00_00_01_-_Specifications_03312025_0007.pdf

Navajo-Gallup Water Supply Project Amendment 007 San Juan Lateral – Reach 1 Pipeline Improvements Solicitation No.

Revised - Table of Contents

00 01 10 - 1

SECTION C - DESCRIPTION/SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 – GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 12 10 Other Contracts 01 14 10 Use of Site 01 14 12 Work Restrictions and Limitations 01 31 19 Project Management and Coordination 01 31 30 Contract Document Management System 01 32 10 Construction Program 01 33 00 Submittals 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 30 Contractor’s Onsite Safety Personnel 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 46 20 Testing Agency Services 01 51 00 Temporary Utilities 01 55 00 Vehicular Access and Parking 01 55 20 Traffic Control 01 56 10 Protection of Existing Installations 01 56 15 Protection of Existing Utilities 01 56 20 Existing Fences 01 56 26 Temporary Fence 01 56 32 Temporary Safety Fence 01 57 20 Environmental Controls 01 57 30 Water Pollution Control 01 57 40 Pesticides 01 57 50 Tree and Plant Protection 01 57 60 Protected Species 01 57 90 Preservation of Historical and Archeological Data 01 60 00 Product Requirements 01 71 20 Surveying 01 74 00 Cleaning and Waste Management 01 78 30 Project Record Documents

DIVISION 02 – EXISTING CONDITIONS

02 41 16 Building Demolition 02 80 10 General Requirements for Hazardous Materials Abatement, Asbestos 02 82 20 Removal and Disposal of Asbestos Containing Materials 02 83 37 Disposal of Universal Waste

00 01 10 - 2

DIVISION 03 – CONCRETE

03 11 10 Concrete Forming 03 20 00 Concrete Reinforcement 03 30 00 Cast-In-Place Concrete 03 48 00 Precast Concrete Structures 03 62 20 Nonshrink Grout for Equipment and Metalwork 03 63 00 Epoxy Grout

DIVISION 05 – METALS

05 50 00 Metal Fabrications

DIVISION 07 – THERMAL AND MOISTURE PROTECTION

07 21 20 Extruded Polystyrene Foam Insulation 07 21 50 Spray-Applied Polyurethane Foam Insulation 07 21 60 Insulation Jacket

DIVISION 08 – OPENINGS

08 31 25 Access Hatches

DIVISION 09 – FINISHES

09 96 20 Coatings

DIVISION 10 – SPECIALTIES

10 14 26 Utility Markers

DIVISION 26 – ELECTRICAL

26 42 00 Cathodic Protection Systems

DIVISION 31 – EARTHWORK

31 02 10 Water for Dust Abatement 31 02 30 Dust Palliative 31 03 33 Removal and Control of Water 31 11 00 Clearing and Grubbing 31 14 10 Topsoil Stripping, Stockpiling and Placement 31 23 02 Compacting Earth Materials 31 23 11 Earthwork for Structures 31 23 22 Pipe Trench Earthwork 31 23 39 Disposal of Excavated Materials

00 01 10 - 3

31 23 70 Controlled Low Strength Material (CLSM) 31 31 30 Soil Applied Herbicide

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 12 22 Asphalt Concrete Pavement 32 15 10 Gravel Surfacing 32 92 20 Seeding

DIVISION 33 – UTILITIES

33 11 12 Steel Manways and Line Pipe 33 12 10 Valves and Equipment for Line Pipe Installations

DIVISION 35 – WATERWAY AND MARINE CONSTRUCTION

35 21 95 Steel Manifold Piping 35 22 14 Valves and Equipment

DIVISION 51 – INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors 51 00 10 Pipeline Inspection Report 51 00 20 Analytic Test Results 51 00 40 NTUA Markers 51 00 50 Electronic Media Release 51 00 60 Boundary Survey 51 00 70 BLM Herbicides 51 02 83 Hazardous Materials Survey and Analytical Results

DIVISION 52 – DRAWINGS

52 00 00 Drawings

DIVISION 53 – GEOLOGIC INVESTIGATIONS AND RECORDS

53 10 00 Geologic Investigations 53 20 00 Records of Geologic and Subsurface Investigations

END OF CONTENTS

00 01 10 - 4

This page intentionally left blank.

Revised Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost: Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-2020 Decimal Inch Drawing Sheet Size and

Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-2014 United States National CAD Standards, Version 6

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittal Types, as listed in Table 01 33 00A – List of Submittals:

1. A – Action:

a. Government will respond as to adequacy of submittal.

b. Action submittals: Considered to be “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I – Informational:

a. Government will acknowledge receipt of Informational submittals.

b. Government may reject an Informational submittal when submittal does not comply with contract. Contractor shall correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational submittals: Considered to be “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

01 33 00 - 2

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number, title, and RSN.

3. Measurement units: US Customary Units.

4. Provide unique transmittal number for each submittal.

C. Drawings:

1. Minimum identification in title block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3- by 3-inch space next to title block for review stamps.

3. Print Size: D size (22- by 34-inches) as defined by ASME Y14.1.

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified:

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AutoCAD, Version 2018 or later.

