1305M224R0081.pdf

1305M224R0081

SOLICITATION, OFFER AND AWARD

4. TYPE OF SOLICITATION2. CONTRACT NUMBER 3. SOLICITATION NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO (If other than Item 7)

System (DPAS) - Code of Federal Regulations - at 15 CFR 700.

6. REQUISITION/PURCHASE NUMBER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

NEGOTIATED (RFP) REQUEST FOR

SEALED BID (IFB) INVITATION FOR BID

5. DATE ISSUED

1. This Contract is a Rated Order under the Defense Priorities and Allocations RATING PAGE OF PAGES

1 78

C. E-MAIL ADDRESS

EXT.NUMBERAREA CODE

B. TELEPHONE (NO COLLECT CALLS)A. NAME

10. FOR

INFORMATION

CALL:

CAUTION: LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

(Date)(Hour) local timeuntildepository located in copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if hand carried, in the

SOLICITATION

9. Sealed offers in original and

PART IV - REPRESENTATIONS AND INSTRUCTIONS

OTHER STATEMENTS OF OFFERORS

EVALUATION FACTORS FOR AWARD

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND

LIST OF ATTACHMENTS

CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

I

J

K

L

M SPECIAL CONTRACT REQUIREMENTS

CONTRACT ADMINISTRATION DATA

DELIVERIES OR PERFORMANCE

INSPECTION AND ACCEPTANCE

PACKAGING AND MARKING

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

SUPPLIES OR SERVICES AND PRICES/COSTS

SOLICITATION/CONTRACT FORM

PART II - CONTRACT CLAUSESPART I - THE SCHEDULE

H

G

F

E

D

C

B

A

SEC. DESCRIPTION PAGE(S) (X) DESCRIPTION SEC. (X)

11. TABLE OF CONTENTS

18. OFFER DATE17. SIGNATURE

SUCH ADDRESS IN SCHEDULE.

IS DIFFERENT FROM ABOVE - ENTER

15C. CHECK IF REMITTANCE ADDRESS

EXTENSIONNUMBERAREA CODE

15B. TELEPHONE NUMBER

(Type or print)AND

ADDRESS

OF

OFFEROR

CODE FACILITY

16. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER15A. NAME

DATEAMENDMENT NO.DATEAMENDMENT NO.

and related documents numbered and dated):

amendments to the SOLICITATION for offerors

(The offeror acknowledges receipt of

14. ACKNOWLEDGEMENT OF AMENDMENTS

CALENDAR DAYS (%)30 CALENDAR DAYS (%)20 CALENDAR DAYS (%)10 CALENDAR DAYS (%)

(See Section I, Clause No. 52.232.8)

13. DISCOUNT FOR PROMPT PAYMENT

designated point(s), within the time specified in the schedule.

by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

OFFER (Must be fully completed by offeror)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

28. AWARD DATE

(Signature of Contracting Officer)

27. UNITED STATES OF AMERICA

25. PAYMENT WILL BE MADE BY

26. NAME OF CONTRACTING OFFICER (Type or print)

CODE 24. ADMINISTERED BY (If other than Item 7)

ITEM

(4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN

41 U.S.C. 3304 (a) ( 10 U.S.C. 3204 (a) (

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION UNDER THE

21. ACCOUNTING AND APPROPRIATION20. AMOUNT19. ACCEPTED AS TO ITEMS NUMBERED

AWARD (To be completed by government)

CODE

140802-24-048709/19/2024 X

EAD-OMAO

EAD-OMAO

FED BLDG 200 GRANBY ST SUITE 815

NORFOLK VA 23510

1600 ES 11/27/2024

SHANNON GRISCOM 757

SHAWN.GRISCOM@NOAA.GOV

302-7783

X

X

X

X

X

X

X

X

X

X

X

X

X

PAGE(S)

ASHLEY PERRY

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is unusable

STANDARD FORM 33 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214(c)

12. In compliance with the above, the undersigned agrees, if this offer is accepted within _____180_________ calendar days (60 calendar days unless a different period is inserted

