SIR 6973GH-26-R-00002 Final 10.6.25.pdf

SOLICITATION, OFFER AND AWARD

3. SOLICITATION TYPE1. CONTRACT NO. 2. SOLICITATION NUMBER

6. ISSUED BY CODE 7. ADDRESS OFFER TO (If other than Item 6)

5. REQUISITION/PURCHASE NUMBER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder"

NEGOTIATED BID (RFP)

SEALED BID (IFB)

4. DATE ISSUED

PAGE OF PAGES

1 70

C. E-MAIL ADDRESS

EXT.NUMBERAREA CODE

B. TELEPHONE (NO COLLECT CALLS)A. NAME

9. FOR

INFORMATION

CALL

CAUTION: LATE Submissions, Modifications and Withdrawals. All offers are subject to all terms and conditions contained in this solicitation.

(Date)(Hour) local timeuntildepository located in copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 7, or if hand carried, in the

SOLICITATION

8. Sealed offers in original and

PART IV - REPRESENTATIONS AND INSTRUCTIONS

OTHER STATEMENTS OF OFFERORS

EVALUATION FACTORS FOR AWARD

INSTR., CONDS., AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND

LIST OF ATTACHMENTS

CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACH.

I

J

K

L

M SPECIAL CONTRACT REQUIREMENTS

CONTRACT ADMINISTRATION DATA

DELIVERIES OR PERFORMANCE

INSPECTION AND ACCEPTANCE

PACKAGING AND MARKING

DESCRIPTION/SPECS./WORK STATEMENT

SUPPLIES OR SERVICES AND PRICE/COST

SOLICITATION/CONTRACT FORM

PART II - CONTRACT CLAUSESPART I - THE SCHEDULE

H

G

F

E

D

C

B

A

SEC. DESCRIPTION PAGE(S) (X) DESCRIPTION SEC. (X)

10. TABLE OF CONTENTS

17. OFFER DATE16. SIGNATURE

SUCH ADDRESS IN SCHEDULE.

IS DIFFERENT FROM ABOVE - ENTER

14C. CHECK IF REMITTANCE ADDRESS

EXT.NUMBERAREA CODE

14B. TELEPHONE NUMBER

(Type or print)AND

ADDRESS

OF

OFFEROR

CODE FACILITY

15. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER14A. NAME

DATEAMENDMENT NO.DATEAMENDMENT NO.

and related documents numbered and dated):

amendments to the SOLICITATION for offerors

(The offeror acknowledges receipt of

13. ACKNOWLEDGEMENT OF AMENDMENTS

CALENDAR DAYS (%)30 CALENDAR DAYS (%)20 CALENDAR DAYS (%)10 CALENDAR DAYS (%)12. DISCOUNT FOR PROMPT PAYMENT the designated point(s), within the time specified in the schedule.

by the offeror) from the date for receipt of offers specified above , to furnish any or all items upon which prices are offered at the price set opposite each item , delivered at

11. In compliance with the above, the undersigned agrees, if this offer is accepted within ___120___________ calendar days (60 calendar days unless a different period is inserted

NOTE: Item 11 does not apply if the solicitation includes Minimum Bid Acceptance Period .

OFFER (Must be fully completed by offeror)

IMPORTANT - Award will be made on this Form, or by other authorized official written notice.

27. AWARD DATE

(Signature of Contracting Officer)

26. CONTRACT AUTHORITY

24. PAYMENT WILL BE MADE BY

25. NAME OF CONTRACTING OFFICER (Type or print)

CODE 23. ADMINISTERED BY (If other than Item 6)

ITEM

(4 copies unless otherwise specified)

22. SUBMIT INVOICES TO ADDRESS SHOWN IN21. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

20. ACCOUNTING AND APPROPRIATION19. AMOUNT18. ACCEPTED AS TO ITEMS NUMBERED

AWARD (To be completed by CONTRACT AUTHORITY)

CODE

10/06/2025 X

AAQ730-AFN

AAQ-730 FAC. & AVIATION SAFETY ACQ

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY OK 73125

Neil S. Amaral 405 Neil.S.Amaral@faa.gov

954-8381

X

X

X

X

X

X

X

X

X

X

X

X

PAGE(S)