3) Compile using “eTransmit” utility in AutoCAD.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings designated as “Government Format” in specifications:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on Standard Drawing 40-D-7102.

2) Government will provide template.

3) Government will provide specific title block information to be used.

01 33 00 - 3

6. Final Drawings:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

d. Electronic Files: On Reclamation issued USB Drive.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets:

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional:

a. Not required for non-design work.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

b. Electronic copies: Searchable Adobe .pdf on Reclamation issued USB

Drive:

1) Bookmark longer files to assist in navigating file.

2) Electronic files may be submitted as separate parts of a manual.

After each separate electronic file is approved, compile each approved electronic file to assemble an entire manual which shall be consistent with final manual submittal.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

01 33 00 - 4

d. As-built drawings, photographs, and test records or reports if required by specifications.

G. Photographs:

1. Digital files: In .jpeg or similar format.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A – List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit sets specified in “Sets to be sent:” columns in Table 01 33 00A – List of Submittals:

1. Submittals identified with “CDMS” in “Sets to be sent” column shall be submitted electronically in accordance with Section 01 31 30 – Contract Document Management System.

2. Submittals identified with “CDMS” in the top row of the “Sets to be sent” column require approval (Action) or acknowledgement (Informational) before sending required sets of hardcopy submittals.

3. Submittals identified with “CDMS” in the bottom row of the “Sets to be sent” column require submittal of hardcopy submittals before finalizing submittal in

CDMS.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 28 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

01 33 00 - 5

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through digital signature date stamp and upload date in CDMS.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time:

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract, and

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR

52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Return of Submittals:

1. Return of submittals will be by CDMS response or hard copy, as applicable.

2. Action Submittals: One set of submittals required for action will be returned either approved, partially approved, approved subject to identified changes and resubmit, or not approved:

a. Submittals that are not approved shall be revised and resubmitted.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

c. Exception: Schedules will be either accepted, partially accepted or not accepted.

01 33 00 - 6

3. Informational Submittals: Government will acknowledge Informational submittals:

a. Informational submittals will not be returned when they comply with specifications.

b. Informational submittals that do not comply with specifications may be returned for resubmittal or additional information may be requested.

1.07 HARD COPY OF TRANSMITTALS

A. Addresses for codes listed in Table 01 33 00A – List of Submittals:

1. Contracting Officer, Bureau of Reclamation, Attn: UC-840, 125 South State St., Room 6107, Salt Lake City, UT 84138-1147.

2. Construction Engineer, Bureau of Reclamation, 1235 La Plata Hwy, Farmington, New Mexico, 87401.

3. Technical Service Center, Bureau of Reclamation, Attn: 86-68160, PO Box

25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

4. Navajo Tribal Utility Authority (NTUA), Attn: Operations Manager, PO Box 1749, Shiprock, NM 87420.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A – List of Submittals:

1. Responsible codes starting with “86-6” are located in the Technical Service

Center. Send these submittals to the TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not the responsible code but show “No. of sets to be sent to” in Table 01 33 00A – List of Submittals.

D. Provide copy of transmittal letter on CDMS.

E. When “No. of sets to be sent to” is 0, send a copy of transmittal letter to that office.

F. Submittals required by the specifications, but not listed in Table 01 33 00A – List of Submittals:

1. Submit in accordance with this section.

2. Submit to CE, unless otherwise specified.

PART 2 PRODUCTS

Not Used

01 33 00 - 7

PART 3 EXECUTION

01 33 00 - 8

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates the City of Gallup New Mexico.

RSN Clause or Section Title

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 14 10-1 Use of Site Land Use and Landscape Rehabilitation Plan

At least 63 days before use of

ROW

A CE CDMS

01 31 19-1 Project Management and Coordination

Written Summary Monthly once onsite construction begins

A CE CDMS

01 31 19-2 Project Management and Coordination

Off ROW Land Use Coordination

At least 6 months before use of OFF ROW land

I CE CDMS

01 31 19-3 Project Management and Coordination

Key Personnel Within 7 days after receipt of Notice of Award

A CE CDMS

01 31 19-4 Project Management and Coordination

Replacement of Key Personnel

A minimum of 2 business days prior to work being performed by new personnel

A CE CDMS

01 31 30-1 Contract Document Management System

Approval Data Within 21 days of Award

A CE 0 1 0 0

CDMS

01 31 30-2 Contract Document Management System

Final Data Within 14 days of completion of work

A CE 0 2 2 0

CDMS

01 32 10-1 Construction Program

Representative Information

Within 7 days after receipt of Notice of Award

I CE CDMS

01 32 10-2 Construction Program

Baseline Schedule Within 21 days after receipt of initial Notice to Proceed

A CE CDMS

01 32 10-3 Construction Program

Updated Schedule Reports

Monthly or with Progress Payments

A CE CDMS

01 33 00 - 9

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 32 10-4 Construction Program

Time Impact Analysis

Within 28 days after CO directs a contract change, with any proposal for a future modification, with any value engineering proposal, or with any request or claim for an equitable adjustment to the contract.