PROPOSAL

UNITED STATES CODE AT:

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 78

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

1305M224R0081

(A) (B) (C) (D) (E) (F)

1000 Base Work Items - Class 20000

See Section J - Attachment J.10 Schedule of Items and Prices

Anticipated Award Type: Firm-fixed-price

Product/Service Code: 1910

2000 Additional Item Requirements-Growth

See Section J - Attachment J.10 Schedule of Items and Prices

**Provide breakdown, as follows:

AIRs/Growth Labor Rate

Unit Price: $________; Quantity: 65,000 Unit of

Issue: Hour; Extended Price: $____________

AIRs/Growth Material Markup/Handling Fee

Unit Price: $500,000.00; Quantity: 1; Unit of

Issue: Percent ________%;

Extended Price: [$500,000.00 X percentage quoted]: $______________

Anticipated Award Type: Firm-fixed-price

Product/Service Code: 1910

3000 Optional Work Items - Class 60000

See Section J - Attachment J.10 Schedule of Items and Prices.

Anticipated Award Type: Firm-fixed-price

(Option Line Item)

Product/Service Code: 1910

OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

NSN 7540-01-152-8067

1305M224R0081 BASE

Section A - Solicitation/Contract Form Section B - Supplies or Services/Prices Section C - Description/Specifications Section D - Packaging and Marking Section E - Inspection and Acceptance Section F - Deliveries or Performance Section G - Contract Administration Data Section H - Special Contract Requirements Section I - Contract Clauses Section J - List of Documents, Exhibits and Other Attachments Section K - Representations, Certifications, and Other Statements of Bidders Section L - Instructions, Conditions, and Notices to Bidders Section M - Evaluation Factors for Award

Section A - Solicitation/Contract Form

STANDARD FORM 33 - SOLICITATION, OFFER AND AWARD.

Section B - Supplies or Services/Prices

1. This acquisition will be competed utilizing Federal Acquisition Regulation (FAR) Part 12, Acquisition of Commercial Products and Commercial Services utilizing the procedures in FAR Part 15, Contracting by Negotiation.

2. The contractor shall perform all work in accordance with the Work Specification titled "Attachment J.1 NOAA Oscar Dyson Fisheries Survey Vessel (FSV) Midlife Extension Program Work Specification”.

3. This solicitation is a Request for Proposal (RFP). See Sections L and M, respectively, for instructions regarding submission of offers and the evaluation factors for award.

4. The North American Industry Classification System (NAICS) code for this acquisition is 336611, Ship Building and Repairing. The small business size standard is 1,300 employees.

5. FAR, Commerce Acquisition Regulations (CAR), and the National Oceanic and Atmospheric Administration (NOAA), NOAA Acquisition Manual (NAM), Acquisition and Grants Office (AGO), Eastern Acquisition Division (EAD) provisions and clauses that are included in this solicitation are annotated by the applicable acronym.

6. The Price portion shall be completed using Attachment J.10 Schedule of Items and Prices (found in Section J, List of Attachments).

Section C - Description/Specifications

The Contractor shall furnish the necessary personnel, material, equipment, services, and facilities (Except as otherwise specified) to perform the Work Specification referenced as an attachment in Section J – List of Documents, Exhibits, and Other Attachments. The Work Specification is a combination of 91 Base Work Items, Additional Item Requirements, and 19 Optional Work Items.

Section D - Packaging and Marking

Mark All Government Furnished Material in the following manner:

National Oceanic Atmospheric Administration Oscar Dyson - Midlife Extension Program Contract Number: To be Determined Attn: Frank Wood, Contracting Officer Representative

Section E - Inspection and Acceptance

CAR 1352.246-70 Place of acceptance. (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

The place of acceptance shall be at the contractor’s proposed certified dry dock facility capable of docking the vessel that is geographically located in the Continental United States, Alaska, or Hawaii.

(End of clause)

Section F - Deliveries or Performance

CAR 1352.270-70 Period of Performance (APR 2010)

(a) The period of performance of this contract shall be from date of award through April 25, 2027.

The repair period shall start on April 26, 2026.

