Atch 2 Specifications 626-24-204 Final R1.pdf

Project Table of Contents

Division Section Title Division 01 - General Requirements

010000 General Requirements 013216 Project Schedules 013323 Shop Drawings, Product Data, and Samples 013526 Safety

014219 Reference Standards 014500 Quality Control 017419 Construction Waste Management 018113 Sustainable Construction Requirements 019100 General Commissioning Requirements

Division 02 – Existing Conditions 022100 Site Survey 024100 Demolition 028211 Traditional Asbestos Abatement

Division 03 – Concrete 033000 Cast in Place Concrete 033053 Cast in Place Concrete (short form)

Division 05 – Metals 055000 Metal Fabrications

Division 07 – Thermal and Moisture Protection 07600 Flashing and Sheetmetal 078400 Fire Stopping 079200 Joint Sealants

Division 09 - Finishes 099100 Painting

Division 13 – Special Construction 130541 Seismic Restraint Requirements for Non-Structural

Components

Division 22 - Plumbing 220511 Common Work Results for Plumbing 220512 General Motor Requirements for Plumbing Equipment

220519 METERS AND GAUGES FOR PLUMBING PIPING

220523 General Duty Valves for Plumbing Piping

221300 FACILITY SANITARY AND VENT PIPING

221433 Packaged Pedestal Drainage Pump Units 224000 Plumbing Fixtures

Division 23 – Heating, Ventilation, and Air conditioning 230510 Common work results for Boiler and Steam Generation 230511 Common Work Results for HVAC

230512 General Motor Requirements for HVAC and Steam Gen Eqip.

230541 Noise and Vibration Control for HVAC Piping and Equipment 230593 Testing, Adjusting, and Balancing for HVAC

230711 HVAC and Boiler Plan Insulation

230800 Commissioning of HVAC System 230911 Instrumentation and Control for Boiler Plant

232111 Boiler Plant Piping System

232213 Steam and Condensate Heating Piping

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 Upgrade Steam System Components

232223 Steam Condensate Pumps

232500 HVAC Water Treatment 233100 HVAC Ducts and Castings

233700 AIR outlets and Inlets

Division 26 - Electrical 260511 Requirement for Electrical Installations 260521 Low-Voltage Electrical Power Conductors and Cables

260526 Grounding and Bonding for Electrical Systems 260533 Raceways and Boxes for Electrical Systems 260573 Overcurrent Protection Device Coordination Study 262300 Low-voltage Bussed Junction Box

262419 Motor Control Centers

262911 Motor Controllers 264100 Facility Lightening Protection

Division 27 - Communications 270533 Raceways and Boxes for Communications Systems

Division 28 - Electronic Safety and Security 280500 Common Work Results for Electronic Safety and Security

Division 31 - Earthwork 312011 Earthwork

Division 33 – Steam 336300 Steam Energy Distribution

- - - E N D - - -

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work to complete the subject project, including demolition and associated trades work as required by the request, Drawings and Specifications.

B. Visits to the site by Bidders shall be made only by appointment with t h e

Contracting Officer and/or Contracting Officer’s Representative.

C. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection. Such prior notice shall be not less than three workdays unless otherwise designated by the COR.

D. All employees of general Contractor and sub-Contractors shall comply with

VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

Each contractor that shall work on this VA project shall need to submit information for a possible background check and be issued a VA contractor badge.

E. Prior to commencing work, General Contractor shall provide proof that.

an OSHA certified “competent person” (CP) (29 CFR 1926.20(b) (2) shall maintain a presence at the Work site whenever the general or sub-Contractors are present.

F. Training:

1. All employees of general Contractor or sub-Contractors shall have the

10-hour OSHA certified Construction Safety course and/or other relevant competency training, as determined by VA CP with input from the ICRA team.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

2. Submit training records of all such employees for approval before the start of work.

G. Submit Long Lead Item submittals at Notice to Proceed to order long lead items.

H. Manifestly Necessary Requirement: Omissions from the Drawings or Specifications or the mis-description of details of work which are manifestly necessary to carry the intent of the Drawings and Specifications, or which are customarily performed, shall not relieve the Contractor from performing such omitted or mis-described details of the work, but shall be performed as if fully and correctly set forth and described in the Drawings and

Specifications.