A CE CDMS

01 35 10-1 Safety Data Sheets Complete LHM and SDS

At least 14 days before jobsite delivery of hazardous material

I CE CDMS

01 35 10-2 Safety Data Sheets Updated LHM and

SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

I CE CDMS

01 35 20-1 Safety and Health

(WBR 1452.223-

81)

Safety Program Submitted and accepted before commencing onsite work.

Submit at least 45 days before beginning onsite work. See Section

1.03 of RSHS

A CE CDMS

01 35 20-2 Safety and Health Job Hazard Analyses

At least 14 days before commencing onsite activities for each phase of work

A CE CDMS

01 35 20-3 Safety and Health Monthly Accident Summary Report

First day of each month.

01 33 00 - 10

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 35 30-1 Contractor’s Onsite Safety Personnel

Resumes At least 45 days before beginning onsite construction;

resubmit upon personnel change

A CE CDMS

01 35 30-2 Contractor’s Onsite Safety Personnel

Safety Inspection Reports

At least once each week

I CE CDMS

01 46 00-1 Quality Procedures Contractor Quality Control (QC) Plan

At least 45 days before beginning onsite work

A CE CDMS

01 46 00-2 Quality Procedures Contractor’s Daily Report

Weekly I CE CDMS

01 46 00-3 Quality Procedures Quality Control Supervisor (QCS) Resume

At least 45 days before beginning onsite work.

Resubmit upon personnel change.

A CE CDMS

01 46 00-4 Quality Procedures Contractor’s Quality Testing Plan

At least 45 days before beginning onsite work

A CE CDMS

01 46 00-5 Quality Procedures Summary of Monthly Test Results

Monthly, on or before 5th day of each month

A CE CDMS

01 46 20-1 Testing Agency Services

Testing Agencies Services Plan

At least 45 days before testing is required

A CE CDMS

01 55 00-1 Vehicular Access and Parking

Preconstruction Digital Recording

At least 21 days before beginning onsite work

A CE 0 1 0 0

01 55 00-2 Vehicular Access and Parking

Right of Way (ROW) Access Plan

At least 21 days before beginning onsite work.

A CE CDMS

01 55 00-3 Vehicular Access and Parking

Post-Construction and Post-Repair Digital Recording

At least 21 days before leaving site.

A CE 0 1 0 0

01 55 20-1 Traffic Control Traffic Control Plan

At least 70 days before affecting public traffic.

A CE CDMS

01 55 20-2 Traffic Control Approved NMDOT Permit(s)

At least 45 days before affecting public traffic.

01 33 00 - 11

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 56 10-1 Protection of Existing Installations

Plan for Protecting Existing Installations

At least 45 days before start of onsite construction work

A CE CDMS

01 56 15-1 Protection of Existing Utilities

Utility Owner Acknowledgement

At least 45 days prior to submitting RSN 33 11 12-5

A CE CDMS

01 56 15-2 Protection of Existing Utilities

Utility Crossing Investigation

At least 45 days prior to submitting RSN 33 11 12-5 and at least 45 days prior to excavation

A CE CDMS

01 56 15-3 Protection of Existing Utilities

Work Plan within Utility Easements

With RSN 33 11 12-5 and at least 45 days prior to excavation

A CE CDMS

01 56 26-1 Temporary Fence Approval Data At least 45 days before start of onsite construction work

A CE CDMS

01 57 20-1 Environmental Controls

Copy of Applicable Air Quality Permit

At least 14 days before beginning onsite work

I WCAO CDMS

01 57 30-1 Water Pollution Control

Stormwater Pollution Prevention Plan

(SWPPP)

At least 28 days before start of onsite construction work

A WCAO CDMS

01 57 30-2 Water Pollution Control

Spill Prevention, Control, and Countermeasure (SPCC) Plan

At least 28 days before delivery or storage of oil

A WCAO CDMS

01 57 40-1 Pesticides Qualifications At least 45 days before beginning onsite work

A WCAO CDMS

01 57 40-2 Pesticides Pesticide Use Plan At least 45 days before application of first pesticide

A CE CDMS

01 57 50-1 Tree and Plant Protection

Protection Plan At least 45 days before beginning onsite work

01 33 00 - 12

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 57 90-1 Preservation of Historical and Archeological Data

Alternate Use Area or Borrow Area

At least 45 days before beginning offsite work, if commercial site;

if non-commercial site then at least 6-months prior to use of land

A CE CDMS

01 71 20-1 Surveying Surveying Plan Within 45 days after Notice to Proceed, and approved before beginning survey work

A CE CDMS

01 71 20-2 Surveying Resume(s) At least 45 days before beginning survey work;

resubmit upon personnel change

I CE CDMS

01 71 20-3 Surveying Accuracy Check Results

At least 45 days before beginning survey work

I CE CDMS

01 71 20-4 Surveying Completed and Reduced Survey Notes

Within 2 days of completing and reducing notes

I CE CDMS

01 71 20-5 Surveying Original Field Survey Books

Weekly I CE CDMS

01 71 20-6 Surveying Quantity Survey Notes and Computations

Accompanying progress payment requests

I CE CDMS

01 71 20-7 Surveying Workday's Survey Notes

At conclusion of workday if requested by Government

I CE CDMS

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

At least 45 days before beginning onsite work

I CE CDMS

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of hazardous waste disposal

I CE CDMS

01 33 00 - 13

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 45 days before beginning environmental assessment

I CE CDMS

01 74 00-4 Cleaning and Waste Management

Environmental Site Assessment

Within 14 days of completion of work

I CE CDMS

01 78 30-1 Project Record Documents

Electronic Media Release Form

With request for Electronic Drawings

A CE CDMS

01 78 30-2 Project Record Documents

Progress As-Built Drawings

Monthly once onsite construction begins.