Section G - Contract Administration Data

CAR 1352.201-70 Contracting Officer's Authority. (MAR 2010)

CAR 1352.201-72 Contracting Officer's Representative (APR 2010)

(a) Frank Wood is hereby designated as the Contracting Officer’s Representative (COR).

The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Marine Operations Center – Pacific 2002 SE Marine Science Drive Newport, OR 97365

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

CAR 1352.245-70 Government furnished property. (APR 2010)

The Government will provide the following item(s) of Government property to the contractor . The contractor shall be accountable for, and have stewardship of, the property in the performance of this contract. This property shall be used and maintained by the contractor in accordance with provisions of the "Government Property" clause included in this contract.

A List of Government Furnished Material is provided in Section J - Attachment J.7 Government Furnished Material.

Section H - Special Contract Requirements

CAR 1352.208-70 Restrictions on printing and duplicating. (APR 2010)

CAR 1352.209-72 Restrictions against disclosure. (APR 2010)

CAR 1352.209-73 Compliance with the laws. (APR 2010)

CAR 1352.209-74 Organizational conflict of interest. (APR 2010)

CAR 1352.271-70 Inspection and manner of doing work. (APR 2010)

CAR 1352.271-75 Delivery and shifting of the vessel. (APR 2010)

CAR 1352.271-76 Performance. (APR 2010)

CAR 1352.271-77 Delays. (APR 2010)

CAR 1352.271-78 Minimization of delay due to Government furnished property. (APR 2010)

CAR 1352.271-79 Liability and insurance. (APR 2010)

CAR 1352.271-80 Title. (APR 2010)

CAR 1352.271-81 Discharge of liens. (APR 2010)

CAR 1352.271-82 Department of Labor occupational safety and health standards for ship repair. (APR 2010)

CAR 1352.271-83 Government review, comment, acceptance and approval. (APR 2010)

CAR 1352.271-84 Access to the vessel. (APR 2010)

CAR 1352.271-85 Documentation of requests for equitable adjustment. (APR 2010)

CAR 1352.271-86 Lay days. (APR 2010)

CAR 1352.271-87 Changes-ship repair. (APR 2010)

CAR 1352.271-89 Temporary services. (APR 2010)

CAR 1352.271-71 Method of Payment and Invoicing Instructions for Ship Repair (APR 2010)

(a) The Government will make payment under this contract based on a percentage of completion. The contractor may invoice for the percentage completed for each work item as work progresses. The amount invoiced shall be calculated based on prices stated in the Schedule, as follows: A work item may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that work item have no limitation as to the percentage of completion required before invoicing, but in no event may invoices be submitted more frequently than every 2 weeks, or for amounts less than $10,000, unless it is the final payment. The minimum percentage of completion (25%) to be reached prior to billing each work item may be waived by the Contracting Officer for large dollar work items on a case-by-case basis.

(b) Invoices submitted by the contractor which are deemed not proper, in accordance with FAR 52.232- 25, will be returned. Invoices shall include:

(1) Name and Address of the contractor;

(2) DUNS Number;

(3) Invoice Date;

(4) Contract Number/Modification Number;

(5) CLIN/Work Item Number, to include: Description, Quantity, Unit of Measure, Unit Price and Extended Price;

(6) Shipping and Payment Terms; and,

(7) Contractor Point of Contact, including: Name, Title, Phone Number, and Mailing Address;

(8) The percentage of completion for each CLIN/work item identified;

(9) Name of the Contracting Officer ;

(10) Ship name;

(11) The overall percentage and dollar amount previously billed, currently billed and unbilled.

(c) When invoicing for changed work, the contractor shall identify it as a contract change and shall identify the modification authorizing the change, and the CLIN/Work Item associated with the change.

(d) All items of work invoiced under this contract will be verified and confirmed by the Contracting Officer's Representative as accurate and complete and approved by the designated billing office before payment will be made.

(e) Invoices shall be submitted electronically through the Invoice Processing Platform System.