1.3 STATEMENT OF BID ITEM(S)

A. BID ITEM NO. I: GENERAL CONSTRUCTION: Work includes selective demolition, general construction, alterations, necessary removal of existing structures and construction and certain other items. The contractor shall provide all tools, labor, material, equipment, and supervision necessary to perform all work as required by the contract bid documents including:

1. Architectural Modifications,

2. Fire Protection Systems,

3. Plumbing Systems,

4. Mechanical systems,

5. Electrical Systems

6. Telecommunication Systems

7. Fire Alarm

8. Equipment, Fixtures, and Finishes

B. BID ITEM NO. 2: Same as Bid Item No. 1 except [Insert description].

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. The Contractor shall reproduce Specifications and Drawings provided on www.fbo.gov. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that shall remain effective for the entire duration of the project.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 Upgrade Steam System Components http://www.fbo.gov/

2. The General Contractor is responsible for assuring that all sub-

Contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They shall also be subject to inspection of their personal effects when entering or leaving the project site.

2. For working outside the “regular hours” as defined in the contract, The

General Contractor shall give 3 days’ notice to the COR so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without permission of the COR.

4. VA reserves the right to close or shut down the project site and order

General Contractor’s employees off the premises in the event of a national emergency. The General Contractor shall return to the site only with the written approval of the Contracting Officer.

5. During the COVID pandemic, precautions will remain in place until directed otherwise by the medical center Director. All project employees and on-site personnel, including but not limited to owners, management, superintendent, workmen, subcontractors, vendors, testing agencies, deliveries, and other individuals onsite in the performance of the contract shall be screened daily at one of the identified screening locations at entry points. Contractors are not permitted to self-screen or clear themselves for entry/work within the building.

6. Contractors, subcontractors, and staff found to be in violation with

TVHS policies can have their onsite privileges revoked and be removed from the job at the discretion of the COR or VA Police.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the COR for the purpose of security inspections of every area of project including toolboxes and parked machines and take any emergency action.

2. The General Contractor shall install all permanent lock cylinders within the project and provide necessary documentation to the VA locksmith. See

Section 08 71 00, DOOR HARDWARE, and coordinate.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

3. The General Contractor will be assigned 1 set of Facility Keys for access to Mechanical Rooms, Fan Rooms, Sub-basements, etc. as necessary.

The Superintendent for the project is responsible for requesting keys from the COR in writing or through email with specific rooms required for entry for the project. Once the request is made, the Superintendent and COR will sign out keys through the VA Locksmith, quantity of keys is contingent on the size of the project and will be determined based on complexity of scope.

4. Contractor keys will be collected at the end of the project. Keys not returned/Lost keys will result in a $500 fine.

D. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all Drawings, Project Manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and Drawings shall be marked “Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who shall need it for the project. Return the information to the Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information.”

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project Drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including Drawings and other documents shall

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 be attached to email provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted in writing or email no more than 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of permits (2 to 3) shall be issued for General

Contractor and its employees for parking in designated areas only in the

VA garage, 6th floor. Permits are purchased through Travel Pay/Agent

Cashier Office, cost no more than $50 per permit, and last for 2-month cycles before renewal is required.

3. Contractor will not have a staging area or dumpster for this project.

Any contractor questions/concerns regarding the Conex location shall be addressed through the RFI process prior to proposal. Contractor can actively drop-off/ pickup personnel and materials but cannot park illegally when doing so and shall not leave a vehicle unattended.

Contractor actively working out of a vehicle (on-board welder, pressure washer, waste catch) shall have to coordinate these provisions/allowances in advance with its Contracting Officer Representative (COR) in writing or email. During demolition, Contractor shall remove waste from the Campus at the end of the shift.