A CE CDMS

01 78 30-3 Project Record Documents

Final As-Built Drawings

Within 28 days of Government issued substantial completion of work

A CE CDMS

01 78 30-4 Project Record Documents

Draft O&M Manuals

Within 28 days of Government issued substantial completion of work

A CE 0 2 2 2

CDMS

01 78 30-5 Project Record Documents

Final Drawings Within 14 days of approval of

RSN 01 78 30-3

A CE 0 2 0 2

CDMS

01 78 30-6 Project Record Documents

Final O&M Manuals

Within 14 days of approval of

RSN 01 78 30-4

A CE 0 2 2 2

CDMS

02 41 16-1 Weathers Building Demolition

Utility Identification Plan

At least 35-days prior to locating utilities

A CE CDMS

02 41 16-2 Weathers Building Demolition

Building Demolition Plan

At least 35-days prior to building demolition

A CE CDMS

02 41 16-3 Weathers Building Demolition

Existing Utility Removal Plan

At least 35-days prior to removing utilities

01 33 00 - 14

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

02 41 16-4 Weathers Building Demolition

Notifications and Permits

Within 14-days of demolition

I CE CDMS

02 41 17-1 Shaw Building Demolition

Utility Identification Plan

At least 35-days prior to locating utilities

A CE CDMS

02 41 17-2 Shaw Building Demolition

Building Demolition Plan

At least 35-days prior to building demolition

A CE CDMS

02 41 17-3 Shaw Building Demolition

Existing Utility Removal Plan

At least 35-days prior to removing utilities

A CE CDMS

02 41 17-4 Shaw Building Demolition

Notifications and Permits

Within 14-days of demolition

I CE CDMS

02 80 10-1 General Requirements for Hazardous Materials, Asbestos

Qualifications At least 35-days prior to commencing asbestos removal work

A CE CDMS

02 80 10-2 General Requirements for Hazardous Materials, Asbestos

Worker Protection and Monitoring Plan

At least 35-days prior to commencing asbestos removal work

A CE CDMS

02 80 10-3 General Requirements for Hazardous Materials, Asbestos

Background Test Results

At least 35-days prior to commencing asbestos removal work

A CE CDMS

02 80 10-4 General Requirements for Hazardous Materials, Asbestos

Worker Exposure Test Results

At least 28-days after completion of asbestos removal work

I CE CDMS

02 80 10-5 General Requirements for Hazardous Materials, Asbestos

Visual Inspection and Final Air Clearance

At least 28-days after completion of asbestos removal work

01 33 00 - 15

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

02 82 20-1 Removal and Disposal of Asbestos Containing Materials

Certificates, Qualifications and Resumes

At least 35-days prior to removal of asbestos

A CE CDMS

02 82 20-2 Removal and Disposal of Asbestos Containing Materials

Asbestos Contractor’s History

At least 35-days prior to removal of asbestos

A CE CDMS

02 82 20-3 Removal and Disposal of Asbestos Containing Materials

Asbestos Hazard Abatement Plan

At least 35-days prior to removal of asbestos

A CE CDMS

02 82 20-4 Removal and Disposal of Asbestos Containing Materials

Notice of Asbestos Abatement

At least 35-days prior to removal of asbestos

A CE CDMS

02 82 20-5 Removal and Disposal of Asbestos Containing Materials

Bills of Lading Within 28-days of completing asbestos removal work

A CE CDMS

02 83 37-1 Removal and Disposal of Universal Waste

Qualifications At least 28-days prior to commencing building demolition

A CE CDMS

02 83 37-2 Removal and Disposal of Universal Waste

UW Handling and Disposal Plan

At least 28-days prior to commencing building demolition

A CE CDMS

02 83 37-3 Removal and Disposal of Universal Waste

Shipping Papers Within 28-days of completing building demolition

01 33 00 - 16

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

02 83 37-4 Removal and Disposal of Universal Waste

Disposal Certificate Within 28-days of completing building demolition

I CE CDMS

03 20 00-1 Concrete Reinforcement

Reinforcement Diagrams and Lists

At least 28 days prior to delivery of reinforcement

A CE CDMS

03 30 00-1 Cast-In Place Concrete

Approval Data At least 42-days before placing concrete

A TSC

86-68530

CDMS

03 30 00-2 Cast-In Place Concrete

Concrete Placement Schedule

At least 42-days before placing concrete

A CE CDMS

03 30 00-3 Cast-In Place Concrete

Certifications 42-days before placing concrete

A TSC

86-68530

CDMS

03 30 00-4 Cast-In Place Concrete

Test Reports Within 7-days of completing tests

A TSC

86-68530

CDMS

03 48 00-1 Precast Concrete Structures