A copy of all invoices shall be sent by electronic mail to the COR and contract administration office as follows:

Ashley.Perry@noaa.gov Shawn.Griscom@noaa.gov Frank.Wood@noaa.gov

Payment will be made by the designated payment office, which is Department of Commerce, Financial Management Division, 7600 Sand Point Way NE, Seattle, WA 98115.

(f) The contractor's final invoice submitted under the contract must be marked as follows: “THIS INVOICE CONSTITUTES THE FINAL INVOICE - UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE

DUE UNDER CONTRACT NUMBER 1305M224CXXXX."

(Award Number will be given at time of award.)

(End of Clause)

CAR 1352.271-73 Schedule of Work. (APR 2010

(a) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents at the time of proposal submission:

(1) Production Schedule.

(2) Work Package Network.

(3) Total Manpower Loading Curve.

(4) Trade Manning Curves.

(5) Subcontracting List.

(b) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(c) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting.

Any anticipated or unanticipated deviation (greater than five (5) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR.

(d) Any unauthorized deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance, including, but not limited to, liquidated damages.

Commerce Ombudsman

The NOAA Ombudsman program is discontinued. The task and delivery order ombudsman is the Department of Commerce Director of Acquisition Policy and Oversight Division who can be reached by emailing OAM_Mailbox@doc.gov.

PROCUREMENT MEMORANDUM (PM) 2024-01 BAS Program PRISM: FedConnect (Effective October 24, 2023)

UTILIZATION OF FEDCONNECT FOR CONTRACT ADMINISTRATION

The Department of Commerce will utilize the FedConnect web portal in administering this award. The contractor must be registered in FedConnect and have access to the FedConnect website located at https://www.fedconnect.net/Fedconnect/. For assistance in registering or for other FedConnect questions please call the FedConnect Help Desk at (800) 899-6665 or email at support@fedconnect.net.

There is no charge for registration in or use of FedConnect.

(End)

CAR 1352.237-75 Key personnel. (APR 2010)

(a) The contractor shall assign to this contract the following key personnel:

Position Title: Project Manager

Position Title: Procurement Manager

Position Title: Ship Superintendent

Position Title: Scheduler

Position Title: Test/ Trials Manager

Position Title: Quality Control/ Quality Assurance (AQ/QC) Manager

(b) The contractor shall obtain the consent of the Contracting Officer prior to making key personnel substitutions. Replacements for key personnel must possess qualifications equal to or exceeding the qualifications of the personnel being replaced, unless an exception is approved by the Contracting Officer.

(c) Requests for changes in key personnel shall be submitted to the Contracting Officer. During the first 180 days of the performance period, no key personnel substitutions will be permitted unless such substitutions are necessitated by an individual's sudden illness, death, or termination of employment, or as otherwise approved by the CO. In any of these events, the contractor shall promptly notify the CO. After the initial 180 day period at least 30 working days prior to making any permanent substitutions. The request should contain a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. The Contracting Officer will notify the contractor within 10 working days after receipt of all required information of the decision on substitutions. The contract will be modified to reflect any approved changes.

(End of clause)

CAR 1352.271-72 Additional Item Requirements (AIR)-growth work (APR 2010)

(a) This clause applies to Additional Item Requirements (AIR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes-Ship Repair clause or mutually agreed upon by the parties. The contractor shall perform AIR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The AIR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling. The estimated quantity of labor hours and handling fees represent the Government's best estimate for growth that may be required throughout the contract performance period. All growth work shall be paid at the prices stated in the Schedule.

(b) The contractor shall take into account the potential for ordering all estimated AIR quantities in developing the Production Schedule. The ordering of any portion of the AIR quantities does not in itself warrant an extension to the original contract completion date; however, for planning purposes, the Government anticipates ordering AIR in accordance with the following schedule:

(1) No more than 75% of the hours during the first half of the contract period of performance.

(2) No more than 50% of the hours during the third quarter of the contract period of performance.

(3) No more than 30% of the hours during the fourth quarter of the contract period of performance.

(c) The AIR labor rate shall be a flat, hourly rate to cover the entire effort and shall be burdened to include:

(1) Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production: Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging.