Neil S. Amaral

6973GH-26-R-00002

X neil.s.amaral@faa.gov Proposal Due Date (unless amended): 11/06/2025 by 3 P.M. CT

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 70

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

6973GH-26-R-00002

Technical, Management, and Administrative Support

Services

Set-Aside for Certified 8(a) Small Businesses

Period of Performance: 01/14/2026 to 01/13/2031

00001 AAM-600 Technical, Management, and Administrative

Support Services IAW the Statement of Work (SOW) dated August 8, 2025 and the Section B Excel

Attachment dated August 5, 2025.

Time & Materials

Five-Year Ordering Period

Electronic & IT: 03

The remainder of this page has been intentionally left blank.

Section B - Supplies or Services/Prices Section B - Schedule

Clause List

Section C - Description/Specifications Scope of Work

Clause List

AC4548 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

(JUL 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel not being subject to the direction and control of Government personnel when performing non-personal contract services in FAA facilities.

(b) All contractor personnel at a FAA work site or facility during an actual emergency shall conform to the procedures posted or directed by FAA officials responsible for emergency response at that site or facility. Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, etc.

(c) Contractor personnel shall participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions and based on advance arrangements that are then announced at the time of an exercise, contractor personnel will be excused from evacuations.

(d) Contractor management/supervisors shall ensure that each contractor employee assigned work in FAA facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Information on emergency procedures may be requested from the Contracting Officer’s Representative (COR) or a designated FAA contact point at the work site.

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.10.4-5 INSPECTION - TIME-AND-MATERIAL AND LABOR-HOUR (APR 1996)

AC1908 INSPECTION AND ACCEPTANCE AT DESTINATION (JUN 2015)

(a) Final inspection and acceptance shall be at destination.

(b) Although source inspection by the Government is not anticipated under this contract, the provisions of this clause shall in no way be construed to limit the rights of the Government under the clause entitled /associated with inspection and/or acceptance.

Section F - Deliveries or Performance Clause List

3.10.1-9 STOP-WORK ORDER (APR 2025)

3.8.2-22 SUBSTITUTION OR ADDITION OF PERSONNEL (OCT 2006)

(1) The Contractor must assign only those individuals whose resumes, personnel data, or personnel qualification statements have been submitted and determined by the Contracting Officer to meet the minimum requirements of the contract. The Contractor must not substitute or add personnel except in accordance with this clause.

(2) Substitution of Personnel.

(a) For the first 120 days of contract performance, the Contractor must not substitute personnel for the individuals whose resumes or other personal qualification were submitted with its offer and that were determined by the Contracting Officer to be acceptable at the time of contract award, unless such substitutions are because of an individual's sudden illness, death, or termination of employment. In any of these events, the Contractor must promptly notify the Contracting Officer and propose substitute personnel as required by paragraph (4) below.

(b) If an individual becomes, for whatever reason, unavailable for work under the contract for a continuous period exceeding thirty (30) working days, or is expected to devote substantially less effort to the planned work, the Contractor must propose a substitute personnel as required by paragraph (4) below.

(3) Addition of Personnel. If an FAA requirement will increase the specified level of effort for a designated labor category, but not the overall level of effort of the contract, then the Contractor must notify the Contracting Officer to add personnel to the designated labor category. The Contractor must request added personnel as required by paragraph (4) below.

(4) Request and Review. The Contractor must submit the request for substitute or added personnel in writing to the Contracting Officer at least 30 days (if a security clearance must be obtained, at least 180 days) before the proposed date of substitution or addition. The Contractor's request must provide a detailed explanation of the circumstances causing the proposed substitution or addition, a complete resume for the proposed substitute or added personnel, and any additional information required by the Contracting Officer. Proposed substitutes and added personnel must have qualifications equal to or higher than those stated in the contract for the labor category. The Contracting Officer will evaluate the Contractor's request and promptly notify the Contractor of the decision to accept or reject the qualifications of the substitute or added personnel.