Certificates At least 28-days before start of onsite construction work

A CE CDMS

03 48 00-2 Precast Concrete Structures

Shop Drawings At least 28-days before start of onsite construction work

A TSC

86-68140

CDMS

01 33 00 - 17

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

03 48 00-3 Precast Concrete Structures

Product Data At least 28-days before start of onsite construction work

A TSC

86-68530

CDMS

03 62 20-1 Nonshrink Grout for Equipment and Metalwork

Packaged Nonshrink Grout Data

At least 28-days before placing grout

A CE CDMS

03 63 00-1 Epoxy Grout Approval Data At least 42-days before placing grout

A CE CDMS

07 21 20-1 Extruded Polystyrene Foam Insulation

Approval Data At least 28-days before applying insulation

A CE CDMS

07 21 50-1 Spray-Applied Polyurethane Foam Insulation

Approval Data At least 28-days before applying insulation

A CE CDMS

07 21 50-2 Spray-Applied Polyurethane Foam Insulation

Instructions At least 28-days before applying insulation

A CE CDMS

07 21 50-3 Spray-Applied Polyurethane Foam Insulation

Documentation At least 28-days before applying insulation

A CE CDMS

07 21 60-1 Insulation Jacket Approval Data At least 28-days before purchasing jacket

01 33 00 - 18

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

07 21 60-2 Insulation Jacket Instructions At least 28-days before purchasing jacket

A CE CDMS

08 31 25-1 Access Hatches Product Data and Shop Drawings

At least 28-days before purchasing hatches

A TSC

86-68120

CDMS

09 96 20-1 Coatings Approval Data At least 42-days before beginning coating work

A TSC

86-68540

CDMS

09 96 20-2 Coatings Final Approval Data

At least 42-days before beginning coating work

A TSC

86-68540

CDMS

09 96 20-3 Coatings Paint Chip Samples At least 42-days before beginning coating work

A CE 0 1 1

09 96 20-4 Coatings Qualifications At least 42-days before beginning coating work

A TSC

86-68540

CDMS

09 96 20-5 Coatings Quality Control Plan

At least 42-days before beginning coating work

A TSC

86-68540

CDMS

09 96 20-6 Coatings Contractor Quality Testing Report

Weekly A TSC 86-68540

01 33 00 - 19

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

10 14 26-1 Utility Markers Utility Marker Plan At least 28-days prior to installation of utility markers

A CDMS

26 42 00-1 Cathodic Protection General Requirements

Certification and Data

28-days prior to installation of cathodic protection

A TSC 86-

68540

CDMS

26 42 00-1 Cathodic Protection General Requirements

Final Data Within 7-days of installation

A TSC 86-

68540

CDMS

31 02 10-1 Water for Dust Abatement

Meter Calibration At least 42-days before beginning onsite work

A CE CDMS

31 02 30-1 Dust Palliative Proposed Application Area for Dust Palliative

At least 42-days before beginning onsite work

A CE CDMS

31 03 33-1 Removal and Control of Water

Removal and Control of Water Plan

At least 28-days before beginning onsite work

A TSC

86-68312

CDMS

31 23 02-1 Compacting Earth Materials

Test Results Within 7-days after completion of tests

I CE CDMS

31 23 11-1 Earthwork for Structures

Geotechnical Engineering Analysis and Design of Structure Subgrade

At least 28-days before start of onsite construction work

01 33 00 - 20

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

31 23 11-2 Earthwork for Structures

Processing Plan for Soils under Structures

At least 28-days before start of onsite construction work

A CE CDMS

31 23 11-3 Earthwork for Structures

Test Results Within 28-days of testing

A CE CDMS

31 23 22-1 Pipe Trench Earthwork

Processing Plan At least 28-days before start of onsite construction work

A CE CDMS

31 23 22-2 Pipe Trench Earthwork

Soil Test Results Within 28-days of testing

A COR CDMS

31 23 70-1 Controlled Low Strength Materials

(CLSM)

Approval Data for

CLSM

At least 42-days before placing

A 86-68530 CDMS

31 23 70-2 Controlled Strength Materials (CLSM)

Cold Weather Protection Plan

At least 28-days prior to anticipated use

A CE CDMS

31 23 70-3 Controlled Low Strength Materials

(CLSM)

Quality Control Test Results

Within 7 days of testing

A CE CDMS

31 31 30-1 Soil-Applied Herbicide

Use Plan At least 28-days before placing

01 33 00 - 21

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

31 31 30-2 Soil-Applied Herbicide

Applier Certification

At least 28-days prior to beginning work

A CE CDMS

32 12 22-1 Asphalt Concrete Pavement

Job Mix Form8ula

(JMF)