(2) Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include:

Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire Watch, General Labor (including general support of journeyman tasks), Cleaning (including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making).

(d) Additional Item Requirements do not include replacement work performed pursuant to the Inspection and Manner of Doing Work or Guarantees clauses.

(e) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(f) The contractor shall submit to the Contracting Officer the following information in all AIR proposals:

(1) Number of labor hours estimated; broken down by specific direct production labor category.

(2) Material estimates, individually broken out and priced. When requested by the Contracting Officer, material quotes shall be provided.

(3) Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer.

(4) Material/subcontractor handling fee and the basis for the fee.

(g) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

(End of clause)

CAR 1352.271-88 Guarantees. (APR 2010)

(a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 90 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 90day period until its expiration.

(c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item.

(d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs.

(1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense.

(2) Where corrections and repairs are to be made by other than the contractor due to nonreturn of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract.

(e) The contractor's liability shall only extend for an additional 90 day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and Insurance clause.

(f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

(g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause.

(End of clause)

CAR 1352.271-90 Insurance requirements. (APR 2010)

(a) The contractor shall procure and thereafter maintain the following insurance:

(1) Ship contractor's legal liability insurance to insure the risks described in paragraph

(b) of clause 1352.271-79. This insurance shall be for $1,000,000.00.

(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.

(3) Full coverage in accordance with the State Worker's Compensation law; and

(4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act.

(b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number (To Be Provided At The Time Of Award) for repair/alteration of (name of vessel) in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (APR 2010) and that each such policy contains the following clause:

"It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer."

Section I - Contract Clauses

Clauses Incorporated by Reference Clause Number Clause Title

52.202-1 Definitions. (JUN 2020) 52.203-3 Gratuities. (APR 1984)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (JUN 2020)

52.204-9 Personal Identity Verification of Contractor Personnel.

(JAN 2011)

52.204-13 System for Award Management Maintenance. (OCT 2018)

52.204-18 Commercial and Government Entity Code Maintenance.

(AUG 2020)

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.212-4 Contract Terms and Conditions - Commercial Products and Commercial Services. (NOV 2023)

52.227-1 Authorization and Consent. (JUN 2020)

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. (JUN 2020)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.232-8 Discounts for Prompt Payment. (FEB 2002) 52.232-11 Extras. (APR 1984) 52.232-17 Interest. (MAY 2014) 52.242-13 Bankruptcy. (JUL 1995) 52.245-1 Government Property. (SEP 2021) 52.245-9 Use and Charges. (APR 2012) 52.253-1 Computer Generated Forms. (JAN 1991)

Full Text Clauses

FAR 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders - Commercial Products and Commercial Services. (MAY 2024)(DEVIATION JAN 2024)

As prescribed in 12.301(b)(4), insert the following clause:

Contract Terms and Conditions Required to Implement Statutes or Executive Orders— Commercial Products and Commercial Services (DEC 2023) (DEVIATION JAN 2024)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) ( 31 U.S.C.

3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 4655).

X (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X (4) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

X (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub.

L. 109-282) ( 31 U.S.C. 6101 note).

__ (6) [Reserved].

__ (7) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

X (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

X (10) 52.204–28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (DEC 2023) ( Pub. L. 115–390, title

II).

X (11)(i) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub.

L. 115–390, title II).

__ (ii) Alternate I (DEC 2023) of 52.204–30.

X (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) ( 31 U.S.C. 6101 note).

X (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) ( 41 U.S.C. 2313).

__ (14) [Reserved].

__ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) ( 15 U.S.C. 657a).

__ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

__ (17) [Reserved] __ (18) __(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-6.

__ (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-7.

X (20) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)).

X (21)(i) 52.219-9, Small Business Subcontracting Plan (SEP 2023) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (NOV 2016) of 52.219-9.

