Desert Visions Renovations
Closed Solicitation Posted
This opportunity was awarded. See the award notice from .
- Solicitation number
- 75H70123R00007
- Agency
- Indian Health Service Department of Health and Human Services
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Sacaton, Arizona 85147, United States
Notice details come from SAM.gov. Updated .
About this opportunity
The Indian Health Service is soliciting proposals to provide construction services for renovations and modifications to the Desert Visions Youth Wellness Center in Sacaton, Arizona. The scope of work includes landscaping and irrigation, replacing concrete surfaces, installing new roofs and flooring, renovating the pool area, and replacing plumbing fixtures. The period of performance is 180 calendar days from notice to proceed, with an estimated contract value between $500,000 and $1,000,000. Proposals will be evaluated using lowest price technically acceptable criteria. The closing date for submissions is December 1, 2022.
This opportunity is designated as a total small business set-aside for firms with average annual revenue less than $39.5 million. The primary NAICS code is 238210 and PSC code S206. The place of performance is Sacaton, Arizona. Tribal employment requirements apply to work performed on tribal lands. Registration in the System for Award Management is mandatory to be eligible for award.
Notice text
4 versions
Update #4 · Latest ·
***Amendment A0003 - See document B05 Amend A0003 for details.
***Amendment A0002 - See document B05 Amend A0002 for details.
***Amendment A0001 - See document B05 Amend A0001 for the site visit sign-in sheet. All other terms remain unchanged.
SCOPE OF WORK:
The purpose of this project is to provide construction services for the renovation and modification of the Desert Visions Youth Wellness Center in Sacaton, AZ.
The primary goal of this work is to provide for the following:
- Landscape and provide irrigation of the grounds of Desert Visions
- Replace concrete panels and paint the court for basketball and pickelball
- Provide concrete sidewalk in the courtyard between dormitories
- Seal west parking lot
- Resurface east parking lot
- Provide new roofs for all buildings
- Provide new epoxy floor in the walk-in freezer
- Replace flooring in the serving & dining area with tile
- Resurface the pool area, provide anchor point for basketball hoop & replace pool system
- Provide Cured-In-Place Pipe interior to and exterior of building 100
- Provide new plumbing fixtures
LOCATION OF PROJECT: The Project is to be performed at the following site: Sacaton, AZ.
TERO: TERO fees do apply.
PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed.
CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204.
SITE VISIT: Details regarding the Site Visit will be included in the solicitation.
CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria.
NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES.
For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov.
Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM.
It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties.
Update #3 ·
***Amendment A0002 - See document B05 Amend A0002 for details.
***Amendment A0001 - See document B05 Amend A0001 for the site visit sign-in sheet. All other terms remain unchanged.
SCOPE OF WORK:
The purpose of this project is to provide construction services for the renovation and modification of the Desert Visions Youth Wellness Center in Sacaton, AZ.
The primary goal of this work is to provide for the following:
- Landscape and provide irrigation of the grounds of Desert Visions
- Replace concrete panels and paint the court for basketball and pickelball
- Provide concrete sidewalk in the courtyard between dormitories
- Seal west parking lot
- Resurface east parking lot
- Provide new roofs for all buildings
- Provide new epoxy floor in the walk-in freezer
- Replace flooring in the serving & dining area with tile
- Resurface the pool area, provide anchor point for basketball hoop & replace pool system
- Provide Cured-In-Place Pipe interior to and exterior of building 100
- Provide new plumbing fixtures
LOCATION OF PROJECT: The Project is to be performed at the following site: Sacaton, AZ.
TERO: TERO fees do apply.
PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed.
CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204.
SITE VISIT: Details regarding the Site Visit will be included in the solicitation.
CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria.
NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES.
For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov.
Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM.
It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties.
Update #2 ·
***Amendment A0001 - See document B05 Amend A0001 for the site visit sign-in sheet. All other terms remain unchanged.
SCOPE OF WORK:
The purpose of this project is to provide construction services for the renovation and modification of the Desert Visions Youth Wellness Center in Sacaton, AZ.
The primary goal of this work is to provide for the following:
- Landscape and provide irrigation of the grounds of Desert Visions
- Replace concrete panels and paint the court for basketball and pickelball
- Provide concrete sidewalk in the courtyard between dormitories
- Seal west parking lot
- Resurface east parking lot
- Provide new roofs for all buildings
- Provide new epoxy floor in the walk-in freezer
- Replace flooring in the serving & dining area with tile
- Resurface the pool area, provide anchor point for basketball hoop & replace pool system
- Provide Cured-In-Place Pipe interior to and exterior of building 100
- Provide new plumbing fixtures
LOCATION OF PROJECT: The Project is to be performed at the following site: Sacaton, AZ.
TERO: TERO fees do apply.
PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed.
CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204.
SITE VISIT: Details regarding the Site Visit will be included in the solicitation.
CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria.
NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES.
For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov.
Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM.
It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties.
Update #1 ·
SCOPE OF WORK:
The purpose of this project is to provide construction services for the renovation and modification of the Desert Visions Youth Wellness Center in Sacaton, AZ.
The primary goal of this work is to provide for the following:
- Landscape and provide irrigation of the grounds of Desert Visions
- Replace concrete panels and paint the court for basketball and pickelball
- Provide concrete sidewalk in the courtyard between dormitories
- Seal west parking lot
- Resurface east parking lot
- Provide new roofs for all buildings
- Provide new epoxy floor in the walk-in freezer
- Replace flooring in the serving & dining area with tile
- Resurface the pool area, provide anchor point for basketball hoop & replace pool system
- Provide Cured-In-Place Pipe interior to and exterior of building 100
- Provide new plumbing fixtures
LOCATION OF PROJECT: The Project is to be performed at the following site: Sacaton, AZ.
TERO: TERO fees do apply.
PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed.
CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204.
SITE VISIT: Details regarding the Site Visit will be included in the solicitation.
CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria.
NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES.
For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov.
Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM.
It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties.
Attachments
| File | Type | Posted |
|---|---|---|
| B05 Amend A0003.pdf | ||
| Asbestos Survey Bldg 200.pdf | ||
| Asbestos Survey Bldg 300.pdf | ||
| Asbestos Survey Bldg 100.pdf | ||
| Asbestos Survey Bldg 500.pdf | ||
| Asbestos Survey Bldg 600.pdf | ||
| Asbestos Survey Bldg 400.pdf | ||
| Attachment J02 Renovation Drawings R1.pdf | ||
| B05 Amend A0002.pdf | ||
| B01 75H70123R00007.pdf | ||
| B05 Amend A0001.pdf | ||
| B01 Attachment J01 - Wage Determination AZ20220033.pdf | ||
| B01 Attachment J06 - ICRA Permit DV.pdf | ||
| B01 Attachment J05 - 2022 Exemption Letter for a Qualifying Hospital.pdf | ||
| B01 Attachment J04 - PPQ.docx | DOCX document | |
| B01 Attachment J03 - Self Performed Calculation Sheet (Construction).docx | DOCX document | |
| B01 Attachment J02 - Renovation drawing COMP 083022.pdf | ||
| B01 75H70123R00007.pdf |
Show all 18
Notice history
| Notice | Type | Posted |
|---|---|---|
| Desert Visions Renovations | Award Notice | |
| Desert Visions Renovations | Solicitation | |
| Desert Visions Renovations | Pre-Solicitation | |
| Desert Visions Renovations | Pre-Solicitation |
On GovTribe
Work this opportunity on GovTribe
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity