B09_Amend_0001_Revised_Pages_0001.pdf
PDF 425 KB Posted
- Attached to
- Susanville/Doyle Interagency Fire Station Construc Federal contract opportunity
- Solicitation number
- 140L1223B0001
About this file
This document is an amendment to a solicitation for the construction of the Susanville/Doyle Interagency Fire Station. The amendment provides revised pages to the solicitation addressing inspection and acceptance, deliveries or performance, and a list of documents, exhibits, and attachments.
The construction is to be completed within 395 calendar days of receiving the notice to proceed, with an additional 45 days allotted for an optional additive bid item for a Doyle Fitness Center. Liquidated damages of $1,393 per day will be assessed for delays in completion. Final inspection and acceptance will occur once all punch list items and submittals are complete, the site is cleaned, and the contracting officer provides written notice. The solicitation includes specifications, drawings, as-built drawings, and a stormwater pollution prevention plan for the fire station and fitness center projects. Prevailing wage determinations from the Department of Labor apply to the construction work.
View the file
Other files for this federal contract opportunity
Show all 22
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Solicitation No. 140L1223B0001
E-1
SECTION E -- INSPECTION AND ACCEPTANCE
Clause Title Date 52.246-12 Inspection of Construction AUG 1996
FINAL INSPECTION AND ACCEPTANCE
Final completion of the punch list items, submission of all required submittals, and final cleanup of the project site shall be accomplished before the contract’s required completion date. The Contracting Officer or his/her designated representative will perform final inspection. Acceptance of the work will occur only upon written notice of acceptance by the Contracting Officer or any other warranted Contracting Officer at the California State Office (CASO), Bureau of Land Management (BLM) performing authorized duties in conjunction with this contract. The contracts required completion date is 395 calendar days after receipt of the notice to proceed.
Additional 45 calender days after receipt of the notice to proceed (issued seperately) for Additive Bid Item 03 - Doyle Fitness Center if awarded.
(END OF SECTION)
Amendment 0001
Solicitation No. 140L1223B0001
F-1
SECTION F - DELIVERIES OR PERFORMANCE
CLAUSES INCORPORATED BY REFERENCE
Clause Title Date 52.211-13 Time Extensions SEP 2000 52.242-14 Suspension of Work APR 1984
CLAUSES INFORPORATED BY FULL TEXT
52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK APR 1984
The Contractor shall be required to
(a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed,
(b) prosecute the work diligently, and
(c) complete the entire work ready for use not later than 395 calendar days after the date the Contractor receives the notice to proceed. Additional 45 calender days after receipt of the notice to proceed (issued separately) for Additive Bid Item 03 "Doyle Fitness Center" if awarded. The time stated for completion shall include final cleanup of the premises.
52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION SEP 2000
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,393.00 for each calendar day of delay until the work is completed or accepted.
(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(END OF SECTION)
M-1
SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS
Attachment Number List of Documents, Exhibits, and other Attachments
1 B08 Attach 1 Statement of Work Rev 19 Jul 2023
B08 Attach 1 SOW EX 1 Project Specifications (Doyle Fire Station)
B08 Attach 1 SOW EX 2 Project Drawings (Doyle Fire Station)
B08 Attach 1 SOW EX 3 Supplemental Specifications (Doyle Fitness Center)
B08 Attach 1 SOW EX 4 Supplemental Drawings (Doyle Fitness Center)
B08 Attach 1 SOW EX 5 As-Builts Drawings
B08 Attach 1 SOW EX 6 DRAFT Stormwater Pollution Prevention Plan Vol. 1-4
2 B03 Attach 2 Wage Determination CA20230007 Rev 15 30 June 2023
3* B08 Attach 3 Price Schedule
*Document will not be incorporated in the subsequent contract award.
Construction wage rate requirements are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are included in this Section. Applicable wage rates can be found at https://sam.gov/content/wage-determinations.
END OF SECTION
https://sam.gov/content/wage-determinations
File details come from the government source that posted it. Updated .