__ (iii) Alternate II (NOV 2016) of 52.219-9.

__ (iv) Alternate III (JUN 2020) of 52.219-9.

__ (v) Alternate IV (SEP 2023) of 52.219-9.

__ (22)(i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) ( 15 U.S.C. 644(r)).

__ (ii) Alternate I (MAR 2020) of 52.219-13.

__ (23) 52.219-14, Limitations on Subcontracting (OCT 2022) ( 15 U.S.C. 637s).

X (24) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__ (25) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (OCT 2022) ( 15 U.S.C. 657f).

__ (26) X (i) 52.219-28, Post Award Small Business Program Representation (SEP 2023)( 15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (MAR 2020) of 52.219-28.

__ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (OCT 2022) ( 15 U.S.C. 637(m)).

__ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) ( 15 U.S.C. 637(m)).

__ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) ( 15 U.S.C. 644(r)).

X (30) 52.219-33, Nonmanufacturer Rule (SEP 2021) ( 15U.S.C. 637(a)(17)).

X (31) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

X (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (NOV 2023), (DEVIATION JAN 2024)(a)Applicability. This clause does not apply to the extent that the Contractor is supplying end products mined, produced, or manufactured in— * * *

(1) Mexico, and the anticipated value of the acquisition is $92,319[$102,280] or more; or (2) * * *and the anticipated value of the acquisition is $183,000[$174,000] or more.

X (33) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

X (34) (i) 52.222-26, Equal Opportunity (SEP 2016) (E.O.11246).

__ (ii) Alternate I (FEB 1999) of 52.222-26.

X (35) (i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (JUL 2014) of 52.222-35.

X (36)(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (JUL 2014) of 52.222-36.

X (37) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

X (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

X (39) (i) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (40) 52.222-54, Employment Eligibility Verification (MAY 2022) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__ (41)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (MAY 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

X (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

X (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

X (44)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (OCT 2015) of 52.223-13.

X (45)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun2014) of 52.223-14.

X (46) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) ( 42 U.S.C. 8259b).

__ (47)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (JUN 2014) of 52.223-16.

X (48) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O.

13513).

__ (49) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

__ (50) 52.223-21, Foams (Jun2016) (E.O. 13693).

__ (51)(i) 52.224-3 Privacy Training (JAN 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (JAN 2017) of 52.224-3.

X (52) (i) 52.225-1, Buy American-Supplies (OCT 2022) ( 41 U.S.C. chapter 83).

__ (ii) Alternate I (OCT 2022) of 52.225-1.

__ (53)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501- 4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112- 41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (DEC 2022) of 52.225-3.

__ (iv) Alternate III (NOV 2023) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (54) 52.225-5, Trade Agreements (NOV 2023) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

__ (55) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (56) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__ (57) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ( 42 U.S.C. 5150).

__ (58) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) ( 42 U.S.C. 5150).

__ (59) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

__ (60) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services

(NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

__ (61) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

X (62) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (OCT2018) ( 31

U.S.C. 3332).

__ (63) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332).

__ (64) 52.232-36, Payment by Third Party (MAY 2014) ( 31 U.S.C. 3332).

__ (65) 52.239-1, Privacy or Security Safeguards (AUG 1996) ( 5 U.S.C. 552a).

X (66) 52.242-5, Payments to Small Business Subcontractors (JAN 2017) ( 15 U.S.C. 637(d)(13)).

__ (67) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631).

__ (ii) Alternate I (APR 2003) of 52.247-64.

__ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] __ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter67).

__ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

__ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

__ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) ( 42 U.S.C.

1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by KasperskyLab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a Byte Dance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii)

(A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub. L.

115–390, title II).

(B) Alternate I (DEC 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(x) 52.222-26, Equal Opportunity (SEP 2015) (E.O.11246).

(xi) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O.

13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

X (xvi)(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

(xix) 52.222-54, Employment Eligibility Verification (MAY 2022) (E.O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(xxii) (A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C.

1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C.

55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247- 64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

FAR 52.219-14 Limitations on Subcontracting (OCT 2022) (DEVIATION SEPT 2021)

As prescribed in 19.507(e), insert the following clause:

LIMITATIONS ON SUBCONTRACTING (SEP 2021) (DEVIATION SEP 2021)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that—

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to—

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are—

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are—

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or

19.15…