4. Contractor discovered to be parking illegally shall be reported to VA Police and shall be ticketed and/or asked to leave the property.

1.6 FIRE SAFETY

A. Applicable Publications: Publications listed below form part of this

Article to extent referenced. Publications are referenced in text by basic designations only.

1. American Society for Testing and Materials (ASTM):

E84-2008.............Surface Burning Characteristics of Building

Materials

2. National Fire Protection Association (NFPA):

10-2006..............Standard for Portable Fire Extinguishers

30-2007..............Flammable and Combustible Liquids Code

51B-2003.............Standard for Fire Prevention During Welding, Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

Cutting and Other Hot Work

70-2011..............National Electrical Code

241-2004.............Standard for Safeguarding Construction, Alteration, and Demolition Operations

3. Occupational Safety and Health Administration (OSHA):

29 CFR 1926..........Safety and Health Regulations for Construction

B. Fire Safety Plan: Establish and maintain a fire protection program in accordance with 29 CFR 1926. Prior to start of work, prepare a plan detailing project-specific fire safety measures, including periodic status reports, and submit to COR and Facility Safety Officer for review for compliance with contract requirements in accordance with Section 01 33 23, SHOP

DRAWINGS, PRODUCT DATA AND SAMPLES Prior to any worker for the Contractor’s or subcontractors’ beginning work, they shall undergo a safety briefing provided by the general Contractor’s competent person per OSHA requirements.

This briefing shall include information on the construction limits, VAMC safety guidelines, means of egress, break areas, work hours, locations of restrooms, use of VAMC equipment. Documentation shall be provided to the

COR that individuals have undergone Contractor’s safety briefing.

C. Site and Building Access: Maintain free and unobstructed access to facility emergency services and for fire, police, and other emergency response forces in accordance with NFPA 241.

E. Temporary Construction Partitions:

1. Provide and maintain temporary construction partitions to provide smoke-tight separations between construction areas and adjoining areas.

Construct partitions of gypsum board or treated plywood (flame spread rating of 25 or less in accordance with ASTM E84) on both sides of fire-retardant treated wood or metal steel studs. Extend the partitions through suspended ceilings to floor slab deck or roof. Seal joints and penetrations. At door openings, provide Class C, ¾ hour fire/smoke rated doors with self-closing devices.

2. Provide one-hour fire-rated temporary construction partitions as shown on Drawings to maintain integrity of existing exit stair enclosures, exit passageways, fire-rated enclosures of hazardous areas, horizontal exits, smoke barriers, vertical shafts, and openings enclosures.

3. Close openings in smoke barriers and fire-rated construction to

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 maintain fire ratings. Seal penetrations with listed through-penetration firestop materials in accordance with Section 07 84 00, FIRESTOPPING.

F. Temporary Heating and Electrical: Provide, use and maintain installations in accordance with 29 CFR 1926, NFPA 241 and NFPA 70.

G. Means of Egress: Do not block exiting for occupied buildings, including paths from exits to roads. Minimize disruptions and coordinate with COR and

Facility Safety Manager.

H. Egress Routes for Construction Workers: Maintain free and unobstructed egress. Inspect daily. Report findings and corrective actions weekly to COR and Facility Safety Manager.

I. Fire Extinguishers: Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with 29 CFR 1926, NFPA

241 and NFPA 10.

J. Flammable and Combustible Liquids: Store, dispense and use liquids in accordance with 29 CFR 1926, NFPA 241 and NFPA 30.

K. Sprinklers: Provide, test, and activate new automatic sprinklers prior to removing existing sprinklers.

L. Existing Fire Protection: Do not impair automatic sprinklers, smoke and heat detection, and fire alarm systems, except for portions immediately under construction, and temporarily for connections. Provide fire watch for impairments more than 4 hours in a 24-hour period. Request interruptions in accordance with Article, OPERATIONS AND STORAGE AREAS, and coordinate with

COR and Facility Safety Manager. All existing or temporary fire protection systems (fire alarms, sprinklers) located in construction areas shall be tested as coordinated with the medical center. Parameters for the testing and results of any tests performed shall be recorded by the medical center and copies provided.

to the COR.