(5) The Contracting Officer may terminate the contract if the Contractor has not made suitable, timely, and reasonably forthcoming replacement of personnel who have been reassigned or terminated or otherwise become unavailable to work under the contract or the resulting loss of productive effort would impair the successful completion of the contract. Alternatively, if the Contracting Officer finds the Contractor to be at fault for the condition, then the Contracting Officer may equitably adjust (downward) the contract price or fixed fee to compensate the Government for any delay, loss or damage as a result of the Contractor's action.

(End of clause)

AC0168 AUTHORIZED PERFORMANCE (JUL 2015)

The execution of a contract shall not constitute authority for the contractor to commence performance. Performance shall be ordered by the issuance of a formal delivery order by an authorized Contracting Officer of the Mike Monroney Aeronautical Center. Orders issued orally or by written telecommunications shall reference a formal delivery order number and shall be confirmed by issuance of the formal delivery order.

Section G - Contract Administration Data Clause List

AC0116 OPTION TO EXTEND SERVICES (JUN 2015)

The Government may unilaterally exercise its option to extend the term of the contract for performance of specified services pursuant to Section I, AMS Clause 3.2.4-34, Option to Extend Services , by written notice to the contractor not later than the expiration date of the current contract period.

AC2604 INCREMENTAL FUNDING (JAN 1997)

(a) The Government reserves the right to incrementally fund this contract on a periodic basis to promote efficiency in the utilization of fiscal allotments through the routine budget process or the use of interim funding measures such as under congressional ""continuing resolution"" procedures.

(b) Delivery orders will be periodically issued to provide a not-to-exceed amount of funds. Such amount will be sufficient to cover contract performance for the period specified in the order, plus an estimated cost for terminating the contract should additional funds not be available to continue performance under the contract.

(c) This clause becomes inoperative when the contract period is fully funded.

AC4546 WAIVER OF WITHHOLDING (JUL 2015)

Funds shall not be withheld from contract payments as described in subparagraph (a)(2) of AMS clause 3.3.1-5 'Payments Under Time-and-Material and Labor-Hour Contracts.'

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.13-15 CONFIDENTIALITY OF DATA AND INFORMATION (NOV 2016)

(a) In performance of this contract, the contractor and any of its subcontractors, may need access to and use various data and information in the possession of the Government.This data and information may have been obtained under conditions which restrict the Government's right to use and disclose this data and information or which may be adverse to the interests of the Government or other parties if it is disseminated or used in a capacity other than in performance of this contract. Therefore, the contractor and its subcontractors agree to abide by any restrictive use conditions on such data and not to: (1) knowingly disclose such data and information to others without written authorization from the Contracting Officer, unless it is already publically available; or (2) use for any purpose other than the performance of this contract any data or information which bears a restrictive marking or legend which the contractor has gained access to through the performance of this contract, or information that should be marked according to FAA Order 1600.75 "Protecting Sensitive Unclassified Information (SUI)". For the sole purpose of this clause, "information" means any communication or representation of knowledge such as facts, data, or opinions in any medium or form, including textual, numerical, graphic, cartographic, narrative or visual form.

(b) In the event the work required to be performed under this contract requires access to proprietary data and information of other companies, the contractor must obtain agreement from such other companies for such use unless such data are provided or made available to the contractor by the Government. Two copies of such company-to-company agreements must be furnished promptly to the Contracting Officer for information only. These agreements must prescribe the scope of authorized use and disclosure of the proprietary data and information as well as any other terms and conditions to be agreed upon between the parties thereto. It is agreed by the contractor that any such data or information, whether obtained by the contractor pursuant to the aforesaid agreement or from the Government, must be protected from unauthorized use by or unauthorized disclosure to any individual, corporation, or organization so long as it remains proprietary.

(c) The contractor agrees to conduct formal training to make employees aware of the requirement to maintain confidentiality of data and information as required above. The contractor must obtain from each employee in connection with this contract a signed Non-Disclosure Agreement. This agreement must provide that the employee will not, during employment or anytime thereafter, disclose or use for current or future benefit of any party any of the data (to include any form of Sensitive Unclassified Information (SUI) described in FAA Order 1600.75) or information not publically available received in connection with the work under the contract.