At least 35-days prior to placing asphalt

A CE CDMS

32 15 10-1 Gravel Surfacing Gravel Certification

At least 35-days before placing surfacing

A CE CDMS

32 15 10-2 Gravel Surfacing Geotextile

Installation At least 28-days before placing surfacing

A CE CDMS

32 15 10-3 Gravel Surfacing Geotextile Certification

At least 28-days before placing surfacing

A CE CDMS

32 92 20-1 Seeding Seeding Plan At least 28-days before seeding

A CE CDMS

32 92 20-2 Seeding Certifications At least 28-days before seeding

A CE CDMS

33 11 12-1 Steel Manway and Line Pipe

Qualifications At least 42-days prior to fabrication or procurement

A CE CDMS

33 11 12-2 Steel Manway and Line Pipe

Existing Pipeline Video Inspection

Within 60-days of NTP

01 33 00 - 22

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

33 11 12-3 Steel Manway and Line Pipe

Existing Pipeline Hydrostatic Testing

At least 60-days before beginning repair work

A CE CDMS

33 11 12-4 Steel Manway and Line Pipe

Existing Pipeline Survey

Within 60-days of NTP

1 1 33 11 12-5 Steel Manway and

Line Pipe Existing Pipeline Non-destructive Assessment

Within 60-days of NTP

A CE CDMS

1 1

33 11 10-6 Steel Manway and Line Pipe

Work Plan At least 42-days prior to fabrication or procurement

A TSC 86-

68141

CDMS

33 11 12-7 Steel Manway and Line Pipe

Shop Drawings At least 42-days prior to fabrication or procurement

A TSC 86-

68141

CDMS

33 11 12-8 Steel Manway and Line Pipe

Filling and Testing Plan

At least 42-days prior to fabrication or procurement

A COR CDMS

33 11 12-9 Steel Manway and Line Pipe

Floatation Prevention Plan

At least 42-days prior to fabrication or procurement

A TSC 86-

68141

33 12 10-1 Valves and Equipment for Line Pipe Installations

Commercial Product Data

At least 42-days before fabrication or procurement

A TSC

86-68410

CDMS

33 12 10-2 Valves and Equipment for Line Pipe Installations

Service Manuals Within 14-days after installation

I TSC

86-68410

01 33 00 - 23

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

33 12 10-3 Valves and Equipment for Line Pipe Installations

Shop Testing Certifications and Reports

Within 14-days of testing

A TSC

86-68410

CDMS

35 21 95-1 Steel Manifold Piping

Shop Drawings At least 42-days before fabrication or procurement

A COR CDMS

35 21 95-2 Steel Manifold Piping

Commercial Products Data

At least 42-days before fabrication or procurement

A COR CDMS

35 21 95-3 Steel Manifold Piping

Pipe Removal Procedure

At least 42-days before removal

A COR CDMS

35 21 95-4 Steel Manifold Piping

Pipe Installation Procedure

At least 42-days before installation

A COR CDMS

35 21 95-5 Steel Manifold Piping

Final Data Within 14-days after installation

A COR CDMS

35 21 95-6 Steel Manifold Piping

Final Drawings Within 14-days after installation

A COR CDMS

35 22 14-1 Valves and Equipment

Plunger Valve Commercial Products Data

At most 15 days after notice to proceed

A COR CDMS

01 33 00 - 24

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO

Submittals Required

Due Date or Delivery Time

Type

Respon-sible Code

No. of sets to be sent to:**

CO CE TSC NTUA

35 22 14-2 Valves and Equipment

Commercial Products Data

At least 42-days before fabrication or procurement

A COR CDMS

35 22 14-3 Valves and Equipment

Field Installation Procedures

At least 42-days before installation

A COR CDMS

35 22 14-4 Valves and Equipment

Shop Testing Certifications, Reports, and Data

Within 14 days of testing

A COR CDMS

35 22 14-5 Valves and Equipment

Plunger Valve Field Test Plan

At least 42-days before testing

A COR CDMS

35 22 15-6 Valves and Equipment

Service Manuals and Final Data

Within 14-days after installation

A COR CDMS

END OF SECTION

Revised Pesticides

01 57 40 - 1

SECTION 01 57 40

PESTICIDES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

2. Contractor is responsible for damages resulting from use of pesticides under these specifications in accordance with the clause at FAR 52.236-7, Permits and Responsibilities.

1.02 DEFINITIONS

A. Pesticides: Includes herbicides, insecticides, fungicides, rodenticides, piscicides, avicides, surface disinfectants, animal repellants, and insect repellants.

1.03 REFERENCE STANDARDS

• Reclamation requires that the Contractor be

• Chemicals intended for use in the Project area must be reviewed and approved by Reclamation prior to application and must be legal and appropriate to the site-specific conditions where they are to be applied. A safety hazard analysis and the Material Safety Data Sheets (MSDS) for chemicals used must be submitted to the COR for each chemical with the chemical list at least 15 days prior to application of any chemical.

o Ideally a list of all herbicides that are intended for use and the approximate areas where they intend to be used should be provided as soon as possible after award.

Other notes:

• Moving forward, all NGWSP specs for herbicide usage should reference the BLM Approved Herbicide list.

• WCAO didn't think we needed to list specific herbicides in the specs; that could be determined by the applicator. The same applies to the concentration of herbicide applied, as this may vary by weed density, type, etc.

A.