M. Smoke Detectors: Prevent accidental operation. Remove temporary covers at end of work operations each day. Coordinate with COR and Facility Safety

Manager.

N. Hot Work: Perform and safeguard hot work operations in accordance with NFPA.

241 and NFPA 51B. Coordinate with COR. Obtain permits from facility Safety

Manager at least 72 hours in advance.

Designate Contractor's responsible project-site fire prevention program

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 manager to permit hot work.

O. Fire Hazard Prevention and Safety Inspections: Inspect entire construction areas weekly. Coordinate with, and report findings and corrective actions weekly to COR and facility Safety Manager.

P. This is a smoke free campus. The contractor, their employees and affiliates shall not smoke in any building, on the grounds or in a vehicle located on

VA property. Contractor shall ensure employees do not smoke on VA property.

Q. Dispose of waste and debris in accordance with NFPA 241. Remove from buildings daily.

R. Perform other construction, alterations, and demolition operations in accordance with 29 CFR 1926.

S. If required, submit documentation to the COR that Personnel have been trained in the fire safety aspects of working in areas with impaired structural or compartmentalization features.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

PERMIT

FOR CUTTING AND WELDING WITH PORTABLE GAS OR ARC EQUIPMENT VA

Project No.:

Name of Contractor’s Firm:

Date:

Building/Location:

Work to be done:

Any special precautions:

Fire Watch Required: yes no.

The location where the Work is to be performed has been examined, necessary precautions have been taken, and permission is granted for this work.

Signed:

(Contractor or individual responsible for authorizing hot work)

Permit expires: (Date)

Time hot work started:

FINAL CHECK-UP

Time hot work completed.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

Work area and all adjacent areas to which sparks, and heat might have spread

(including floors above and below and on opposite sides of walls) were inspected 30 minutes after the Work was completed and were found fire safe.

Signed:

(Contractor’s Fire Watch)

ATTENTION

Before approving any cutting and welding permit, Contractor’s authorized representative or their appointee shall inspect the Work area and confirm that precautions have been taken to prevent fire in accordance with NFPA

Standard No. 51B.

PRECAUTIONS

Sprinklers are in service where installed.

Cutting and welding equipment in good repair.

Within 35 feet: Floors swept clean of combustible, no combustible material or flammable liquids, all wall and floor openings covered, and covers suspended beneath work to collect sparks.

When working on enclosed equipment and in confined space, equipment and area is free of flammable vapors.

Fire watch provided during and 30 minutes after operation (60 minutes for torch applied roofing operations).

Portable fire extinguisher with adequate rating available in the immediate vicinity.

Standpipe system in service where installed.

Protection of any sprinkler heads when hot work is in proximity.

Smoking prohibited in immediate vicinity.

Non-combustible shields provided when hot work is done near combustible walls, partitions, floors, roofs.

Prohibition of hot work on pipes contacting combustible walls.

Personnel trained in use of equipment including portable fire extinguishers and sounding a fire alarm.

Final check-up conducted after 30 minutes.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

1.7 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers, and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. No temporary buildings, such as (e.g., storage sheds, shops, offices) and utilities are allowed by the contract. Any temporary measures erected by the Contractor only with the approval of the Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. Any temporary measures shall remain the property and responsibility of the Contractor and shall be removed by the Contractor at its expense upon completion of the Work.

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the Work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Staging / Working space and space available for storing materials outside of the jobsite is extremely limited. Staging will not be located next to jobsite. There will not be a staging area for this project; however, contractor will be allowed to store materials in a Conex Container. Smoking shall not be permitted on Campus. Contractors shall ensure any stored material is protected from weather, conditioned, and stored in a

Conex Container.