(d) The contractor agrees to hold the Government harmless and indemnify the Government as to any cost/loss resulting from the unauthorized use or disclosure of third party data or software by the contractor, its employees, subcontractors, or agents.

(e) The contractor agrees to include the substance of this clause in all subcontracts awarded under this contract. The Contracting Officer will consider case-by-case exceptions to this requirement for individual subcontracts in the event that: (1) the contractor considers this clause to be inappropriate and unnecessary in the case of a particular subcontract; (2) the contractor provides a written statement affirming absolute unwillingness of a subcontractor to perform, absent some relief from the substance of this prohibition and the reason why; (3) use of an alternate subcontract source would unreasonably detract from the quality of effort; and (4) the contractor provides the Contracting Officer timely written advance notice of these and any other extenuating circumstances.

(f) Except as the Contracting Officer specifically authorizes in writing, upon completion of all work under this contract, the contractor must return all such data and information described above obtained from the Government, including all copies, modifications, adaptations, or combinations thereof, to the Contracting Officer. Data obtained from another company must be disposed of in accordance with the contractor's agreement with that company, or if the agreement makes no provision for disposition, must be returned to that company. The contractor must further certify in writing to the CO that all copies, modifications, adaptations, or combinations of such data or information which cannot reasonably be returned to the Contracting Officer (or to the appropriate company), have been deleted from the contractor's (and any subcontractor's) records and destroyed. The FAA reserves the right to audit the deletion. The FAA must provide notice of the audit 10 calendar days prior to the audit.

(g) These restrictions do not limit the contractor's (or subcontractor's) right to use and disclose any data and information obtained from another source without restriction.

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.1.7-5 DISCLOSURE OF CONFLICTS OF INTEREST (JUL 2018)

3.1.8-1 CANCELLATION, RESCISSION AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (APR 2024)

3.1.8-2 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (APR 2024)

3.2.2.3-33 ORDER OF PRECEDENCE (APR 2024)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.4-34 OPTION TO EXTEND SERVICES (OCT 2019)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2024)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.2.5-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (OCT 2024)

3.2.5-14 DISPLAY OF HOTLINE POSTER(S) (OCT 2024)

3.3.1-1 PAYMENTS (JUL 2018)

3.3.1-5 PAYMENTS UNDER TIME-AND-MATERIALS AND LABOR-HOUR CONTRACTS (OCT

2024)

3.3.1-8 EXTRAS (OCT 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-10 AVAILABILITY OF FUNDS (OCT 2024)

3.3.1-16 PROHIBITION OF ASSIGNMENT OF CLAIMS (OCT 2024)

3.3.1-17 PROMPT PAYMENT (OCT 2024)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (OCT 2024)

3.3.1-39 INCREMENTAL FUNDING - TIME-AND-MATERIALS AND LABOR-HOUR

CONTRACTS (OCT 2024)

3.3.2-1 FAA COST PRINCIPLES (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.1-12 INSURANCE (OCT 2019)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2021)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JUL 2023)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME

COMPENSATION (OCT 2018)

3.6.2-2 CONVICT LABOR (APR 2025)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 2025)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2024)

3.6.2-46 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (APR 2025)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-14 CHANGES - TIME AND MATERIALS OR LABOR HOURS (APR 2022)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.2-3 SUBCONTRACTS (TIME-AND-MATERIALS AND LABOR-HOUR CONTRACTS) (JUL

2023)

3.13-10 CONTRACTOR ATTENDANCE AT FAA SPONSORED TRAINING (JAN 2003)

3.14-5 SENSITIVE UNCLASSIFIED INFORMATION (SUI) (JAN 2022)

3.14-10 PRIVACY ACT NOTIFICATION (OCT 2018)

3.14-11 PRIVACY ACT (OCT 2018)

3.1.7-6 DISCLOSURE OF CERTAIN EMPLOYEE RELATIONSHIPS (APR 2023)

(a) The policy of the FAA is to avoid doing business with contractors, subcontractors, and consultants who have a conflict of interest or an appearance of a conflict of interest. The purpose of this policy is to maintain the highest level of integrity within its workforce and to ensure that the award of procurement contracts is based upon fairness and merit.

