S06 - Updated Bid Schedule_36C25225B0015 Amend 0002.pdf
PDF 158 KB Posted
- Solicitation number
- 36C25225B0015
About this file
This is a Bid Schedule for VA Project Number 556-24-107 to replace cooling tower fans at the Captain James A. Lovell Federal Health Care Center in North Chicago, IL. The project has a price range of $1,000,000 to $2,000,000 and requires the contractor to provide all labor, materials, equipment, and supervision to complete the work within 197 calendar days after receiving the Notice to Proceed. The solicitation (Number 36C25225B0015) is set for a single award to the lowest responsive bidder, with the requirement that the contractor submit an approved cost-loaded Critical Path Method (CPM) construction schedule before commencing work. The project is being managed by the Department of Veterans Affairs Veterans Health Administration, and is specifically targeted for Service-Disabled Veteran-Owned Small Businesses (SDVOSB).
View the file
Other files
Show all 30
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
ACCOMPANYING SOLICITATION 36C25225B0015 AMENDMENT 0002
BID SCHEDULE
VA Project Number: 556-24-107 Replace Cooling Tower Fans
Price Range: $1,000,000 to $2,000,000.
Base Bid
Contractor shall provide for and furnish all labor, materials, equipment, qualified supervision, and other items designated in this contract in accordance with the specifications and drawings to complete Project # 556-24-107: Replace Cooling Tower Fans at the Captain James A. Lovell Federal Health Care Center, 3001 Green Bay Rd, North Chicago, IL 60064
All work shall be completed within 197 calendar days after receiving Notice to Proceed.
Base Bid LUMP SUM: _______________________________
NOTICE TO BIDDERS: Award will be made to the responsible bidder who submitted the lowest responsive bid. Work shall not commence until all required submittals are approved by the Contracting Officer or the Contracting Officer’s Representative (COR). An approved cost-loaded, Critical Path Method (CPM) construction schedule is required prior to commencement of construction. See specifications for details. CPM schedule shall be approved by the Contracting Officer or the Contracting Officer’s Representative. See specifications for details.
NOTICE TO BIDDERS: Additional information regarding the general and specific scope of work is defined in the specifications and drawings. This BID SCHEDULE is in addition to and augments the specifications and drawings. ONLY ONE AWARD WILL BE MADE AS A RESULT OF
THIS SOLICITATION.
File details come from the government source that posted it. Updated .