E. Workmen are subject to rules of Medical Center applicable to their conduct.

F. Execute work to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by

COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of Veterans Affairs in quantities sufficient for not more than two workdays. Provide unobstructed access to Medical Center areas required.

to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment shall be permitted within the worksite subject to fire and safety requirements.

G. Utilities Services: always Maintain existing utility services for Medical Center. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, gases, sewer or air pipes, or conduits, wires, cables of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, sewers or electricity, or fire protection systems and communications systems shall be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment.

de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without the Medical Center Director’s prior knowledge and written approval.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 72 hours in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor shall be advised (in writing) of approval of request, or of which other date and/or time such interruption shall cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center shall occur at other than Contractor’s.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

Nashville,TN 37212 6/6/2024 normal working hours.

4. Major interruptions of any system shall be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service shall be interrupted on approval of COR. Such approval shall be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas, payment of such fee shall be the responsibility of the Government and not the Contractor.

H. To minimize interference of construction activities with flow of Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances shall be approved by the

Contracting Officer’s Representative.

I. Coordinate the Work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

J. Contractor shall perform work between 7:00 am – 6:00 pm Monday through

Friday and per phasing notes indicated on the contract drawings. No work shall be performed on federal VA holidays. To accomplish tasks and meet deadlines, permission to work (no extra cost allowed) at times other than those specified above shall be granted/denied at the COR discretion upon request, in writing. Work during off hours shall be required to minimize disruptions. Conduct work on floor below and floor above after hours and on weekends. Temperature dependent work shall be done during mild weather of the Spring or Fall. Provide Fire Watch personnel during Fire Protection or Fire Alarm outages. Heavy vibration work shall be after normal duty hours. Work outside of construction limits shall be done outside of normal duty hours or on the weekends.

K. Job sites, mechanical room, electrical closets shall be secured.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

They shall be keyed to government keying system. VA shall provide keys for prime Contractor to distribute to the Superintendent and lead

Foremen. Keys are a privilege that can be taken away.

L. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which shall be abandoned, and which are abandoned already shall be removed entirely. The lines shall not be capped in finished areas, but shall be removed to the limits of construction.

M. Phasing and Coordination: The Medical Center must maintain its operation

24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate coordination dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such coordination dates to ensure accomplishment of this work in successive phases mutually agreeable to Medical Center Director, COR, and Contractor.

1.8 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR of areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the Contracting Officer.

This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, Shades required by Drawings to be either reused or relocated, or both.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

3. Shall note any discrepancies between Drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur, and which have been agreed upon by Contractor and COR.

B. Any items required by Drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with Specifications which shall be furnished by Government.

Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4 and VAAR 852.236-88).

C. Resurvey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. The contractor shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls, and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and shall form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled, and equipment moved and/or relocated.

3. Protection of interior of existing structures always, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 maintained intact until all work in the area is completed.

1.9 INFECTION PREVENTION MEASURES

A. Implement the requirements of VAMC’s Infection Control Risk Assessment

(ICRA) team and Pre-Construction Risk Assessment (PCRA) Sheet. ICRA Group shall monitor dust in the vicinity of the construction work and require the Contractor to take corrective action immediately if the safe levels are exceeded.

B. Establish and maintain a dust control program as part of the

Contractor’s infection preventive measures in accordance with the guidelines provided by ICRA Group as specified here. Prior to start of work, prepare a plan detailing project-specific dust protection measures, including periodic status reports, and submit to COR and Facility ICRA team for review for compliance with contract requirements in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA AND SAMPLES.

1. All personnel involved in the construction or renovation activity shall be educated and trained in infection prevention measures established by the medical center.