(b) The contractor must provide to the Contracting Officer the following information with its proposal and must provide an information update within 30 days of the award of a contract, any subcontract, or any consultant agreement, or within 30 days of the retention of a Subject Individual or former FAA employee subject to this clause:

(1) The names of all Subject Individuals who:

(i) participated in preparation of proposals for award; or

(ii) are planned to be used during performance; or

(iii) are used during performance; and

(2) The name of each individual, retained in any capacity by the contractor, who was employed by FAA during the five-year period immediately prior to the date of award; and

(3) The date on which the initial expression of interest in a future financial arrangement was discussed with the contractor by any former FAA employee whose name is required to be provided by the contractor pursuant to subparagraph (2); and

(4) The location where any Subject Individual or former FAA employee whose name is required to be provided by the contractor pursuant to subparagraphs (1) and (2), are expected to be assigned.

(c) "Subject Individual" means a current FAA employee's father, mother, son, daughter, brother, sister, uncle, aunt, first cousin, nephew, niece, husband, wife, father-in-law, mother-in-law, son-in-law, daughter-in-law, brother-in-law, sister-in-law, stepfather, stepmother, stepson, stepdaughter, stepbrother, stepsister, half brother, half sister, spouse of an in-law, or a member of his/her household.

(d) The contractor must incorporate this clause into all subcontracts or consultant agreements awarded under this contract and must further require that each such subcontractor or consultant incorporate this clause into all subcontracts or consultant agreements at any tier awarded under this contract unless the Contracting Officer determines otherwise.

(e) The information as it is submitted, must be certified as being true and correct. If there is no such information, the certification must so state.

(f) Remedies for nondisclosure: The following are possible remedies available to the FAA should a contractor misrepresent or refuse to disclose or misrepresent any information required by this clause:

(1) Termination of the contract.

(2) Exclusion from subsequent FAA contracts.

(3) Other remedial action as may be permitted or provided by law or regulation or policy or by the terms of the contract.

(g) Annual Certification. The contractor must provide annually, based on the anniversary date of contract award, the following certification in writing to the Contracting Officer:

ANNUAL CERTIFICATION OF DISCLOSURE OF CERTAIN EMPLOYEE RELATIONSHIPS

The contractor represents and certifies that to the best of its knowledge and belief that during the prior 12 month period:

[ ] A former FAA employee(s) or Subject Individual(s) has been retained to work under the contract or subcontract or consultant agreement and complete disclosure has been made in accordance with subparagraph (b) of AMS Clause 3.1.7-6.

[ ] No former FAA employee(s) or Subject Individual(s) has been retained to work under the contract or subcontract or consultant agreement, and disclosure required by AMS Clause 3.1.7-6 is not applicable.

Authorized Representative

Company Name

Date

(h) The contractor agrees to include the substance of this clause in all subcontracts awarded under this contract. The Contracting Officer will consider case-by-case exceptions to this requirement for individual subcontracts in the event that: (1) the contractor considers this clause to be inappropriate and unnecessary in the case of a particular subcontract; (2) the contractor provides a written statement affirming absolute unwillingness of a subcontractor to perform, absent some relief from the substance of this prohibition and the reason why; (3) use of an alternate subcontract source would unreasonably detract from the quality of effort; and (4) the contractor provides the Contracting Officer timely written advance notice of these and any other extenuating circumstances.

(End of clause)

3.2.4-5 ALLOWABLE COST AND PAYMENT (OCT 2019)

(a) Invoicing. The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with the Federal Aviation Administration's (FAA) "Contract Cost

Principles" in effect on the date of this contract and the terms of this contract (upon request, the Contracting Officer will provide a copy of the FAA Contract Cost Principles). The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract. Any payments for costs under this contract, particularly for costs of Indirect Rates under paragraph (d), must be subject to the provisions of the "Limitation of Costs" clause, or the "Limitation of Funds" clause, if applicable. The Contractor must be responsible to manage and control the allowable cost of performance of the contract, such that payments for any allowable costs, including Indirect Rates under paragraph (d), must not exceed the estimated cost set forth in the schedule, or the funded amount, less an allowance for fee, if the contract is incrementally funded.

