250003_ATT08_LDS.pdf
PDF 225 KB Posted
- Solicitation number
- FA813726R0013
About this file
This document is a Liquidated Damages (LD) assessment sheet for a federal construction delivery order. The project is titled "RELOCATE FIRE ALARM CIRCUIT, B3001, O106-O65, B3001" under project number WWYK250003. In accordance with FAR 36.101-5, DFARS 236.101-5, and DFARS 211.400, liquidated damages will be assessed at $227.75 per calendar day for each day of delay in completing the work. The assessment is based on three criteria: the contractor maintains complete control over the pace of work, the contract provides for daily LD assessments, and the rate is reasonable given the project requirements.
The daily LD amount of $227.75 is composed of two components. Engineering costs total $122.36 per day and include 0.5 hours of Engineering Manager time at $57.69/hour, 1 hour of Project Manager at $36.06/hour, 1 hour of Engineering Tech/Inspector at $28.52/hour, 0.5 hours of Project Engineers at $38.46/hour, and 0.5 hours of Clerical support at $19.41/hour. Government costs total $105.39 per day and include 0.5 hours of FAS (GS-12/5) support at $39.19/hour, 1 hour of Legal (GS-13/5) at $46.60/hour, and 1 hour of Contracting (GS-12/5) at $39.19/hour. The document is signed by Contracting Officer Sara Hinds.
View the file
Other files
Show all 16
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$
ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$
SUBTOTAL 122.36$
GOVERNMENT TITLE Hrs RATE TOTAL
FAS (GS-12/5) 0.5 39.19$ 19.60$
Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$
SUBTOTAL 105.39$
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$
Contracting Officer (Signature)
Contracting Officer (Print)
Date:
LIQUIDATED DAMAGES
PROJECT NUMBER & TITLE: WWYK250003 RELOCATE FIRE ALARM CIRCUIT, B3001, O106-O65, B3001
In accordance with FAR 36.101-5, DFARS 236.101-5, and DFARS 211.400, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/ delivery order.
As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work.
b. The contract provides for LDs for delay of work for each calendar day of the contract.
c. Considering the requirement, the rate of assessment is reasonable.
Sheet1
| FACILITYUSER DAMAGES: |
| Daily Consideration of Delivery Extension: |
| Engineering Manager: |
| Project Manager: |
| Engineering Tech Inspector: |
| Project Engineers: |
| Clerical: |
| FAS GS125: |
| Legal GS135: |
| Contracting GS125: |
| Contracting Officer Print: Sara Hinds |
| Date: |
File details come from the government source that posted it. Updated .