C. Medical Center Infection Control personnel shall monitor for airborne disease (e.g. aspergillosis) as appropriate during construction. A baseline of conditions shall be established by the medical center prior to the start of work and periodically during the construction stage to determine impact of construction activities on indoor air quality. In addition:

1. The COR and VAMC Infection Control personnel shall review pressure differential monitoring documentation to verify that pressure differentials in the construction zone and in the patient-care rooms are appropriate for their settings. The requirement for negative air pressure in the construction zone shall depend on the location and type of activity. Upon notification, the Contractor shall implement corrective measures to restore proper pressure differentials as needed.

2. In case of any problem, the medical center, along with assistance from the Contractor, shall conduct an environmental assessment to find and eliminate the source.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

D. In general, following preventive measures shall be adopted during construction to keep down dust and prevent mold.

1. Dampen debris to keep down dust and provide temporary construction partitions in existing structures where directed by COR. Blank off ducts and diffusers to prevent circulation of dust into occupied areas during construction.

2. Do not perform dust producing tasks within occupied areas without the approval of the COR. For construction in any areas that shall remain jointly occupied by the medical Center and Contractor’s workers, the

Contractor shall:

a. Provide dust proof one-hour fire-rated temporary drywall construction barriers to completely separate construction from the operational areas of the hospital in order to contain dirt debris and dust. Barriers shall be sealed and made presentable on hospital occupied side. Provide a self-closing rated door in a metal frame, commensurate with the partition, to allow worker access.

Maintain negative air at all times. A fire retardant polystyrene, 6-mil thick or greater plastic barrier meeting local fire codes shall be used where dust control is the only hazard, and an agreement is reached with the COR and Medical Center.

b. HEPA filtration is required where the exhaust dust shall reenter the breathing zone. Contractor shall verify that construction exhaust to exterior is not reintroduced to the medical center through intake vents, or building openings. Provide HEPA (High

Efficiency Particulate Accumulator) filter vacuum system rated at

95% capture of 0.3 microns including pollen, mold spores and dust particles. Insure continuous negative air pressures occurring within the Work area. HEPA filters shall have ASHRAE 85 or other prefilter to extend the useful life of the HEPA. Provide both primary and secondary filtrations units. Exhaust hoses shall be heavy duty, flexible steel reinforced and exhausted so that dust is not reintroduced to the medical center.

c. Adhesive Walk-off/Carpet Walk-off Mats, minimum 600mm x 900mm

(24” x 36”), shall be used at all interior transitions from the construction area to occupied medical center area. These mats shall be changed as often as required to maintain clean work areas directly outside construction area at all times.

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

d. Vacuum and wet mop all transition areas from construction to the occupied medical center at the end of each workday. Vacuum shall utilize HEPA filtration. Maintain surrounding area frequently.

Remove debris as they are created. Transport these outside the construction area in containers with tightly fitting lids.

e. The Contractor shall not haul debris through patient-care areas without prior approval of the COR and the Medical

Center. When, approved, debris shall be hauled in enclosed dust proof containers or wrapped in plastic and sealed with duct tape.

No sharp objects shall be allowed to cut through the plastic. Wipe down the exterior of the containers with a damp rag to remove dust. All equipment, tools, material transported through occupied areas shall be made free from dust and moisture by vacuuming and wipe down.

f. Using a HEPA vacuum, clean inside the barrier and vacuum ceiling tile prior to replacement. Any ceiling access panels opened for investigation beyond sealed areas shall be sealed immediately when unattended.

g. There shall be no standing water during construction. This includes water in equipment drip pans and open containers within the construction areas. All accidental spills shall be cleaned up and dried within 12 hours. Remove and dispose of porous materials that remain damp for more than 72 hours.

h. At completion, remove construction barriers and ceiling protection carefully, outside of normal work hours. Vacuum and clean all surfaces free of dust after the removal.

E. Final Cleanup:

1. Upon completion of project, or as work progresses, remove all construction debris from above ceiling, vertical shafts and utility chases that have been part of the construction.

2. Perform cleaning of all surfaces in the construction area and removal of any dust (HEPA vacuum). This includes walls, ceilings, cabinets, furniture (built-in or free standing), partitions, flooring, etc.

