal Lands Division Office 12300 W. Dakota Avenue Lakewood, CO 80228

9. FOR INFORMATION CALL

SEE PAGE A-3

A. NAME:

SEE PAGE A-3

B. TELEPHONE NO. (Include area code)

SEE PAGE A-3

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS:

ROADWAY CONSTRUCTION PROJECT IN STRICT ACCORDANCE WITH:

1. FEDERAL ACQUISITION AND TRANSPORATION ACQUISITION REGULATIONS (FAR & TAR)

2. DEPARTMENT OF LABOR, CONSTRUCTION WAGE RATE REQUIREMENT RATES

3. SPECIAL CONTRACT REQUIREMENTS

4. PLANS

5. BID SCHEDULE

6. STANDARD SPECIFICATIONS FOR CONSTRUCTION OF ROADS AND BRIDGES ON FEDERAL HIGHWAY

PROJECTS, FP-14, U.S. CUSTOMARY UNITS

See Subsection 104.04 of the FP-14 for governing order of precedence

11. The Contractor shall begin performance within 10 calendar days and complete it within * calendar days after receiving award notice to proceed. The performance period is mandatory negotiable. *Refer to Subsection 108.01 as amended in the Special Contract Requirements.

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.) YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 0 copies to perform the work required are due at the place specified in Item 8. by 2:00 p.m. (hour) local time on 10/03/2024 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is is not required.

C. All offers are subject to the (1) work requirements and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA

FAR (48 CFR) 53.236-1(d)

X

X

X

X

X

A-1

10/10/2024

6982AF24B000019

Amendment A004

10/01/2024

C-3

Provided by Kaspersky Lab and Other Covered Entities (DEC 2023)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021)

52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023)

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021)

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations (NOV 2015)

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) Alternate I

(APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than {Refer to Subsection 108.01 of the SCRs}. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by November 18, 2024 December 3, 2024. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.211-12 Liquidated Damages - Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $3,400.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 Time Extensions. (SEP 2000)

52.211-18 Variation in Estimated Quantity. (APR 1984)

6982AF24B000019

Amendment A004

10/01/2024 kelly.palmer Cross-Out

E-16

CA ERFO NP DEVA 2022-1(2)

Salt Creek Interpretive Trail

PMIS #: 331907

(c) Coordination will be required with multiple construction projects in the Park, including but not limited to;

(1) CA ERFO NP 2023-3(2), Repairs and Armoring Project, scheduled for completion in Summer, 2025.

During the listed Federal holidays and surrounding days as shown in Table 108-2, perform no work except to maintain traffic control devices, erosion control devices, the roadway driving surface, and to control dust.

Table 108-2 Federal Holidays and Surrounding Days

Federal Holiday Time Remarks

Memorial Day 12:00 Noon Friday to 6:00 am Tuesday -

Independence Day 12:00 Noon July 3 to 6:00 am July 5

If July 4 falls on a weekend, Friday, or Monday, do not work the weekend.

Labor Day 12:00 Noon Friday to 6:00 am Tuesday -

Thanksgiving 12:00 Noon Wednesday to 6:00 am Monday -

Christmas / New Year’s

12:00 Noon December 23 to 6:00 am January 2

If December 23 or January 1 falls on a Monday, do not work the adjacent weekend and do not work on December 23. If January 1 falls on a Friday, do not work the weekend.

Schedule at least 2 non-work days out of every 14 calendar days. The selected non-work days do not need to be consecutive, but they must be scheduled. Notify the CO at least 2 weeks before changing the scheduled days off.

The CO may grant written approval for exemptions to scheduled days off for specific project operations and for periods of limited duration.

Add the following:

The CO will issue a Notice to Proceed before commencement of any work. The contract completion date is May 16,2025 May 21, 2025.

Add the following:

6982AF24B000019

Amendment A004

10/01/2024