B. Code of Federal Regulations (CFR)

1. 40 CFR Subchapter E Pesticide Programs

2. 40 CFR 156.10 Labeling Requirements for Pesticides and

Devices, Labeling Requirements

01 57 40 - 2

1.04 SUBMITTALS

A. Submit in accordance with Section 01 33 00 – Submittals.

B. RSN 01 57 90-1, Qualifications

1. Certifications

2. Resubmit within 10 days of personnel change.

C. RSN 01 57 40-2, Pesticide Use Plan:

1. Not required for insect repellant to be applied directly to clothing, or for small quantities of aerosol insecticide, such as fly and spider sprays, to be applied within or directly to offices or shop buildings.

2. Submit when chemicals or applications meet one or more of the following:

a. Chemicals categorized by USEPA for restricted use per 40 CFR

Subchapter E.

b. Chemicals applied to or that can reasonably be expected to contact water; except this requirement does not apply to Rodeo herbicide or copper sulfate used for control of noxious weeds.

c. Chemicals expected to endanger threatened animal or plant species.

3. For each pesticide:

a. Complete Reclamation Form 7-2615 “Pest Management/Integrated Pest Management Checklist” available from:

1) Bureau of Reclamation, Attn: 86-68200, P.O. Box 25007, Denver, CO 80225-0007.

b. SDS.

c. Complete label as defined by 40 CFR 156.10, containing the following:

1) Name, brand, or trademark product sold under.

2) Name and address of the producer or registrant.

3) Net contents.

4) Producing establishment’s number.

5) Ingredient statement.

6) Warning or precautionary statements.

7) Directions for use.

8) Use classification.

01 57 40 - 3

1.05 QUALIFICATIONS

A. Certified to apply appropriate weed and vegetation control measures in the project area. Possess, at a minimum, a commercial applicator’s license for the State of New Mexico to dispense herbicides in industrial-right-of-ways, rangeland settings, and in wetland areas for weed control work involving herbicide application.

1.06 DELIVERY, STORAGE, AND HANDLING

A. Comply with labeling and Safety Data Sheet (SDS) requirements when dealing with pesticides.

B. Keep records of pesticide types and amounts purchased, delivered, stored, mixed, and actually used, and disposal means of excess. Make records available for review by COR upon request.

PART 2 PRODUCTS

2.01 PESTICIDES

A. Allowed pesticides:

1. Refer to pesticides in Section 51 70 00 – BLM

2. Only those registered with EPA in compliance with Federal Environmental

Pesticide Control Act of 1972 and Pesticide Registration Improvement Act of 2003.

3. Not prohibited by State, Navajo Nation, or local agencies.

PART 3 EXECUTION

3.01 APPLICATION

A. Apply pesticides only as allowed by labeling.

B. In accordance with and only after approval of Pesticide Use Plan.

01 57 40 - 4

Revised - Protected Species

01 57 60 - 1

SECTION 01 57 60

PROTECTED SPECIES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost: Include in prices offered in the Price Schedule for other items of work.

1.02 PROJECT CONDITIONS

A. Certain native plant and animal species in the State of New Mexico are protected under Federal, Tribal, and State laws. Government has ascertained that protected species and/or their habitats may exist in the areas to be disturbed by construction activities. These species include, but may not be limited to:

1. Migratory Birds.

2. Mesa Verde Cactus.

3. Raptors.

B. Federal legislation provides for protection of Threatened and Endangered Species, which might otherwise be lost due to alteration of terrain as a result of any Federal construction project.

C. Project is designed to comply with Environment Commitments of Navajo-Gallup Water Supply Project Final Environmental Impact Statement, Realignment of the Northern Portion of the San Juan Lateral Environmental Assessment, and Final Biological Opinion for the Navajo-Gallup Water Supply Project reissued by U.S. Fish and Wildlife Service on September 20, 2022.

D. Insert this section in subcontracts.

E. In accordance with Federal, Tribal, and State Law, Government may arrange for removal of protected species.

1. Cooperate with those performing such removal.

2. If these species are not removed, cooperate with and abide by protection plans developed by appropriate Federal, Tribal, and State entities to avoid damage to or disturbance of protected species.

F. Persons who, without permission contribute to the take of threatened and endangered species are subject to arrest and penalty of United States, Navajo Nation, and New Mexico laws.

1. Take: To harass, harm, pursue, hunt, shoot, wound, kill, trap, capture or collect, or to attempt to engage in any such conduct.

01 57 60 - 2

2. Harm: Includes significant habitat modification or degradation that results in death or injury to listed species by significantly impairing essential behavioral patterns, including breeding, feeding, or sheltering.

3. Harass: Intentional or negligent actions that create the likelihood of injury to listed species to such an extent as to significantly disrupt normal behavior patterns which include, but are not limited to, breeding, feeding or sheltering.

4. Incidental Take: Take that is incidental to, and not the purpose of, the carrying out of an otherwise lawful activity.

5. Offenders will be subject to United States, Navajo Nation, and New Mexico environmental protection laws and civil penalties.