3. All new air ducts shall be cleaned prior to final inspection.

1.10 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 follows:

1. Reserved items which are to remain property of the Government are noted on Drawings or in Specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by Contracting Officer’s Representative.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by Drawings and Specifications to be either relocated or reused shall be removed by the Government in advance of work to avoid interfering with Contractor's operation.

1.11 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the

Work site, which are not to be removed and which do not unreasonably interfere with the Work required under this contract. The Contractor shall only remove trees when specifically authorized to do so and shall avoid damaging vegetation that shall remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the Work site and on adjacent property of a third party, the locations of which are made known to or shall be known by the

Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the Work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer shall have the necessary work performed and charge

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 the cost to the Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

1.12 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to provide new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, gas, or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Where removal of partitions results in adjacent spaces becoming one, rework floors, walls and ceilings to a smooth plane without breaks, steps, or bulkheads. Where a change of plane of 1/4 inch or more occurs, make transition as recommended by flooring manufacturers. Trim existing doors as necessary to clear new floors. Refinish trim as needed for a complete installation.

C. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

D. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workmen to existing piping and conduits, wires, cables of utility services or of fire protection systems and communications systems (including telephone) which are indicated on Drawings and which are not scheduled for discontinuance.

E. Expense of repairs to such utilities and systems not shown on drawings

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING SITE CONDITIONS" (FAR

52.236-2).

1.13 Not Used

1.14 PROFESSIONAL SURVEYING SERVICES-Not Applicable

1.15 LAYOUT OF WORK

A. The Contractor shall lay out the Work from Government established base lines and benchmarks, indicated on the Drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at Contractor's own expense, templates, platforms, equipment, tools, materials, and labor required to lay out the Work. The Contractor shall be responsible for executing the Work to the lines and grades that shall be established or indicated by the Contracting Officer.

B. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through Contractor's negligence before their removal is authorized, the Contracting Officer shall replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

(FAR 52.236-17)

C. Establish and plainly mark center lines for addition(s) to existing building, and such other lines and grades that are reasonably necessary to properly assure that location, orientation, and elevations established for the Work are in accordance with lines and elevations shown on contract

Drawings.

D. During progress of the Work, and particularly as work progresses from floor to floor, Contractor shall have line grades and plumbness of all major form work checked and certified by a qualified, competent individual as meeting requirements of contract Drawings. Furnish such certification to the COR before any major items of concrete work are placed.

1.16 AS-BUILT DRAWINGS

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204

A. The Contractor shall maintain two full size sets, and 1 half size set of as-built Drawings which shall be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract Drawings. To ensure compliance, as-built Drawings shall be made available for the COR's review, as often as requested.

C. Contractor shall deliver three approved completed sets of as-built

Drawings to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.17 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on Medical

Center property and, when authorized by the COR, such temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed by the Contractor at Contractor's expense.

When necessary to cross curbing, sidewalks, or similar construction, they shall be protected by well-constructed bridges.

1.18 CONTRACTING OFFICER'S REPRESENTATIVE FIELD OFFICE-Not Applicable

1.19 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power shall be permitted subject to compliance with the following provisions:

1. Permission to use each unit or system shall be given by the COR in writing. If the equipment is not installed and maintained in accordance with the following provisions, the COR shall withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the Drawings and Specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014 Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical equipment shall be

Dept. of Veteran Affairs Nashville Medical Center Nashville, TN

VA Project 626-24-204 thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations shall be eliminated.

4. Automatic temperature control systems for preheat coils shall function properly and all safety controls shall function to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elements shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distribution system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

B. Prior to final inspection, the equipment or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical Specifications sections.

D. Any damage to the equipment or excessive wear due to prolonged use will be repaired/replaced by the contractor at the contractor’s expense.

1.20 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevator for handling building materials and

Contractor's personnel shall be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators.

Contractor is permitted to only…