(b) Reimbursing costs.

(1) For the purpose of reimbursing allowable costs (except as provided in subparagraph (2) below, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term costs includes only:

(i) Those costs the Contractor has incurred and recorded at the time of the request for reimbursement;

(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid for-

(A) Materials issued from the Contractor's inventory and placed in the production process for use on the contract;

(B) Direct labor;

(C) Direct travel;

(D) Other direct in-house costs; and

(E) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under FAA contracts; and

(iii) The amount of payments that have been paid to the Contractor's subcontractors under similar cost standards.

(2) Contractor contributions to any pension or other post-retirement benefit, profit-sharing or employee stock ownership plan funds that are paid quarterly or more often may be included in indirect costs for payment purposes: Provided, that the Contractor pays the contribution to the fund within 30 days after the close of the period covered. Payments made 31 days or more after the close of a period must not be included until the Contractor actually makes the payment. Accrued costs for such contributions that are paid less often than quarterly must be excluded from indirect costs for payment purposes until the Contractor actually makes the payment.

(3) Notwithstanding the audit and adjustment of invoices or vouchers under paragraph (g) below, allowable indirect costs under this contract must be obtained by applying indirect cost rates established in accordance with paragraph (d) below.

(4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of materials at the Contractor's expense or at no cost to the Government will be disregarded for purposes of cost-reimbursement under this clause.

(c) Small business concerns. A small business concern may be paid more often than every 2 weeks and may invoice and be paid for recorded costs for items or services purchased directly for the contract, even though the concern has not yet paid for those items or services.

(d) Final indirect cost rates.

(1) Final annual indirect cost rates and the appropriate bases must be established for the period covered by the indirect cost rate proposal.

(2) The Contractor must, within 180 days after the expiration of each of its fiscal years, or by a later date approved by the Contracting Officer, submit to the cognizant Contracting Officer and to the cognizant audit activity proposed certified final indirect cost rates for that period and supporting cost data specifying the contract and/or subcontract to which the rates apply. The proposed rates must be based on the Contractor's actual cost experience for that period. The appropriate Government representative and Contractor will establish the final indirect cost rates as promptly as practical after receipt of the Contractor's proposal.

(i) An adequate indirect cost rate proposal must include the following data unless otherwise specified by the cognizant Contracting Officer:

(A) Summary of all claimed indirect expense rates, including pool, base, and calculated indirect rate.

(B) General and Administrative expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts).

(C) Overhead expenses (final indirect cost pool). Schedule claimed expenses by element of cost as identified in accounting records (Chart of Accounts) for each final indirect cost pool.

(D) Occupancy expenses (intermediate indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Charts of Accounts) and expense reallocation to final indirect cost pools.

(E) Claimed allocation bases, by element of cost, used to distribute indirect costs.

(F) Facilities capital cost of money factors computation.

(G) Reconciliation of books of account (i.e., General Ledger) and claimed direct costs by major cost elements.

(H) Schedule of direct costs by contract and subcontract and indirect expense applied at claimed rates, as well as a subsidiary schedule of Government participation percentages in each of the allocation base amounts.

(I) Schedule of cumulative direct and indirect costs claimed and billed by contract and subcontract.

(J) Subcontract information. Listing of subcontracts awarded to companies for which the contractor is the prime or upper-tier contractor (include prime and subcontract numbers;

subcontract value and award type; amount claimed during the fiscal year; and the subcontractor name, address, and point of contract information).

(K) Summary of each time-and-materials and labor-hour contract information, including labor categories, labor rates, hours, and amounts; direct materials; other direct costs; and, indirect expense applied at claimed rates.

(L) Reconciliation of total payroll per IRS form 941 to total labor costs distribution.

(M) Listing of decisions/agreements/approvals and description of accounting/organizational changes.

(N) Certificate of final indirect…