1.03 SPECIAL REQUIREMENTS

A. Migratory Birds:

1. Nesting may occur in area between March 15th and August 15th:

a. Government will survey for nesting birds in vegetated areas to be disturbed. Evaluation shall be performed no more than 5 days prior to area disturbance.

b. Notify COR 10 days before disturbing an area.

c. Do not disturb a nesting pair of birds with eggs:

1) Avoid birds and modify construction activities as directed by COR.

B. Mesa Verde Cactus:

1. Mesa Verde Cactus is found directly adjacent to construction areas.

a. Government will monitor work in these areas.

b. Coordinate work with COR.

c. Government will conduct preconstruction surveys for Mesa Verde Cactus.

Evaluation shall be performed in blooming season in the year prior to construction.

1) Blooming may occur from April to May.

d. Notify COR before a minimum of 14 days prior to disturbing an area with enough time to schedule complete spring surveys.

1) Do not disturb potential Mesa Verde Cactus habitat prior to preconstruction surveys.

2) Modify construction activities as directed by COR.

e. Onsite Contractor personnel shall complete Mesa Verde Cactus awareness training prior to working in project area.

1) Government will provide training to inform onsite personnel of environmental requirements and expectations.

01 57 60 - 3

2) Training session will occur during preconstruction meeting or other mutually agreed upon time before initial groundbreaking takes place.

a) Duration: Approximately 1 hour.

b) Training will be recorded, and a digital copy of Mesa

Verde Cactus awareness training will be provided to Contractor.

3) Require onsite personnel to complete required Mesa Verde Cactus awareness training before being allowed to work in project area.

4) Maintain training records.

5) Onsite personnel added after completion of Government-provided training session shall view digital copy of training before being allowed to work in project area.

C. Raptors:

1. Raptor nesting may occur in the area from January 15th to July 15th:

a. Minimize disturbance to raptors.

b. Government will conduct raptor surveys prior to construction that is to begin between January 15th and July 15th. Evaluation shall be performed no more than 5 days prior to area disturbance. The survey will include all potential nesting habitat within specified buffer distances (0.25-mile to 0.625-mile, depending on the species) of the construction right- of-way.

2. Notify COR 10 days prior to construction to allow for raptor nest surveys.

3. Do not disturb an active raptor nest:

a. Government will notify Contractor of nest locations.

b. No construction will be allowed within the above months within 0.25-mile to 0.625-mile of active nests, depending on the species.

4. Raptor Safe Utility Poles:

a. All above ground utility poles shall conform to a design standard(s) that comply with the Raptor Electrocution Prevention Regulations RCS-43-08 published September 10, 2008. This is to avoid unintentional electrocution of raptors that may perch on the utility pole.

1.04 DISCOVERY OF RESOURCES

A. When Contractor or parties operating or associated with Contractor, in performance of this contract discover threatened and endangered species on ROW:

1. Immediately cease work within 50 feet of discovery location.

01 57 60 - 4

a. Place temporary safety fence in accordance with 01 56 32 –Temporary Safety fence to prevent disturbance until biologist can investigate to avoid inadvertent disturbance by construction activities.

2. Verbally notify CO and OGR within 2 hours, giving location and nature of findings.

a. Follow with written confirmation to CO within 12 hours.

3. Verbally notify Reclamation staff biologist within 2 hours.

a. Name of assigned staff biologist and telephone number will be provided at preconstruction meeting.

B. Do not disturb or damage threatened and endangered species discovered during construction activities. Provide cooperation and assistance to preserve findings for removal or other disposition by CO.

C. Government, in consultation with appropriate regulatory agencies upon discovery of threatened and endangered species, will manage required removal/replacement planting in accordance with consultation commitments.

1. When discovery mitigation has been completed, CO will notify Contractor that work can resume in discovery area.

2. Do not resume work in area of discovery until receipt of written notice to proceed from CO.

D. Where appropriate by reason of discovery, CO may order delays in time of performance or changes in work or both. When such delays or changes are ordered, an equitable adjustment will be made in the contract in accordance with applicable clauses of the contract.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 MESA VERDE CACTUS MONITORING AREA

A. Provide 48-hour notice to OGR prior to approaching or entering the Mesa Verde Cactus Monitoring Area for construction activities.

1. Coordinate with the Government for a biological monitor for new ground disturbing construction activities within the required monitoring area identified on the drawings or other areas as directed by COR.

B. Erect Mesa Verde Cactus Monitoring Area Boundary Fence.

01 57 60 - 5

1. From Station 279+73 to 284+23.

2. Government Biologist will be on site during fence installation.

a. COR will coordinate Government Biologists attendance.

b. Notify COR 7 days prior to fence installation.

3. Refer to Section 01 56 32 – Temporary Safety Fence.

4. Maintain fence throughout its installation.

5. Remove fencing after reseeding.

01 57 60 - 6

New - BLM Herbicides

51 00 70 - 1

SECTION 51 00 40

BLM HERBICIDES

PART 1 GENERAL

51 00 70 - 2

51 00 70 - 3

51 00 70 - 4

51 00 70 - 5

51 00 70 - 6

51 00 70 - 7

51 00 70 - 8

51 00 70 - 9

51 00 70 - 10

51 00 70 - 11

PART 2 PRODUCTS

51 00 70 - 12

Not Used

PART 3 EXECUTION